Investigation of Factors Affecting Termination of Construction Contracts in Gaza Strip
Investigation of Factors Affecting Termination of Construction Contracts in Gaza Strip
Researcher:
Eng. Khalil Hamdan Abu Eed
Supervisor:
Dr. Nabil I. El Sawalhi
of Palestine.
v Every person who offers a useful science, a good deal, for the
II
Acknowledgment
III
Abstract
Construction contracts are one of the high risky contracts because of its unique features
such as long period, complicated processes, unexpected environment, financial intensity
and dynamic organization structures.
The major objective of this research was to identify and investigate the factors affecting
the construction contracts termination in the Gaza Strip. Also, to check the current
situation for construction contracts termination in Gaza from contractor 's respective.
This research relied mainly on analytical, descriptive and field study methodologies.
And the questionnaire was designed in the light of the literature review and tested by
pilot study, and then it is applied on a sample of 73 contracting companies. The
collected data is manipulated by Excel and SPSS software using many statistical tools
such as, frequencies, percentile values, means and coloration coefficient tests.
The results show that most companies have an experience over than ten years exposed
to contract termination, which was referred to donors. Most of their employees were
satisfied about the administrative level of their companies and directors have the final
decision especially to regarding financial issues.
The results of analyzing 51 causes of contracts termination showed that the main cause
of termination are: closure, lack of resources, contractors bankruptcy or insolvent,
increment of material prices, lack of experience in the line of work, wrong cost
estimation, lack of capital, working at hot (dangerous) areas, low margin of profit due to
competition and difference of local currency exchange with contract currency. 40% of
the most important factors affecting the construction contracts termination are related to
financial issues while 30% of the most important factors are related to political issues.
This study recommended that the contracting companies should estimate cost of project
with proper way and should not increase the number of projects over the capacity of the
company. Documentation works should be applied widely in the industry, Contractors
are recommended to qualify technical staff with appropriate experience of the project.
The government must take the risk when the donors delay the debts of the contractors
and try to save a new resource or internal fund. The PCU should conduct continuous
training programs to contractors in this field (Construction contracts termination).
IV
ﻣﻠﺧص اﻟﺑﺣث
ﺗﻌﺗﺑر اﻟﻌﻘود اﻹﻧﺷﺎﺋﯾﺔ ﻣن اﻟﻌﻘود اﻟﺧطرة ﺑﺳﺑب ﺗﻣﯾزﻫﺎ ﺑﺄﻧﻬﺎ ﻓرﯾدة ﻣن ﺣﯾث اﻟﻔﺗرة اﻟطوﯾﻠﺔ وﻋﻣﻠﯾﺎت
اﻹﻧﺷﺎء اﻟﻣﻌﻘدة و اﻷﻣور اﻟﻣﺎﻟﯾﺔ اﻟﻛﺛﯾرة و اﻟﺑﯾﺋﺔ اﻟﻣﺣﯾطﺔ و ﻛﺛرة اﻟﻣوظﻔﯾن ﻓﯾﻪ.
اﻟﻬدف اﻟرﺋﯾﺳﻲ ﻣن ﻫذا اﻟﺑﺣث ﻫو ﺗﺣدﯾد درﺟﺔ ﺗﺄﺛﯾر ﻫذﻩ اﻟﻌواﻣل ﻋﻠﻰ إﻧﻬﺎء اﻟﻌﻘود اﻹﻧﺷﺎﺋﯾﺔ ﻓﻲ ﻗطﺎع
ﻏزة .وأﯾﺿﺎ ﺗﺣدﯾد اﻟﻌواﻣل اﻟﺣرﺟﺔ ﻣﻧﻬﺎ و دراﺳﺔ اﻟوﺿﻊ اﻟﺣﺎﻟﻲ ﻹﻧﻬﺎء ﻟﻠﻌﻘود ﻓﻲ اﻟﻘطﺎع ﻣن وﺟﻬﺔ ﻧظر
اﻟﻣﻘﺎول.
وﻗد اﻋﺗﻣدت ﻫذﻩ اﻟدراﺳﺔ ﻋﻠﻰ اﻟﻣﻧﻬﺞ اﻟوﺻﻔﻲ اﻟﺗﺣﻠﯾﻠﻲ وأﺳﻠوب اﻟدراﺳﺔ اﻟﻣﯾداﻧﯾﺔ ،ﺣﯾث ﺗم ﺗﺻﻣﯾم
اﺳﺗﺑﯾﺎن ﻛﺄداة ﻟﻠدراﺳﺔ وذﻟك ﻓﻲ ﺿوء أدﺑﯾﺎت اﻟﺑﺣث وﻧﺻﺎﺋﺢ اﻷﻛﺎدﯾﻣﯾﯾن واﻟﺧﺑراء ﻓﻲ ﻣﺟﺎل اﻹﻧﺷﺎءات.
وﻗد ﺗم ﻋﻣل ﻋﯾﻧﺔ اﺳﺗطﻼع ﻟﻼﺳﺗﺑﯾﺎن ﺛم ﺗطﺑﯾﻘﻪ ﻋﻠﻰ 73ﺷرﻛﺔ ﻣﻘﺎوﻻت ﻓﻲ ﻗطﺎع ﻏزة ،وﻗد اﺳﺗﺧدم
اﻟﺑرﻧﺎﻣﺞ اﻹﺣﺻﺎﺋﻲ Excel Sheetsو SPSSﻓﻲ ﻣﻌﺎﻟﺟﺔ اﻟﺑﯾﺎﻧﺎت وذﻟك ﺑﺗطﺑﯾق اﻟﻌدﯾد ﻣن اﻻﺧﺗﺑﺎرات
اﻹﺣﺻﺎﺋﯾﺔ ﻛﺣﺳﺎب اﻟﻧﺳب واﻟﺗﻛرار واﻟﻣﺗوﺳطﺎت وﻣﻌﺎﻣل اﻻرﺗﺑﺎط.
و ﻗد أوﺿﺣت اﻟﻧﺗﺎﺋﺞ أن ﻣﻌظم اﻟﺷرﻛﺎت ﻟﻬﺎ ﺧﺑرة ﻛﺑﯾرة ﻓﻲ ﻣﺟﺎل اﻹﻧﺷﺎءات وﻗد ﺗﻌرﺿت ﺧﻼل ﻫذﻩ
اﻟﻔﺗرة إﻟﻲ إﻧﻬﺎء ﻋﻘود إﻧﺷﺎﺋﯾﺔ ﻟﻬﺎ وأن اﻟﺳﺑب ﻓﻲ ذﻟك ﯾرﺟﻊ ﻟﻠﻣﻣوﻟﯾن .و ﻣﻌظم ﻣوظﻔﯾﻬم راﺿون ﻋن
اﻟﻣﺳﺗوي اﻹداري ﻟﻠﺷرﻛﺔ و أن ﺻﺎﺣب اﻟﻘرار اﻟﻧﻬﺎﺋﻲ ﻓﻲ اﻟﺷرﻛﺔ ﯾرﺟﻊ إﻟﻰ ﺻﺎﺣﺑﻬﺎ وﺧﺻوﺻﺎ ﻓﻲ اﻷﻣور
اﻟﻣﺎﻟﯾﺔ.
و أوﺿﺣت اﻟدراﺳﺔ ﺑﻌد ﺗﺣﻠﯾل 51ﻋﺎﻣل ﻣن اﻟﻌواﻣل اﻟﻣﺳﺑﺑﺔ ﻟﺗوﻗف اﻟﻌﻘود اﻹﻧﺷﺎﺋﯾﺔ أن أﻫم اﻟﻌواﻣل ﻫﻲ
اﻹﻏﻼق ،ﻧﻘص اﻟﻣوارد ،إﻓﻼس اﻟﻣﻘﺎول ،زﯾﺎدة أﺳﻌﺎر اﻟﻣواد ،ﻧﻘص اﻟﺧﺑرة ﻓﻲ ﻣﺟﺎل اﻟﻌﻣل،أﺧطﺎء ﻓﻲ
ﺗﻘدﯾر اﻟﺗﻛﻠﻔﺔ ،رأس اﻟﻣﺎل ﻏﯾر ﻛﺎﻓﻲ ،اﻟﻌﻣل ﻓﻲ اﻟﻣﻧﺎطق اﻟﺧطرة ،ﺗدﻧﻲ ﻣﺳﺗوى اﻟرﺑﺢ وﺗﻐﯾر ﺳﻌر ﺻرف
اﻟﻌﻣﻠﺔ اﻟﻣﺣﻠﯾﺔ ﺑﺎﻟﻧﺳﺑﺔ ﻟﻠﻌﻣﻼت اﻟﻣﺳﺗﺧدﻣﺔ ﻓﻲ اﻟﻌﻘود .وﺗﺑﯾن أن %40ﻣن اﻟﻌواﻣل ذات اﻷﻫﻣﯾﺔ اﻟﻌﺎﻟﯾﺔ
ﻧﺎﺗﺞ ﻋن اﻷﻣور اﻟﻣﺎﻟﯾﺔ ﺑﯾﻧﻣﺎ %30ﻣﻧﻬﺎ ﻧﺎﺗﺞ ﻋن اﻷوﺿﺎع اﻟﺳﯾﺎﺳﯾﺔ.
وﻗد أوﺻت ﻫذﻩ اﻟدراﺳﺔ ﺷرﻛﺎت اﻟﻣﻘﺎوﻻت ﺑﺗﻘدﯾر ﺗﻛﻠﻔﺔ اﻟﻌﻘود ﺑطرﯾﻘﺔ ﺻﺣﯾﺣﺔ وﻋدم زﯾﺎدة اﻟﻣﺷﺎرﯾﻊ ﻟدﯾﻬﺎ
واﺳﺗﺧدام ﻧظﺎم اﻟﺗوﺛﯾق ﻟدﯾﻬﺎ ﺑﺷﻛل أوﺳﻊ وﻋﻠﻰ أﺻﺣﺎب اﻟﺷرﻛﺎت ﺗﻌﯾﯾن ﻣوظﻔﯾن ﻣؤﻫﻠﯾن وذو ﺧﺑرة
ﻣﻧﺎﺳﺑﺔ.
ﻛﻣﺎ أوﺻت اﻟدراﺳﺔ اﻟﺣﻛوﻣﺔ أن ﺗﺗﺣﻣل اﻟﻣﺧﺎطر اﻟﻧﺎﺗﺟﺔ ﻣن ﺗﺄﺧر اﻟﻣﻣوﻟﯾن ﻓﻲ دﻓﻊ ﻣﺳﺗﺣﻘﺎت اﻟﻣﻘﺎوﻟﯾن
واﻟﺑﺣث ﻟﺗوﻓﯾر ﻣﺻدر ﺟدﯾد أو ﻣﺻدر داﺧﻠﻲ ﻟﻠﺗﻣوﯾل .وأوﺻت أﯾﺿﺎ اﺗﺣﺎد اﻟﻣﻘﺎوﻟﯾن أن ﯾﻌطﻲ دورات
ﻟﺗدرﯾب اﻟﻣﻘﺎوﻟﯾن ﻋﻠﻰ اﻷﻣور اﻟﻣﺗﻌﻠﻘﺔ ﺑﺎﻟﻌﻘود اﻹﻧﺷﺎﺋﯾﺔ وﺑﯾﺎن ﻟﻬم اﻟﻘواﻧﯾن واﻷﻧظﻣﺔ اﻟﻣﺗﻌﻠﻘﺔ ﺑذﻟك.
V
Table of Contents
Dedication ……………...………………………………………………….……….… II
Acknowledgement …………………….……………………………….……...…...… III
Abstract ..………………………………………..…….…………………...…………. IV
Arabic abstract ……………………...……...………………………..…………..….… V
Table of Contents ……………………………….…...………………………..….……VI
List of Tables ………………….……………..…………………………………...…... X
List of Figures………………………………….……………….………......….….…. XII
List of Equations …………………………………………………….……...…….… XIII
List of Annexes……………………...………………………………..…………...… XIII
List of Abbreviations …………………………...……………………………....…....XIV
Chapter 1
Introduction
1.1 Construction industry and Palestinian economy ……………….…………..…1
1.2 The Nature of the construction industry and risk …………….……………..…3
1.3 Construction project termination in Gaza Strip …………..…….…………..…4
1.4 The contractor's organization …………………....……..……….…………..…5
1.5 Research purpose ……………………………………….……….…….…...…5
1.6 Research problem …….………………………………….………………....…6
1.7 Research aims …….……..……………………………….………………....…6
1.8 Research objective ………………….……..…………….…………..……....…6
1.9 Research limitation ……………...…….....…………….…………..….…...…6
1.10 Research methodology ……………...…….......……….…………..….…...…6
1.11 Outline contents of the thesis………………………………….….……….....…7
Chapter 2
Construction Contracts Termination
2.1 Background for contacts …………………..…………………….…………..…8
2.1.1 Definitions……………………………………………………….…………..…8
2.1.2 Essential elements of a valid contract…………………...……….…………..…9
2.1.3 Contract documents………………………………..…………….…………..…10
2.1.4 Construction project stakeholders……………………………….…………..…11
VI
2.1.5 Type of contracts……………………………..………………..….…………….12
2.1.6 Factors influencing the choice of the type of contract….……….………...….…13
2.1.7 Preparing for contract management and providing oversight…………...………13
2.2 Construction project overview……………………..…………….…………....…14
2.2.1 Project success overview ……………………..……..………….…………....…15
2.2.2 Project failure overview……………………..……………...….……..….…..…15
2.2.3 Warning signs that a construction projects is in trouble………..………..…..…16
2.2.4 Risk in construction project……………………..…………….……..…….....…16
2.3 Termination of construction contracts…………..………………………..…..…17
2.3.1 Types of termination…………..……………..…….………………………...…17
2.3.2 Ways of termination …………..……………………………….………..…..…18
2.3.3 When to terminate a project…………..………………………………….…..…20
2.3.4 Typical contractual grounds to terminate…………..…………...……….…...…21
2.3.5 Notice of termination…………..………………..……………………….…...…22
2.3.6 Steps to proper termination…………..…………………………….……………22
2.3.7 The effectiveness of termination on project…………..…...………………....…23
2.3.8 Available damages from termination …………..…………………………....…23
2.3.9 Why PM's ignore termination…………..………………………………..…...…24
2.3.10 Prevention of construction project failure or termination………..…...….......…25
2.4 Previous studies for construction contracts termination…………..…………..…27
2.5 Common causes of project termination (Failure) …..………..……….…..…..…35
2.6 The 6 steps guide to a smooth closure (termination) …..……….…….….…..…38
2.6.1 Completion …..……………………………………………………...…….....…38
2.6.2 Documentation…..…………….…………..………………………...…….....…39
2.6.3 Project systems closure…..…….………….………………………...…..…...…39
2.6.4 Project reviews…..…………….…………..………………………...…..…...…39
3.6.5 Disband the project team…..…………….…………..…….………...……....…40
2.6.6 Stakeholder satisfaction…..………………..………………………...……....…40
2.7 Impacts of project parties (Stakeholders) on project termination……….…...…41
2.8 Methods of disputes on construction projects…..…………………...……...…43
VII
Chapter 3
Methodology
3.1 Introduction…..…………….………….......…..………………………….……..…45
3.2 Research design…..…………….……….……..………………………….……..…45
3.3 Research method…..…………….……………..………………………….……..…47
3.3.1 Primary data…..…………….…………..……………………………...…..…..…47
3.3.2 Secondary sources…..…………….…………..………………………...……..…47
3.4 Population…..…………….…………..………………………….........………..…..47
3.5 Sample size determination…..…………….…………………....……….....…....…47
3.6 Research location…..…………….…………..…………………………...……..…48
3.7 Questionnaire design and contents…..………...…………………….…...….…..…49
3.8 Pilot study…..…………….…………..……………………..…………….……..…50
3.9 Response rate…..…………….…………..…………………….………...……....…50
3.10 Validity of the research…..…………….……………..……………….....……..…51
3.10.1 Content validity of the questionnaire……..…………...……………...…..…..…51
3.10.2 Statistical validity of the questionnaire ……..…..……...………......……...…...51
3.11 Reliability of the research……..…………………….......………………….…..…53
3.11.1 Split-Half coefficient method……..……………...…...……………...……....…53
3.11.2 Cronbach's coefficient alpha……..………….………...……………...…..…..…53
3.12 Data measurement……..…………………….………….…………….....……..…54
3.13 Data collection……..…………...……………………………...…..…...…........…55
3.14 Data analysis……..…………...………………………………..…..…...…........…56
Chapter 4
4. Results and discussion
4.1 First part: General information……..…………………………..…...…...……....…57
4.1.1 Type of work executed by the respondents……..…….…..…..…..…...……....…57
4.1.2 Company classification ……..…………………….…………..…..…...…..…..…57
4.1.3 Respondents' occupation……..…………...……….…………..…..…...…..……..58
4.1.4 Experience years of the respondents...………………………..…..…...……....…58
4.1.5 Experience years of the company…..…….…….……………..…..…...…..……..59
4.1.6 Volume during the last 10 year…..…………..………………..…..…...……...…60
4.1.7 Number of labors…..………….…………..…………………..…..…...……....…60
VIII
4.2 Second part: Evaluation the current situation in Gaza Strip……….…....…...….…61
4.2.1 Company exposed to unnatural termination of project………..…...….......……61
4.2.2 Number of projects expose to unnatural termination……….……....…..….….…62
4.2.3 Records of information about previous project terminated…….….…..…....……62
4.2.4 Benefits from previous information……….……………………......……………63
4.2.5 Who is the responsible for unnatural project termination in the company.....……64
4.2.6 Solving the resulting dispute from project termination ……………..….……..…64
4.2.7 Satisfaction about the administrative level in the company.…..….…………..…65
4.2.8 Who has the final decision in the company ……………..….…..……………..…67
4.3 Third part: Contracts termination factors……………..….…..……...………..……67
4.3.1 Main groups……………..….…..……..…..………..………..….……..…………67
4.3.2 IIR and ranking of sub-factors……………..….………..……….……..…...……67
4.3.2.1 Managerial group……………..….…..……..…..…………..………..….......…67
4.3.2.2 Financial group……………..………..…..………..………..………..….......…69
4.3.2.3 Political group……………..….…..……..………..………...………..….......…71
4.3.2.4 Environmental group……………..….…..……..…………..………..…........…72
4.3.2.5 Project characteristics group……………..….…..……..………..….....…….…74
4.4 The highest ten factors causes contracts termination……………..………..…...…76
4.5 The relationship among the highest important factors, main groups and some items
………………………………………………………….……………………..…...…..77
4.6 The situation of contracts termination in Gaza Strip……………..….......…...……83
Chapter 5
Conclusion and Recommendations
5.1 Conclusion.……..………………..……………………………..…..…...…..…..…84
5.2 Recommendations……..……….…………...…………………..…..….....……..…85
5.3 Proposed further studies…….....………………………………..…..….....……..…87
References…….....………………………………………...……..…..….........…..…88
Annexes…….....…………………………………………………..…..….....……..…97
IX
List of Tables
Table 1.1 Percent change of value added for economic activities during 2010 compared
with 2009……………….……………………………………………………….....…… 2
Table 1.2 Construction Cost Index (CCI) by major groups in the West Bank, 2008-
2010……………….………..………………….…………..……….……………...…… 3
Table 1.3 Number of construction companies (2011) ……………….….….. ………… 5
Table 2.1 Summary of driven the factors affecting on termination…….…………..… 31
Table 2.2 Methods of disputes construction ………………....….……….…. ……..… 44
Table 3.1 Correlation coefficient alpha of termination construction contracts groups
……...…….…………………………………………………………………..…..…… 52
Table 3.2 Split-Half coefficient of termination construction contracts groups
……...…………….………..…………………..……………….……………...……… 53
Table 3.3 Cronbach's alpha and internal consistency ………………………..…..…… 54
Table 3.4 Cronbach's coefficient alpha of termination construction contracts groups
……...……………….…….…………………………..………….….…….…..……… 54
Table 3.5 Ordinal scales used for data measurement………………….……..…..…… 55
Table 3.6 IIR and ranking of main groups……………….…………………..……..… 55
Table 4.1 Volume of executed projects during the last 10 year………………..…...… 60
Table 4.2 Records of information about previous project terminated…..……...…...… 63
Table 4.3 IIR and ranking of main groups……………...…………………….......…… 67
Table 4.4 IIR and ranking of managerial sub-factors………………….……………… 68
Table 4.5 IIR and ranking of financial sub-factors……………….…………………… 70
Table 4.6 IIR and ranking of political sub-factors ……………….…………..…..…… 71
Table 4.7 IIR and ranking of environmental sub-factors……….…….………..……… 73
Table 4.8 IIR and ranking of project characteristics sub-factors……….…….……..… 75
Table 4.9 IIR, ranking and groups of highest ten factors causes contracts termination
…………..……………….…………………………………………………...…..…… 76
Table 4.10 The relationship between the main groups and the company experience
…………..……………….………………………………………………….....……… 77
Table 4.11 The relationship between the highest important factors and the company
experience ………………….……………………………………………….....……… 78
Table 4.12 The relationship between the main groups and the projects volume
…………..……………….………………………………………………….....……… 78
X
Table 4.13 The relationship between the highest important factors and the projects
volume ..…………...…….………………………………………………….....……… 79
Table 4.14 The relationship between the main groups and the number of contracts
termination ....……………….…………………...………………………….....……… 80
Table 4.15 The relationship between the highest important factors and the number of
contracts termination ..……………….………………………………………..……… 80
Table 4.16 The relationship between the main groups and satisfaction the administrative
level..……………….………………………………………………...…………..…… 81
Table 4.17 The relationship between the highest important factors and satisfaction the
administrative level . ..……………...………………………………………...…..…… 81
Table 4.18 The relationship between the main groups and who has the final decision
..……………….…………………………………………………...…………..……… 82
Table 4.19 The relationship between the highest important factors and who has the final
decision ..……………….…………..………………………………………….……… 82
XI
List of Figures
Figure 1.1: Contribution of Economic Activities in Gross Domestic Product, (Gaza
Strip, 2010) …..………….…………………………………………..……….....……… 2
Figure 2.1: Major stakeholders………..……………………………………...……..… 11
Figure 2.2: The good practice contract management framework ……….....….……… 14
Figure 2.3: Project termination decision tree…………………….………….....……… 21
Figure 2.4: Stakeholders relationship……………...…………….…………...……..….42
Figure 3.1: Research summary…....................…………………….….……...…..….…46
Figure 3.2: Research location……………………….…...…………….….…..…..……49
Figure 3.3: Questionnaire response rate……………….………….….…..…….....……51
Figure 4.1: Classification of the respondents…………...……………..….……………57
Figure 4.2: Respondents' occupation…………………...………....….…..….…...……58
Figure 4.3: Experience years of the respondents………………….…...………….……59
Figure 4.4: Experience years of the companies………………………...…..…….……59
Figure 4.5: Number of labors…………………………….…….….…..……….....……61
Figure 4.6: Company exposed to unnatural termination of project…..…….........……61
Figure 4.7: Number of project expose to unnatural termination…..………...........……62
Figure 4.8: Benefits from previous information…..………....................................……63
Figure 4.9: Responsible for the unnatural project termination in the company …….…64
Figure 4.10: Solving the resulting dispute from project termination …..…………...…65
Figure 4.11: Satisfaction about the administrative level in the company ..…..…..…... 65
Figure 4.12: Who has the final decision in the company …..………...………....…..…66
XII
List of Equations
3.1 Equation 1: Sample Size…..………..………...………………..………...........……48
3.2 Equation 2: Spearman's rank correlation coefficient ..……...…………...........……58
3.3 Equation 3: The Importance Index Rate…..………………...…………...........……55
List of Annexes
Annex 1: Questionnaire (ARABIC) …..………..………...…………….….........……97
Annex 2: Questionnaire (ENGLISH) …..………..……...……...…………….......…104
XIII
List of Abbreviations
B.o.Q Bill of Quantity
CCI Construction Cost Index
CSFs Critical Success Factors
D&B Design and Build
DRTs Dispute Resolution Techniques
EPM Engineering Project Management
GMP Guaranteed Maximum Price
GNP Gross National Production
GDP Gross Domestic Product
IIR The Importance Index Rate
IT Information Technology
PCR Project Closeout and Review
PCU Palestinian Contractors Union
SRO Senior Responsible Owner
SPSS Statistical Package for Social Science
UAE United Arab Emirate
XIV
Chapter 1
Introduction
This research identifies and investigates factors that influence the construction contracts
termination in the Gaza Strip. Understanding this mechanism may prevent their failure
in the future contracts.
In this chapter an introduction to the construction industry and the Palestinian economy
is highlighted. Also, the research problem, the research purpose, objectives, and
boundaries are to be explained.
1
Table 1.1 Percent change of value added for economic activities during 2010 compared
with 2009 – Value added in $ million
Palestinian
% change
Territory
Economic Activity
Value Value % West Gaza
added added change Bank Strip
Agriculture and Fishing 293.2 360.0 22.8 17.2 34.6
Mining, manufacturing, electr. and water 747.7 706.6 -5.5 -5.7 -3.8
Construction 387.7 525.6 35.6 13.9 23.2
Wholesale and retail trade 566.5 634.7 12.0 11.9 12.7
Transport, Storage and Communications 421.0 446.5 6.0 5.7 12.9
Financial intermediation 269.1 297.2 10.4 11.9 2.2
Services 1157.5 1196.0 3.3 2.9 4.1
Public administration and defense 750.6 798.8 6.4 8.5 3.2
GDP 5241.3 5728.0 9.3 7.6 15.1
Source: (PCBS, 2011)
The GDP in the Gaza Strip had increased by 15.1%. Among economic activities,
Construction recorded the highest increase by 23.2% during 2010. In addition, the
Transport, Storage and Communications Activity had recorded increase in the value
added. The Agriculture Activity in the Gaza Strip had witnessed improvement by 34.6%
compared to 2009 while Mining and manufacturing reflected fallback (Palestinian
central bureau of statistics, 2011).
6% 9%
7%
22%
9%
8%
2%
3%
34%
Agriculture and Fishing
Mining, manufacturing, electr. and water
Construction
Wholesale and retail trade
Transport, Storage and Communications
Financial intermediation
services
Public administration and defense
Others
2
The value added of the Construction Activity had increased by 35.6% in 2010 compared
to 2009. In addition, administrative records also showed a rise by 17.5% in the number
of building licenses issued in the West Bank for the year 2010. The prices of
construction materials rose by 1.6% compared to 2009 despite quantities of imported
cement reached 1.3 million ton in 2010 compared to 1.2 million ton in 2009. The year
2010 also witnessed a rise by 26.2% in the number of workers in construction activity to
reach 57 thousand workers in 2010. The average daily wage of a worker in the
Construction Activity is considered the highest among economic activities to reach NIS
117.4; while productivity rate reached USD$ 15,600.7 per worker (Palestinian central
bureau of statistics, 2011).
The Construction Cost Index had increased by 1.6% in 2010 compared to 2009.
Table 1.2 Construction Cost Index (CCI) by major groups in the West Bank, 2008-
2010.
Major Groups 2008 2009 2010
Raw materials 114.13 104.30 105.85
Hiring of equipment 119.61 131.11 137.28
Labor cost and wages 105.30 116.69 118.89
All- Items construction cost index 111.63 107.67 109.36
Source: (PCBS, 2011)
3
The construction contracting business has the second highest failure rate of any
business. (Clough and Sears as cited Enshassi et al., 2006 ). A contractor is at far more
risk than his counterpart in almost any other industry (Kangari, 1988).
Construction is difficult to comprehend fully because the relationships between the parts
are not always clear and the boundaries of the industry may be characterized as:
• It is fragmented,
• It is sensitive to economic cycles,
• There are extraordinary diversity of professions, specialists and suppliers,
• It is largely affected by external environments (Abu Mousa, 2005).
4
due to many reasons affecting the developing and the expansion of the construction
sector. One of them is construction contracts termination . Thus, this research is
important in order to determine the construction contracts termination factors affected
in the construction industry in Gaza Strip.
5
1.6 Research purpose
This study will provide contractors by practical suggestions to deal with the
construction contract termination and improve the performance of contracting
companies in this field. The value of this research is seen through increased project
success, better relationship between the construction team, the contractors and owner
agency, fewer claims, and reduced overall project costs.
6
construction contracts termination, the different strategies to deal with these
construction contracts termination. And techniques developed to deal with termination.
Second stage: Field survey
Several meetings and discussions were held with experts in the construction field.
Hence, a structured questionnaire was designed and then distributed by direct contact to
contractors in Gaza Strip.
Target group is the first three classes of contractors classification.
Statistical analysis for questionnaires is analyzed using Statistical Package for the
Social Sciences (SPSS) and Excel Sheets. In order to verify the validity and reliability
of the study hypotheses, variables associations were tested. The important factors were
identified. Investigate the current situation in Gaza Strip.
Third stage: Results and conclusion
The outputs of this research are a questionnaire analysis and discussion . Finally, the
conclusion and recommendation of the study were drawn up.
7
Chapter 2
Construction Contracts Termination
The definition, causes and symptoms, types of termination are to be explained in this
chapter. Also cure and prevention of contracts termination are to be illustrated.
BPI, (2007) define the construction contract as a contract which places responsibility on
the construction contractor to perform as per the design developed by design staff
and/or by an independent architectural, engineering firm under a separate contract.
Construction contract is a contract specifically negotiated for the construction of an
asset or a combination of assets that are closely interrelated or interdependent in terms
of their design, technology and function or their ultimate purpose or use (Haider, 2009).
Gilbreath, (1986) as cited in (Dilts et al., 2006) defined a project as a series of tasks or
activities needed to achieve a specific objective within certain technical specifications,
within defined start and end dates, and subject to funding limits and resource
availability.
Iyer et al., (2008) define the termination of contracts as ending the contract work with
no intention of resuming it in the foreseeable future.
Balachandra and Friar (1997) define the termination as the discontinuation of a project
before it achieves its complete implementation.
The termination of a contract results in its end and neither party is required to continue
performance under it. However, once the contract is terminated, the parties may still be
8
entitled to damages based on the termination. The nature and amount of these damages
depends, again, on the way termination is treated in the construction contract (Wittbrodt
et al., 2009).
2.1.2 Essential elements of a valid contract
There are a number of essential elements required for a valid contract to be formed
a. Agreement
Agreement between the parties regarding the purpose, rights, obligations, and remedial
measures which the contract will create is essential. A written agreement is not a necessary
requirement, but in practice it is desirable to put the agreement in writing since it will
provide substantial evidence for the terms of the contract.
b. Offer and acceptance
An offer is a proposal by one party of its willingness to be legally bounded by the proposal
as soon it is accepted by another party (Kawakye, 2008).
An acceptance is full acceptance by party to whom an offer has been made (Kawakye,
2008).
In forming a contract, there must be an offer consisting of a definite promise from one party
to the other of his willingness to be legally bounded on specific terms and an unconditional
acceptance of those terms by the second party. An offer may be withdrawn before it has
been accepted and will be valid for a “reasonable” time if no time limit is imposed (Seid,
2008).
c. Considerations
Consideration is what each party contributes to the contract, or in other words, it is what the
parties put into and get out of the contract. Consideration must have some economic value,
but the law is not concerned with the value being inadequate (Seid, 2008).
.
d. The intention to be legally bounded
Although a legal contract necessitates agreement between the parties as to the rights and
obligations it will create, a mere agreement by it self will not be enforceable at law unless
the parties there to fully intend to be legally bounded by its terms and conditions. Hence,
the parties are required to form a contract enforceable at law if it is intended that the
contract is to be legally binding (Seid, 2008).
9
e. Genuine consent of parties
It is essential that the agreements must be free from misrepresentation, mistake, duress, and
undue influence and made with proper and genuine consent by the parties to it (Kawakye,
2008).
f. Legal capacity
Certain parties are either not allowed to enter into a contract or are restricted in some way
which includes minors, drunks, lunatics, and convicts under sentence. Corporate bodies,
such as limited companies and public authorities, can only make contracts within powers
contained in their memorandums of associations and persons signing contracts on behalf of
their organization should not do so unless they are specifically authorized to commit the
organization(Seid, 2008).
10
2.1.4 Construction project stakeholders
Stakeholders are individuals, groups or organizations, institutions and others that are
actively involved in a project and whose interests may be positively or negatively affected
by the project execution (Seid, 2008).
Project stakeholders can be classified into two major groups: primary and secondary
stakeholders as shown in Figure 2.1. Primary stakeholders are those persons or groups of
the project team who have a contractual or legal obligation to the project team and have
responsibility and authority to manage and commit resources according to schedule, cost,
and technical performance objectives. These stakeholders can also be named as contractual
stakeholders. Secondary stakeholders are those who have no formal contractual relationship
to the project but can have strong interest in what is going on regarding the project. These
stakeholders can be participants on budgetary and financial agreements, business and
professional interests or relationships and they are also referred to as budgetary and
collateral stakeholders (Seid, 2008).
11
2.1.5 Type of contracts
As we define the contract before the contract is a legally enforceable agreement
between two or more parties with mutual obligations. And there are more types of it :
12
2.1.6 Factors influencing the choice of the type of contract
• The appropriateness for providing an adequate incentive for efficient
performance by the contractor;
• The ability to introduce changes;
• The allocation of risks;
• The start and completion date of the project.
1. There is a planned transition from the tendering/contract award phase to the contract
management phase, and a handover to contract manager; the cost of contract
management is included in the business case and budgets.
2. Contract ownership is clear, with the budget holder, senior responsible owner (SRO),
and contract manager clearly defined; there is continuity of governance as far as
possible.
3. There are well defined processes and a clear contract management plan, with a focus
on outputs and a ‘whole life’ approach to performance.
4. Overall ownership of contract management across the organization is clear, with a
‘contract management senior responsible owner’ with responsibility for driving
organization-wide contract management performance.
5. Contract management processes are aligned with, among others, wider
organizational governance processes, operational boards, and risk structures.
6. Contract management issues and performance are reported through the governance
structure with senior level engagement.
7. Regular assessment and evaluation takes place to ensure that the cost of contract
management activities is justified and proportionate to the benefits obtained.
8. Knowledge management is embedded, capturing key data and lessons from contract
management process and experience both within the organization and more widely.
9. Professional contract management guidance is developed, or identified from external
sources, and made available to contract managers (NAO, 2008).
13
Figure 2.2 : The good practice contract management framework (NAO, 2008).
14
2.2.1 Project success overview
Dvir (2005) defined project success as the completion of an activity within the
constraints of time, cost, and performance. This was the definition used for the past
twenty years or so. Today, the definition of project success has been modified to include
completion( Dvir, D., 2005):
• Within the allocated time period;
• Within the budgeted cost;
• At the proper performance or specification level;
• With acceptance by the customer/user;
• With minimum or mutually agreed upon scope changes;
• Without disturbing the main work flow of the organization;
• Without changing the corporate culture.
15
2.2.3 Warning signs that a construction projects is in trouble
The Surety Information Office, which is an office that collects data on surety bonds in
the United States, has identified six broad warning signs that a construction company is
in trouble. They are as follows (Halim et al., 2010):
1. ineffective financial management system;
2. bank line of credit constantly borrowed to the limit;
3. poor estimating and/or job cost reporting;
4. poor project management;
5. absence of a comprehensive business plan;
6. communication problems.
16
2.3 Termination of construction contracts
The termination of a contract results in its end and neither party is required to
continue performance under it. However, once the contract is terminated, the parties
may still be entitled to damages based on the termination. The nature and amount of
these damages depends, again, on the way termination is treated in the construction
contract (Wittbrodt et al., 2009).
It is vitally important that contractors and owners understand when and how a
termination can legally occur and how to handle such termination threats ( Brumback,
M., 2006).
Additionally, a contractor can terminate the contract for cause if it experiences repeated
suspensions, delays or interruptions of the work in the following delay situations:
17
• more than 100% of the total number of days scheduled for completion, or 120 days in
any 365 day period, whichever is less; or
• if work is stopped for 60 consecutive delays through the fault of the owner.
2. Owner’s termination for default
Pursuant to A20 I para 14.2.1, the owner can terminate for cause as well, if the
contractor materially breaches the contract in one or the following ways:
• persistently fails to supply enough properly skilled workers or proper materials;
• fails to make payment to Subcontractors for materials or labor in accordance with the
respective agreements;
• persistently disregards laws, ordinances, or rules, regulations or orders of a public
authority having jurisdiction; or
• otherwise is guilty of substantial breach of a provision of the contract documents.
Termination for cause must be for breaches which are “so material as in effect to defeat
the very terms of the contract.
19
Termination by starvation: means
There is a forth type of project termination, although it is not a termination at all. It is
slow starvation by budget decrement.
20
Figure 2.3 : Project termination decision tree (EPM, 2011).
21
• when a prolonged suspension or force majeure type event occurs.
Figure 2.3 shows project termination decision tree
23
can be either the cost of repair/completion the difference in value from what was
contracted. In general, cost of repair is the proper measure of damages in a construction
case where the owner would not get what he bargained for unless he gets the repair,
replacement or completion. If the unpaid contract balance exceeds the costs of finishing
the work, the contractor should be reimbursed the difference. If the work to finish is
greater than the balance remaining, the contractor shall pay the difference to the owner.
(A201, para 14.2.4).
An exception to the cost of repair method of calculating damage exists, however, where
a substantial portion of the completed work would be destroyed to undertake the repair.
In that case, diminution in value may be used as the measure of damages instead,
provided the structure substantially conforms to the contract specifications. If, however,
the defects or omissions are major, such that the building does not substantially
conform, then the decreased value of the constructed building justifies the high cost of
repairs.
24
suggest that the project manager "must accept ultimate responsibility, regardless of the
factors involved". A fair-minded stance on these different viewpoints would evoke that
the purpose of the project review is not to find a scapegoat but to learn from the
mistakes.
25
3. Improving construction management qualities
Qualities are important for a project, an enterprise, or a manager. A manager should
emphasize enterprise’s qualities, and a staff should pay attention on his qualities.
Qualities of an enterprise, a staff and a manager are different. Therefore, it must be
emphasized that everyone should study in all life. Development of a construction
enterprise lies on development of employee’s abilities. Best method to improve qualities
of employee is to promote employee training and make him a talented person.
4. Independent professional inspecting and supervising
Business and management of a construction enterprise needs independent professionals
to supervise. For instance, cost engineers can evaluate exactly and budget prudently;
chief inspectors can supervise efficiently; registered structure engineer can calculate
accurately and save money; an independent construction professional can furnish full
time inspection and strong supervision should be provided to avoid ‘short cuts’ by
workers. Sometimes, improper construction designing will lead to waste. For instance,
if structural design is as secure as possible, it will construct a blockhouse instead of a
building. A construction enterprise should make use of certified professionals and
intermediary agencies. In business and management of construction, intermediary
agencies can be employed in many fields.
5. Adopting synthetic prevention measures for failure
Generally, without obtaining the goals, an enterprise fails. Failures will result in losses
of tangible assets and invisible assets. The first can be calculated by economic figures,
including losses of finance and material resources. Whereas, the latter cannot be
calculated by money, such as brand depreciating, enterprise culture is slack and strategy
is confusing (Wang, 2002). Failures will bring losses of social fortune and resource. It
means that social fortunes are collocated wrongly, and great deals of social wealth are
destroyed. It even will result in a mass of unemployment, accidents, disasters, crimes,
and so on.
In one word, losses brought by failure are various. It is necessary to analyze failures
from various fields and various angles, and adopt synthetic prevention countermeasures
to control failure accordingly.
26
2.4 Previous studies for construction contracts termination
The purpose of the contract is to establish the rights, duties, obligation, and
responsibilities of the parties and to allocate the risk . The acceptance of an obligation
or duty brings with it acceptance of commensurate risk, which is the risk of being
unable to fulfill the obligation or duty because of one 's own inadequate, incapacity,
inadvertence, or error, or because of interference from outside sources or events. But
with any contractual agreement the contract defines only the ground rules, the execution
of contract rests on good well, intent and relationship between the parties. ( Flanagan &
Norman, 1993).
Al-Hallaq (2003), in his thesis study illustrated that the cause of contractors failure are:
delay in collecting bids from clients (donors), closure, depending on banks and paying
high profits, lack of capital, cash flow management, lack of experience in the field of
work in Gaza Strip, absence of construction regulations, low margins of profit due to
competition, award contract to lowest price, and lack of experience in contracts.
Enshassi et al. (2006) in their paper explore the causes of contractor's business failure
in Palestine, and investigate their severity from the contractor's point of view. The
study's results shows that the main causes of business failure are delay in collecting debt
from clients (donors), border closure, heavy dependence on bank loans and payment of
high interest on these loans, lack of capital, absence of industry regulations, low profit
margin due to high competition, awarding contracts by client to the lowest bidder, and
lack of experience in contract management.
Anderson (2010) in her Assay titled " The top three causes of project failure " . She
shows that the common three causes are :
1- Lack of clearly designated project leader;
2- Lack of clear expectations and goals;
3- Communications challenges.
27
Belassi et al. (1996) in their paper grouped the success or failure factors into four areas
• Factors related to the project;
• Factors related to the project manager and the team members;
• Factors related to the organization;
• Factors related to the external environment.
The paper demonstrates the differences between the critical success factors and the
factors identified with the use of our scheme. Many critical factors, such as factors
related to projects manager s' performance, factors related to team members and
environmental factors, became apparent with this study. The results are encouraging, in
that practitioners support the use of this scheme for determining and analyzing critical
success factors and how systems respond to these factors and illustrate that project
manager s' managerial skills are the most critical factors while environmental factors
take the lead in construction.
Hamdia (2008), in his thesis study (Investigate of critical success factors for
construction sector in Gaza Strip) shows that the most notable findings of this
research were, about 71% of contracting companies in Gaza Strip have a clear
description of goals and mission, financial resources is the first Critical Success Factors
(CSF), the second CSF is owner satisfaction. In addition, Pricing polices CSF was the
third. Also the forth CSF was related to Managerial Skills for contractors. Furthermore,
cost control CSF was the fifth. Finally, Mission and Goal has the sixth one. He
recommended the necessity for contractors in Gaza Strip to be more interested in
strategic planning, to formulate and apply adequate CSFs; and contractors in Gaza Strip
must apply modern managerial approaches and scientific tools; as well as top manager
in contracting company in Gaza Strip shouldn’t concentrate efforts on financial issues,
but they are required to be interested in other topics as, human resource development,
owner satisfaction, and cost reduction.
Albert et al. (2001) in their study that aimed to identify a set of project success factors
for Design and Build (D&B) projects and examine the relative importance of these
factors on project outcome. Six project success factors (project team commitment,
contractor's
28
competences, risk and liability assessment, client's competences, end-user's needs and
constraints imposed by end users) were extracted from factor analysis of data provided
by 53 participants of public sector D&B projects through a questionnaire survey. Project
team commitment, client's competences and contractor's competences were found to be
important to bring successful project outcome from the multiple regression findings.
Contractor’s competences also contributed to project time performance. Project team
members should also recognize that time and cost performance as well as quality of
design and workmanship represents the key elements of overall success of D&B
projects. Practitioners are advised to focus on teamwork and partnering for successful
project completion.
Abu Mousa (2005), in his thesis study about gain understanding of 44 risk factors that
could face the building projects in Gaza Strip and also to investigate the effectiveness of
risk preventive and mitigate methods. The study illustrated that " The most important
risk factors are: financial failure of the contractor, working at hot (dangerous) areas,
closure, defective design and delayed payments on contract. On the other hand, owner
respondents concluded that the most important risk factors are: awarding the design to
unqualified designer, defective design, occurrence of accidents, difficulty to access the
site, and inaccurate quantities".
Kartam and Kartam (2001) in their paper present an attitude of typically large
Kuwaiti contractor towards construction risk. The paper is concerned with the
assessment and allocation risk as will as contribution of each risk type to project delay.
The paper also investigate the best contractual arrangements and the most effectives
approaches towards preventing or minimizing construction risk. The study illustrated
that " Financial failure has been consider to be the most significant risk category and a
contractors cloud suffer from in Kuwait".
El Karriri et al. (2011) in their paper show that the political factors and clients' related
factors like (Israel invasion, Imposed closure at Gaza Strip, clients bankruptcy, clients'
bad financial situation, and location of some projects at hot regions) were shown as a
part of the critical drivers for contract termination in construction projects.
29
Dvir (2005) in his paper examines the relationship between planning and preparing the
project termination and commission and project success. The paper suggests that
customer participation in the development process and final user preparations have the
highest impact on project success. Customer participation in the development process is
highly correlated with project efficiency (0.45), while final user preparations are highly
correlated with customer benefits (0.46).
De (2001) in his paper analyzes the key problems faced by project management
professionals in terminating projects in Indian Industry. The paper shows that
negotiating claims with clients, compliance of statutory requirements, receipt of the
final installment of payment, performance guarantee tests, and handling claims of
suppliers are the key problems faced by the project managers in India in terminating
projects.
Dilts et al. (2006) in their paper investigate the impact of job position or role, when
making the decision to cancel a project and the impact of different information
gathering activities, such as information scanning richness of media used, and diversity
of information sources by examining the perspectives of decision makers who have
cancelled or terminated a public sector project. Two decision-making roles are studied:
executives, those with the authority to start or cancel a project, and project managers,
those who direct the day-to-day operations of the project. The paper illustrate that in
project success or failure cannot ignore the impact of role.
30
Table 2.1 Summary of driven the factors affecting on termination
El Karriri et al.
Enshassi et al
Kartam et al.
Abu Mousa,
Belassi et al.
Albert et al.
Anderson,
Al-Hallaq,
Dilts et al.
Hamdia,
(2010)
(2005)
(2001)
(2008)
(2001)
(2001)
(2006)
(2006)
(1996)
(2005)
(2001)
(2003)
Dvir,
De,
Group No.
Managerial 1
P Lack of experience in the line of work 1.1
P Company organization 1.2
P Frauds 1.3
P Neglect 1.4
P Inaccurate quantities 1.5
P Unmanaged cash flow 1.6
P Resource management 1.7
P Poor communication between involved parties 1.8
P Ability to put plans to work 1.9
P Ability to use computer in management 1.10
P Ability to work as a team 1.11
P Unclear goals 1.12
Financial 2
31
P Low margin of profit due to competition 2.1
P Lack of capital 2.2
Difference of local currency exchange with
P contract currency
2.3
Political 3
P Lack of clear expectations 3.1
Internal political troubles; as: rebellion, civil 3.2
P war, or disorder.
32
P Banks policy 3.5
P Closure 3.6
P Lack of resources 3.7
P Difficulty to get permits 3.8
P Change in funding source 3.9
P Inflation in world 3.10
Environmental 4
P Adverse climate conditions 4.1
P Social environment 4.2
P Accounting and tax practices 4.3
P Working at hot (dangerous) areas 4.4
P National slump in economy 4.5
P Change in resources (people, materials, funds) 4.6
P No specialized arbitrators to help settle fast 4.7
P Acts of God (Natural disaster ) 4.8
P Fare of project position to company 4.9
Project Characteristic 5
P Change in the type of work 5.1
P Size & value 5.2
P Life cycle period 5.3
33
P Increase size of projects 5.4
Wrong estimation for the total time of the 5.5
P project.
34
2.5 Common causes of project termination (Failure)
The UK Office of Government Commerce, (2005) cited the common causes of
termination of project as follow:
1. Lack of clear links between the project and the organization's key strategic priorities,
including agreed measures of success.
• Do we know how the priority of this project compares and aligns with our other
delivery and operational activities?
• Have we defined the critical success factors (CSFs) for the project?
• Have the CSFs been agreed with suppliers and key stakeholders?
• Do we have a clear project plan that covers the full period of the planned
delivery and all business change required, and indicates the means of benefits
realization?
2. Lack of clear senior management and Ministerial ownership and
leadership.
• Does the project management team have a clear view of the interdependencies
between projects, the benefits, and the criteria against which success will be
judged?
• If the project traverses organizational boundaries, are there clear governance
arrangements to ensure sustainable alignment with the business objectives of all
organizations involved?
• Are all proposed commitments and announcements first checked for delivery
implications?
• Are decisions taken early, decisively, and adhered to, in order to facilitate
successful delivery?
3. Lack of effective engagement with stakeholders.
• Have we identified the right stakeholders?
• Have we as intelligent customers, identified the rationale for doing so (e.g. the
why, the what, the who, the where, the when and the how)?
• Have we secured a common understanding and agreement of stakeholder
requirements?
• Does the business case take account of the views of all stakeholders including
users?
35
• Do we understand how we will manage stakeholders (e.g. ensure buy-in,
overcome resistance to change, allocate risk to the party best able to manage it)?
4. Lack of skills and proven approach to project management and risk management.
• Is there a skilled and experienced project team with clearly defined roles and
responsibilities? If not, is there access to expertise, which can benefit those
fulfilling the requisite roles?
• Are the major risks identified, weighted and treated by the SRO, the Director,
and Project Manager and/or project team?
• Has sufficient resourcing, financial and otherwise, been allocated to the project,
including an allowance for risk?
Al-Hallaq (2003) illustrated in his study the causes of contractor's failure in Gaza Strip
are:
• Delay in collecting dibs from donors
• Closure
• Depending on banks and paying high
• Lack of capital
• Lack of experience in the line of work
• Cash flow management
• Segmentation of Gaza Strip
• Low margin of profit due to competition
• Lack of experience in contracts
• Award contracts to lowest price
Anderson (2010) in her Assay titled shows that the common three causes of project
failure are :
1- Lack of clearly designated project leader;
2- Lack of clear expectations and goals;
3- Communications challenges.
36
And the UK Office of Government Commerce, (2005) cited the common causes of
termination of project also as follow:
3. Lack of understanding of, and contact with the supply industry at senior levels in the
organization.
• Have we tested that the supply industry understands our approach and agrees
that it is achievable?
• Have we asked suppliers to state any assumptions they are making against their
proposals?
• Have we checked that the project will attract sufficient competitive interest?
• Are senior management sufficiently engaged with the industry to be able to
assess supply-side risks?
37
• Do we have a clear strategy for engaging with the industry or are we making
sourcing decisions on a piecemeal basis?
• Are the processes in place to ensure that all parties have a clear understanding
4. Lack of effective project team integration between clients, the supplier team and the
supply chain.
• Has a market evaluation been undertaken to test market responsiveness to the
requirements being sought?
• Are the procurement routes that allow integration of the project team being
used?
• Is there early supplier involvement to help determine and validate what outputs
and outcomes are sought for the project?
• Has a shared risk register been established?
38
extraordinary effort since all the aspects of the project are written down. Documentation
is the key for well-organized change of the project owner, i.e. for a new investor that
takes over the project after it is finished. (Thompson, 2005) makes a distinction between
the documentation requirements of the internal and the external clients since the
external party usually needs the documents for audit purposes only. Despite the
uninteresting nature of documenting historical data, the person responsible for this task
must engage actively with his assignment.
2.6.3 Project systems closure
All project systems must close down at the closeout phase. This includes the financial
systems, i.e. all payments must be completed to external suppliers or providers and all
work orders must terminate (Department of Veterans Affairs, 2004). "In closing project
files, the project manager should bring records up to date and make sure all original
documents are in the project files and at one location" (Arora, 1995). (Maylor, 2005)
suggest that "a formal notice of closure should be issued to inform other staff and
support systems that there are no further activities to be carried out or charges to be
made". As a result, unnecessary charges can be avoided by unauthorized expenditure
and clients will understand that they can not receive additional services at no cost.
2.6.4 Project reviews
The project review comes usually comes after all the project systems are closed. It is a
bridge that connects two projects that come one after another. Project reviews transfer
not only tangible knowledge such as numerical data of cost and time but also the tacit
knowledge which is hard to document. ‘Know-how’ and more important ‘know-why’
are passed on to future projects in order to eliminate the need for project managers to
‘invent the wheel’ from scratch every time they start a new project. The reuse of
existing tools and experience can be expanded to different project teams of the same
organization in order to enhance project results (Bucero, 2005). Reviews have a holistic
nature which investigate the impact of the project on the environment as a whole.
Audits can also be helpful but they are focused on the internal of the organization.
Planning the reviews should include the appropriate time and place for the workshops
and most important the people that will be invited. Choosing the right people for the
review will enhance the value of the meeting and help the learning process while having
an objective critique not only by the team members but also from a neutral external
auditor. The outcome of this review should be a final report which will be presented to
the senior management and the project sponsor. (Whitten, 2003) also notices that "often
39
just preparing a review presentation forces a project team to think through and solve
many of the problems publicly exposing the state of their work".
3.6.5 Disband the project team
Before reallocating the staff amongst other resources, closeout phase provides an
excellent opportunity to assess the effort, the commitment and the results of each team
member individually. Extra-ordinary performance should be complemented in public
and symbolic rewards could be granted for innovation and creativity (Gannon, 1994).
This process can be vital for team satisfaction and can improve commitment for future
projects (Reed, 2001). Reviewing a project can be in the form of a reflective process,
where project managers "record and critically reflect upon their own work with the aim
of improving their management skills and performance" (Loo, 2002). It can also be
applied in problematic project teams in order to identify the roots of possible conflicts
and bring them into an open discussion.
Ignoring the established point of view of disbanding the project team as soon as
possible to avoid unnecessary overheads, (Meredith and Mandel, 2003) imply that it’s
best to wait as much as you can for two main reasons. First it helps to minimize the
frustration that might generate a team member’s reassignment with unfavourable
prospects. Second it keeps the interest and the professionalism of the team members
high as it is common ground that during the closing stages, some slacking is likely to
appear.
2.6.6 Stakeholder satisfaction
PMBoK (2004 ) defines that "actions and activities are necessary to confirm that the
project has met all the sponsor, customer and other stakeholders’ requirements". Such
actions can be a final presentation of the project review which includes all the important
information that should be published to the stakeholders. This information can include a
timeline showing the progress of the project from the beginning until the end, the
milestones that were met or missed, the problems encountered and a brief financial
presentation. A well prepared presentation which is focused on the strong aspects of the
projects can cover some flaws from the stakeholders and make a failure look like an
unexpected success.
40
2.7 Impacts of project parties (Stakeholders) on project termination
Nowadays, project management has become a key activity in most modern
organizations. Projects usually have a wide variety of objectives, involve numerous
internal and external actors, and are conducted in various activity sectors. Since 1980,
many academics and practitioners have agreed that human resource management
(HRM) is one of the most crucial elements of an organization's success (Belout et al.,
2004).
The project management identifies two requirements for an effective client–contractor
relationship. Firstly, contractor organizations must be customer-focused, in terms of
understanding and fulfilling the expectations of the client. This customer-focus
has been stated as a precursor to success . Secondly, client organizations must be
focused on understanding and accommodating the expectations of all stakeholders in the
supply chain, such as contractors, sub-contractors, suppliers and other team members,
with ‘‘project stakeholders’’ defined as ‘‘people or organizations who have a vested
interest in the environment, performance and/or outcome of the project . This focus on
other stakeholders will create ‘‘win-win’’ situations through trust, openness, teamwork
and shared goals (Bryde et al., 2005).
Stakeholders are individuals, groups or organizations, institutions and others that are
actively involved in a project and whose interests may be positively or negatively
affected by the project execution. They may also exert influence over the project and its
results. In short, they are claimants who claim ownership, who have rights or interests in
a project and its activities. Hence, every project is influenced and must be managed
from a perspective that goes beyond the basic relationship between customers and
companies that perform the project (Seid, 2008).
The pre-qualification of construction contractors is a very important step in project
procurement. Pre-qualification is the process of screening contractors. The selection of a
qualified contractor gives confidence to the client that the selected contractor can
achieve the project goals (El-Sawalhi, 2007).
The responsibility of project integration requires the project manager to perform three
key tasks. Firstly, the project manager has to implement an effective planning and
control system for all the project activities. Secondly, all communication links within
and outside the project need to be established and maintained. Finally, effective project
integration requires the project manager to act quickly to resolve internal and external
41
conflicts before they start to threaten project budget, scheduling and performance
specification (Ogunlana et al., 2002).
The employer plays the most important role within the construction process and
therefore, he is the most important party to the contract for without him there would be
no contract and no work for consultants and contractors (Seid, 2008). Figure 2.4 shows
the relationships between employer, contractor and engineer.
Owners of projects under construction have three common goals: completion of the
project at the lowest reasonable price, within a stated time, and to a specified quality
(Abubshait, 1994).
Owners’ competencies that affect project success include their capability in managing
projects, their understanding of project scope and being able to clearly articulate end-
users’ needs. Owners who have competencies such as being knowledgeable,
enlightened and having initiative would facilitate project-based integrated teams,
leading to higher project performance (Yng Ling et al., 2008).
One of the most reasons that can affect the completion of projects is disputes. It is
normal to have disputes in construction projects due to the related contract nature. The
procurement, execution and completion of construction and engineering contracts differ
from other contracts in many respects (Abu Rass, 2006).
43
Table 2.2 Methods of disputes construction
Attributes of selected dispute resolution techniques (DRTs)
Dispute
resolution Definition of DRT Some attributes of DRTs
technique (DRT)
Strengths Weaknesses
Promotes Some parties may lack
Processes whereby two or
cooperation. negotiation skills.
more parties attempt to settle
Power balance is not
Negotiation what each shall give and take, Cost efficient.
assured.
or perform and receive in a
Promotes open
transaction between them.
process.
An impartial third party Encourages Process can be
attempts to keep com- Participation. expensive.
munication lines open, point High degree of
Participants may
out areas of agreement, Participant
Mediation lack skills.
encourage and assist control.
disputants to resolve their Helps create
A balance of power
differences using compromise alternative
not assured.
and negotiation. options
Results in
Win-lose outcomes
A process similar to litigation conclusive
possible.
but the decision of the decisions.
impartial third party may or Supported by
Arbitration
may not be binding depending established law Adversarial.
on the prior wishes of the and legislation.
disputants. Can be lengthy
process.
Conclusive
Involves courts and a neutral Costly.
Decisions.
Litigation third party that decides the
Supported by Win-lose outcomes
outcome based on law.
law. common.
Sources: (David et al., 2003)
44
Chapter 3
Methodology
3.1 Introduction
This chapter details the methodology and procedures which are used in the field of
study. This chapter deals with the research method, research population and sample,
sample characteristics, pilot study, research tools, Internal Consistent Validity,
Questionnaire Reliability, as well as list of statistical procedure used in the study.
To collect data a questionnaire was designed as a mean of research through pilot study,
validity, and reliability.
The sample of study was collected, analyzed and discussed to get the results, conclusion
and recommendations.
All elements of the research in this chapter such as sample size, sample location,
validity and reliability ….etc. were explained and discussed in details.
45
Topic Selection
Identify the
Problem
Develop Research Research Plan
Research Proposal
Plan
Define the
Problem
Literature Review
Establish
Objectives
Questionnaire Design
Pilot Study
Final Questionnaire
Questionnaire
Validity
Choosing the search sample
and size
Questionnaire
Reliability
Conducting Survey
46
3.3 Research method:
This research used descriptive analytical method. Also primary and secondary data were
used.
3.3.1 Primary data
To analyze the qualitative and quantitative characteristics of the contracts termination, it
has been depends on collecting the primary data by questionnaire ( see annexes 1,2) as a
main tool for the study, it saves time and effort. The questionnaire was designed
especially for this study and contains three parts:
1- Organization Profile and personal characteristics of the responses.
2- Evaluation of the current situation in Gaza Strip for project termination .
3- Project termination factors ( Managerial factors, Financial factors, Political factors,
Environmental factors, Project characteristic factors ).
47
Statistical equations were used in order to calculate the sample size for the contractors.
Equation 3.1 was used to determine the sample size of the unlimited population.
(Creative Research Systems, 2001):
Z 2 × P × (1 − P )
SS =
C2 Equation 3.1
Where SS = Sample Size.
Z = Z Value (e.g. 1.96 for 95% confidence interval).
P = Percentage picking a choice, expressed as decimal, (0.50 used for sample size
needed).
C = Maximum error of estimation (9%)
SS
SSNew =
SS − 1
1+
POP
Where pop is the population = 190 match the proposed classes contracting
companies according to the PCU records (The first three classes).
118
SS New = = 73
118 − 1
1+
190
The total number distributed to contractors was 90 questionnaires.
48
30
27
23
25
0
Rafah Khan-Yunis Middle Area Gaza and
North
49
" The answer can be more accurate. The response rate relatively high (approximately
60-70%), especially if interviewees are contacted directly.
50
Unreturned
questionnaire
17%
Returned
questionnaire
83%
Spearman 's rank correlation coefficient, like all other correlation coefficients, will take
a value between -1 and +1. A positive correlation is one in Which the ranks of both
51
variables increase together. A negative correlation is one In which the ranks of one
variable increase as the ranks of the other variable decrease. A correlation of +1 or -1
will arise if the relationship between the two variables is exactly linear. A correlation
close to zero means there is no linear relationship between the ranks (Altman, 1991).
n
1 − 6 ∑ d i
2
rs = i=1
(Gauthier, 2001) Equation 3.2
n 3
− n
where:
rs = Spearman's rank correlation coefficient
As shown in Table 3. 1 for the questionnaire groups, the p-values are less than 0.05 or
0.01, so the correlation coefficients of all the groups are significant at α = 0.01 or α =
0.05. It can be said that the groups are consistent and valid to measure. This supports
achieving the main aim of the study.
52
3.11 Reliability of the research
3.11.1 Split-Half coefficient method
This method depends on finding Pearson correlation coefficient between the means of odd
questions and even questions of each field of the questionnaire. Then, correcting the
Pearson correlation coefficients can be done by using Spearman Braun correlation
coefficient of correction. The corrected correlation coefficient (consistency coefficient)
2r
is computed according to the following equation: Consistency coefficient =
r +1
(Murairwa et al., 2010)
Where
r is the Pearson correlation coefficient.
2r
The normal range of corrected correlation coefficient r + 1 is between 0.0 and + 1.0 .
The normal range of corrected correlation coefficient (2r/r+1) is between 0.0 and +1.0.
As shown in Table 3.2, all the corrected correlation coefficients values are between 0.0
and +1.0. It can be said that according to the Half Split method, the termination
construction contracts groups are reliable.
53
The normal range of Cronbach’s coefficient alpha value between 0.0 and + 1.0, and the
higher values reflect a higher degree of internal consistency(George and Mallery, 2003).
If the average inter-item correlation is low, alpha will be low. As the average inter-item
correlation increases, Cronbach's alpha increases as well (UCLA, 2011).
As shown in Table 3.4, the Cronbach's coefficient alpha was calculated for the five
groups of termination contracts and the results were in the range from 0.626 and 0.834.
This range is considered high and closed to the full value, which is +1.0. These results
ensure the reliability of the questionnaire.
54
Table 3.5 Ordinal scales used for data measurement
Item High Important Important Medium Low Very Low
Scale 5 4 3 2 1
The Table shows groups have high value of IIR located between (81.29 %) and
(73.03 %) as listed in the Table (3.6) it is denoted to the important and vital of these
groups and it affected to contract termination.
55
3.14 Data analysis
The questionnaire quantitative statistical analysis was done by using Statistical
Package for Social Sciences (SPSS) and Excel sheet. The analysis of data was done to
rank the severity of termination construction contracts in Gaza Strip. Ranking was
followed by comparison of IIR values within groups and for the overall contracts
termination.
The following statistical tests were done:
1. Frequencies and percentages.
2. Correlation coefficients to measure the validity of the questionnaire.
3. Half split method and Cronbach's coefficient alpha for questionnaire
reliability.
4. The importance Index Rate (IIR).
56
Chapter 4
4. Results and discussion
This chapter aims to analyze and discuss the empirical data which are collected through
the questionnaire distribution.
The chapter is divided into three sections:
4.1 : General information;
4.2 : Evaluation of the current situation in Gaza Strip;
4.3: Project termination factors.
Classification of Company
Third class
9.58%
Second class
42.46% First class
47.95%
57
This distribution indicates that little companies establish in construction field in the last
period because of the events occurred in Gaza Strip in the last decade like intifada,
closure and internal dispute. Otherwise, The classification system requirements which
lead to first class or second class is so easy.
35
35
16 30
It is clear that site engineers have got the highest percentage 47.94%. This gives an
indication that the site engineers know all the elements of the project e.g. ( materials,
labors, market,…etc) because they usually work in the site. So they get a good
confidence to answers all questions. It is becoming common in Gaza Strip to have
a project manager in companies.
58
years and 34(46.57%) of them have an experience more than 10 years. And shows
experience years of the respondents.
From 1 to 3
years 16.43%
More than 3
to 5 years
Over 10 years 8.21%
46.57%
More than 5
to 10 years
28.76%
This distribution illustrates that respondents with an experience more than 10 years have
the highest percentage (46.57%) and it indicates the contractors bring in engineers who
work with the contractor in previous project and who has more experience.
From 1 to 3
More than 3
years 12.32%
to 5 years
6.84%
Over 10 years
53.42%
More than 5
to 10 years
27.39%
This Table illustrates that companies volume during the last 10 years with value less
than $1 million has the highest percentage (42.86 %). It also indicates that most of the
companies are of small size and most of the executed projects are small size. This is
mainly because of the unfavorable political and economical situation in Gaza Strip last
10 years.
60
26 30
24
25
4.2 Second part: The evaluation of the current situation in Gaza Strip
63
70
60
Respondents s' No.
50
40
10 30
20
10
0
No Yes
61
This illustrates that most of the companies in Gaza Strip have suffered from projects
termination. And may be traced to the political issues in year 2007.
From 5 to 10
More than 10
1.59%
From 3 t o 5 0.00%
23.81%
From 1 t o 3
74.60%
This distribution clarify that little number of projects exposed to unnatural termination
or little projects were executed by companies in this period because the events occurred
in Gaza Strip like intifada, closure, internal dispute and others.
62
Table 4.2 Records of information for previous project terminated
Yes,
Volume Yes, always No
sometimes
Frequencies 33 23 7
Percentage 52.00% 37.00% 11.00%
This is denoted that the contractors records and keep the information, reasons, data and
reports which leads to termination to benefit from its in the future so we find little
projects will expose to termination as mentioned before.
Yes,
sometimes No 0.00%
22.22%
Yes, always
77.78%
This is denotes that the contractors get benefit from their previous information in the
future to avoid projects termination.
63
4.2.5 Who is responsible for the unnatural project termination in company
As shown in Figure 4.9, 6(9.5%) are contractors, 15(23.8%) are owner, 39(61.9%)are
donors and 3(4.7%) are project manager.
54
60
50
30
13
20
5
1 10
0
Others Site engineer Project Director
manager
This distribution shows that the donors have the highest value 61.90%. Most of the
projects in Gaza Strip funded by external donors who support according to political
agenda or for human aids. Projects need to be funded internally.
64
Arbitration Litigation
7.94% 1.59%
Mediation
15.87%
Negotiation
74.60%
This show that the contractors and owners understood the situations and events
surrounding them which cause projects termination and solve resulting dispute in
friendly way .
Not satisfy
Neutral 8.22% 0.00%
Very satisfy
38.36%
Satisfy 53.42%
65
Management is very important for any thing e.g. money, works, time, material and etc..
This distribution illustrates that most of the employee are satisfied or very satisfied
about the administrative level about their company. This shows that most of the
companies in Gaza Strip are small and they need easy and simple managerial science.
54 60
50
30
13 20
5
1 10
0
Others Site engineer Project Director
manager
This is show that the person who has the final decision is the director because he owns
the company. He who has the money has the decision. In Gaza Strip companies most of
managerial issues goes back to project manager and financial issue goes back to
director.
66
4.3 Third part: Contracts termination factors
4.3.1 Main groups
Table 4.3 IIR and ranking of main groups
Factor IIR Rank
1. Political Factors 81.29 % 1
2. Managerial Factors 79.40% 2
3. Financial Factors 78.08% 3
4. Project Characteristic Factors 74.03 % 4
5. Environmental Factors 73.08 % 5
As mentioned before, the main groups of factors affecting the project termination were
managerial group, financial group, political group, environmental group, and project
characteristic factors. As illustrated in Table (4.3), the IIR and ranking of each group is
listed above. The most severe group of factors that causes project termination was
political group of IIR 81.82 %. It is not strange, because all of sectors in Gaza Strip are
affected from this group (Closure, internal dispute, shortage and expensive materials,
Funds and ….etc.) The last important group of factors that causes project termination
was environmental factors with IIR 73.08 %. Because Gaza is a small area comparison
with other areas in the world, and has nice weather. It also has a stable tax and
accounting system, and experienced labors.
The Table (4.3 ) shows that groups have high value of IIR located between 81.29 % and
73.08 % as listed in the Table (4.3) related to the important and vital of these groups
and it affects the projects termination.
67
There are 12 sub-factors under the managerial group and results show the highest value
is "Lack of experience in the line of work " and the lowest value is "Ability to use
computer in management".
Table (4.4) shows that the respondents group ranked “Lack of experience in the line of
work." in the first position with importance index (I.I = 88 %). No wonder that the
experience of work is one of the effective factors to the success and failure of projects
because lake of experience of work may lead to cost overrun which resulting to coping
with labors, materials, equipment and method statement of work in suitable manners so
more instruction in site more time and more cost, then cost overrun and project
termination.
The experience of work is important especially for directors, site engineer, estimator,
labors, supervision engineer about contracts, plans, specifications, site ,regulations,
materials and markets because they are the main elements to make work continue in the
site. So it is not strange to take the highest value in its group. This findings are
supported by Kartam (2001) and Al-Hallaq, (2003).
As shown in Table (4.4) the respondents ranked “Inaccurate quantities." in the second
position with importance index (I.I = 84 %). The accurate quantities for materials and
68
every thing belongs to work items is very important to estimate cost . Any defect in
one it leads to cost overrun to projects because it affected the project budget, profit and
quality of works. So quantity surveyors and estimators have a good experience,
accurate. They also develop their skills, and know the execution methods and materials,
equipment prices and rent respectively.
Table (4.4) shows that the respondents ranked “Ability to use computer in
management" in the last position with importance index (I.I = 69.14 %). Computers
used in construction management work is very beneficial because it save effort and
time, more accurate and fast. But in Gaza Strip the ability to use computers in
management is not important because most of works in companies can be done without
the use of computers and they use models for reports, check list, material delivery,
…etc. . But some institutions and companies use computers for some work like
payments, monitor cost, scheduling projects and some important reports. This result
matches Al-Hallaq, (2003) and Enshassi et al., (2006).
The Table (4.4) shows that all sub-factors have high value of IIR in managerial groups
located between 88.00 % and 69.14 % as listed in the Table (4.4) it is denoted to the
important and vital of these sub-factors and it affected the projects termination.
69
Table 4.5 IIR and ranking of financial sub-factors
Factor IIR Rank
1. Contractors bankrupting or insolvent 90.00 % 1
2. Lack of capital 86.57 % 2
3. Low margin of profit due to competition 84.57 % 3
4. Difference of local currency exchange with contract currency 84.57 % 3
5. Client delay in the contractor financial payments 84.00 % 4
6. Cost and time organization (cash flow and schedule ) 77.57 % 5
7. Evaluation of profit yearly 76.00% 6
8. Material wastages 73.43 % 7
9. Increment of project size 68.57 % 8
10. Ability to negotiating claims with clients 67.14 % 9
11. Average number of full time employees 66.57 % 10
The respondents ranked “Lack of capital." in the second position in importance index
(I.I = 86.57 %). As you see the second factor also related to money.lack of capital for
contractor means buy and execute a small project with little profit, coping with staff
have little experience to save and reduce cost of project and bad quality. So money is
the backbone for any project execution because it means materials, equipments,
experience, good profit, high quality to project findings. This result matches
Al-Hallaq, (2003).
Table (4.5) shows that the respondents ranked “Average number of full time
employees." in the last position in importance index (I.I = 66.57%). The contactor is
considered successful in his work if he saves it for company because contractors has full
70
time employees with permanent salary make the work continue with high quality
because it makes them comfortable, ingeneric and active towards their work and
company. In our companies in Gaza, the contractor has a main staff contain one
engineer, one surveyor, one monitors or two, two or three skill labors and two or three
labors in general. If work needs more employees, it attracts them with daily and
monthly wages to specific period. So this factor take the lowest value in finance group
from respondents. Hamdia, (2008) supported this finding.
The Table (4.5) shows all sub-factors have high value of IIR in finance groups limited
between 90.00 % and 66.57% as listed in the Table (4.5). It is denoted to the important
and vital of these sub-factors and it affected to project 's termination.
71
Table (4.6) illustrates that the respondents ranked “Closure." in the first position with
importance index (I.I = 92.86 %).One of the important and vital things in construction
industry in Gaza Strip is crossing because it is the only way to get all of construction
material and equipment. Any closing for the crossing, most of construction material
will not be available in the markets, which lead to termination if the period of closing is
very long. To overcome this problem the contractor must store the requested material
and instruments if it possible when he received the site to continue and complete the
project. This finding is supported by El Karriri et al. (2011), Abu Mousa, (2005) and
Al-Hallaq, (2003)
Table (4.6) shows that the respondents ranked “Lack of resources." in the second
position with importance index (I.I = 90.57 %). As discussed and explained in the
previous factor of closure if it closed the construction material and equipment will not
be available in the market of Gaza Strip especially it is exposed to injustice siege last
five years ago. This may make some material not available and if it will found its cost
will be very high. Which cause cost overrun and termination for some projects. This
result matches with Abu Mousa, J. (2005) and take the fifth important factor position in
Enshassi et al. (2006) from nine factors.
As shown in Table (4.6) the respondents ranked “Change in funding source." in the last
position with importance index (I.I = 73.43%). Because of unsuitable situation in Gaza
Strip to closing crossing, new governments, second intifata some of donors stop their
funds for projects. The owner will look for a new donors or internal funds to complete
the projects or substitution the contractor for his cost overrun. So contractor ranked this
factor in the last position. This result take the eighth important factor position in
Dilts et al. (2006) from thirteen factors.
The Table (4.6) shows all sub-factors have high value of IIR in political groups located
between 92.86 % and 73.43 % as listed in the Table (4.6) it is denoted to the important
and vital of these sub-factors and it leaded to projects termination.
72
shifting the goal posts. The IIR of each of the sub-factors of the financial group is
presented in Table 4.5 in a descending order, contain 11 sub-factors affected to
construction contract termination.
Table (4.7) shows that the respondents ranked “Working at hot (dangerous) areas " in
the first position with importance index (I.I = 86.29 %).In Gaza strip the areas near or
close to the borders are very dangerous areas because it is closed Israeli fire and
repeated attacks so the work in this areas is very dangerous to director of company. one
of staff could be killed, destroy, delay and break down the works and the arriving to the
project became difficult and suspension in some times. The contractor may work in
specified hours in the day which cause more time leads to more money and then cost
overrun if the contractor doesn't take it in his mind. This finding matches with Abu
Mousa, (2005) .
Table (4.7) clears that the respondents ranked “ National slump in economy " in the
second position with importance index (I.I = 82.29 %).The economy for any country is
represented the important factors to develop and progress it, the construction sector
effected by the economy in direct affect because slump in economy instability in
construction material and equipments, stopping the country growth and develop and
fluctuation and changes in the local currency all of this things affected to works of
project . It is advised in this state to avoid cost overrun and project termination the
73
donor must fix the cost of national currency to local currency. This finding supported
by and Al-Hallaq, (2003) and take the third position when factors ranked.
Table (4.7) illustrate that the respondents ranked “ Fare of project position to company
" in the last position with importance index (I.I = 53.14 %). Gaza strip consider a small
area comparison with other areas in world and the distance between its towns is short.
But in the first half in the last decade before the Israeli width draw from Gaza the strip
suffered from checkpoints spread a long Gaza main road. Which make difficult
transportation for persons and materials. In the second half Gaza is freed and this factor
becomes unimportant and less affected to projects works. This finding take the first
position in Abu Mousa, (2005).
The Table (4.7) shows all sub-factors have high value of IIR in environmental groups
squeezed between 86.29 % and 53.14 % as listed in the Table (4.7) it is denoted to the
important and vital of these sub-factors and it affected to projects termination.
74
Table 4.8 IIR and ranking of project characteristics sub-factors
Factor IIR Rank
1. Wrong cost estimation 88.00 % 1
2. Increase number of projects 76.57% 2
3. Quality of work 76.29 % 3
4. Life cycle period 75.43 % 4
5. Wrong estimation for the total time of the
74.86 % 5
project
6. Size & value 72.00 % 6
7. Change in overall project complexity 71.71% 7
8. Project position 65.43 % 8
9. Change in the type of work 65.43 % 9
As shown in Table (4.8) the respondents ranked “ Wrong cost estimation " in the first
position with importance index (I.I = 88.00 %).
The preparation of cost estimations is one of the most important activities in
construction. Since estimates are made at the beginning of projects, they are based on
incomplete information. Most of construction companies doesn't have the suitable ways
to make estimating to their projects in correct manner. So before the contractor makes
any estimation, he must Read contract documents very well, and know about
construction techniques, and be familiar with typical job conditions, construction
products, fluctuation and changes in the local currency etc.. And to make a correct cost
estimation you must estimate the direct field cost, the field indirect cost, the office costs
and the profit and contingency. Any mistake, the project would suffer throughout the
duration due to the lack of funding or companies may go bankrupt or project
termination. The result take the sixth important factor position in El Karriri et al. (2011)
(2006) from sixteen factors.
Table (4.8) clears that the respondents ranked “Increase number of projects " in the
second position with importance index (I.I = 76.57 %). Increase number of project
isn't a healthy case for company if the contractor can't coordinate among these projects
because he scattered work and money, brings unskilled labors and staff to complete the
shortage of his staff to work in projects, which leads to increase the period of work,
increase work repeating, increase overheads to projects and bad quality. So the suitable
75
number of projects to company capability is useful to production, progress of work with
experience to staff and best quality. This factor has the fourth value Al-Hallaq, (2003).
The respondents ranked “Change in the type of work " in the last position with
importance index (I.I = 65.43 %). The type of work in Gaza Strip doesn't influence to
companies because most projects in Gaza isn't very difficult and complex. They are of
four types of projects which are building, roads, sewage and water, and electro
mechanic and rarely you find projects different to these types. So various of projects
with skill contractor staff don't influence by quality and project progress and
termination. This factors has the third value in Enshassi et al. (2006).
The Table (4.8) shows all sub-factors have high value of IIR in project characteristics
groups limited between 88.00 % and 65.43 % as listed in the Table (4.8) it is denoted
to the importance of these sub-factors and it leads to projects termination.
Table 4.9 illustrates that the highest ten factors cause project termination from 51 sub-
factors listed under five main groups, which are ranked according to their severity of
causing project termination.
76
40% of the highest causes are listed under the financial group, while 30% of them are
listed under the political group. And also illustrate that the highest factors is " closure "
with IIR= 92.86 % that means construction material and equipments are not available in
the markets which leads to project termination if the period of closure is long. In the
second is lack of resources with IIR= 90.57 % while the contractors bankrupting or
insolvent was the third critical factor with IIR= 90.00%. and the last three critical
factors are working at hot (dangerous) areas, low margin of profit due to competition
and difference of local currency exchange with contract currency respectively.
4.5 The relationship among the highest important factors, main groups
and some items
Kurskal Wallis test (A non-parametric test used to compare three or more independent
groups of sampled data) is used to check the relationship among the highest important
factors, main groups and some items.
If The P- value is less than 0.05 there are a relationship between them and if it more
than 0.05 there are not relationship between them.
1. The relationship among the highest important factors, main groups and company years
of experience.
Table 4.10 The relationship between the main groups and the company experience
No.
Significant
No. groups of P-value
or Not
Items
1 Political Factors 12 0.285 Not
2 Managerial Factors 11 0.821 Not
3 Financial Factors 10 0.371 Not
4 Project Characteristic Factors 9 0.349 Not
5 Environmental Factors 9 0.697 Not
77
Table 4.11 The relationship between the highest important factors and the company years
of experience.
Significant
Factor Group P-value
or Not
1.Closure Political 0.217 Not
2.Lack of resources Political 0.096 Not
3.Contractors bankrupting or insolvent Financial 0.698 Not
4.Increment of material prices Political 0.242 Not
5.Lack of experience in the line of work Managerial 0.694 Not
6.Wrong cost estimation project charact. 0.117 Not
7.Lack of capital Financial 0.447 Not
8.Working at hot (dangerous) areas Environmental 0.100 Not
9.Low margin of profit due to competition Financial 0.115 Not
10.Difference of local currency exchange
Financial 0.759 Not
with contract currency
There is no relationship between the company years of experience and the main groups
and most important factors as illustrate in tables 4.10 and 4.11.
Due to the changing political situation in Gaza Strip in this period, Most of the company
need renewable information and data. These companies uses employees of their own
e.g. engineers, project mangers, etc. to overcome such circumstances.
2. The relationship among the highest important factors, main groups and projects
volume.
Table 4.12 The relationship between the main groups and the projects volume
No.
Significant
No. groups of P-value
or Not
Items
1 Political Factors 12 0.476 Not
2 Managerial Factors 11 0.198 Not
3 Financial Factors 10 0.293 Not
4 Project Characteristic Factors 9 0.887 Not
5 Environmental Factors 9 0.423 Not
78
Table 4.13 The relationship between the highest important factors and the projects
volume
Significant
Factor Group P-value
or Not
1.Closure Political 0.370 Not
2.Lack of resources Political 0.295 Not
3.Contractors bankrupting or insolvent Financial 0.102 Not
4.Increment of material prices Political 0.704 Not
5.Lack of experience in the line of work Managerial 0.223 Not
6.Wrong cost estimation project charact. 0.028 Significant
7.Lack of capital Financial 0.495 Not
8.Working at hot (dangerous) areas Environmental 0.759 Not
9.Low margin of profit due to competition Financial 0.607 Not
10.Difference of local currency exchange
Financial 0.004 Significant
with contract currency
As shown in tables 4.12 and 4.13 there is no relationship between the company volume
and the main groups and most important factors. Because of most of construction
companies in Gaza Strip are small size, a lot of companies execute small and local
projects. Therefore, Two factors had relationships. First, cost estimation which leads to
project termination if it isn't taken properly ( To consider material price, overhead,
profit and risk factors). Secondly difference of local currency exchange with contract
currency which is very important because most of the projects were funded from abroad
and there is a big difference between local and foreign currencies sometimes occurs
because of unsuitable political situation.
79
3. The relationship among the highest important factors, main groups and number of
contracts termination.
Table 4.14 The relationship between the main groups and the number of contracts
termination
No.
Significant
No. groups of P-value
or Not
Items
1 Political Factors 12 0.180 Not
2 Managerial Factors 11 0.300 Not
3 Financial Factors 10 0.809 Not
4 Project Characteristic Factors 9 0.592 Not
5 Environmental Factors 9 0.498 Not
Table 4.15 The relationship between the highest important factors and the number of
contracts termination
Significant
Factor Group P-value
or Not
1.Closure Political 0.090 Not
2.Lack of resources Political 0.230 Not
3.Contractors bankrupting or insolvent Financial 0.686 Not
4.Increment of material prices Political 0.499 Not
5.Lack of experience in the line of work Managerial 0.721 Not
6.Wrong cost estimation project charact. 0.601 Not
7.Lack of capital Financial 0.753 Not
8.Working at hot (dangerous) areas Environmental 0.451 Not
9.Low margin of profit due to competition Financial 0.522 Not
10.Difference of local currency exchange with
Financial 0.627 Not
contract currency
There were not a lot of projects in this period because of the events occurred in Gaza
Strip like intifada, closure, civil war and others and little projects is awarded to most
companies, Therefore, There is no relationship between the number of project expose
80
to unnatural termination and the main groups and most important factors as shown in
tables 4.14 and 4.15.
4. The relationship among the highest important factors, main groups and satisfaction of
`the administrative level.
Table 4.16 The relationship between the main groups and satisfaction of the
administrative level
No.
Significant
No. groups of P-value
or Not
Items
1 Political Factors 12 0.226 Not
2 Managerial Factors 11 0.276 Not
3 Financial Factors 10 0.362 Not
4 Project Characteristic Factors 9 0.376 Not
5 Environmental Factors 9 0.780 Not
Table 4.17 The relationship between the highest important factors and satisfaction of the
administrative level
Significant
Factor Group P-value
or Not
1.Closure Political 0.947 Not
2.Lack of resources Political 0.895 Not
3.Contractors bankrupting or insolvent Financial 0.340 Not
4.Increment of material prices Political 0.316 Not
5.Lack of experience in the line of work Managerial 0.247 Not
6.Wrong cost estimation project charact. 0.829 Not
7.Lack of capital Financial 0.055 Not
8.Working at hot (dangerous) areas Environmental 0.146 Not
9.Low margin of profit due to competition Financial 0.131 Not
10.Difference of local currency exchange with
Financial 0.636 Not
contract currency
81
Tables 4.16 and 4.17 show there is no relationship between the satisfaction of the
administrative level and the main groups and most important factors. that most of the
companies in Gaza Strip are small, local and need simple administration skills.
Therefore, It is very easy to control their activities and employees and solve their
problem easily and fast.
5. The relationship among the highest important factors, main groups and who has the
final decision
Table 4.18 The relationship between the main groups and who has the final decision
No.
Significant
No. groups of P-value
or Not
Items
1 Political Factors 12 0.086 Not
2 Managerial Factors 11 0.138 Not
3 Financial Factors 10 0.180 Not
4 Project Characteristic Factors 9 0.126 Not
5 Environmental Factors 9 0.299 Not
Table 4.19 The relationship between the highest important factors and who has the final
decision
Significant
Factor Group P-value
or Not
1.Closure Political 0.638 Not
2.Lack of resources Political 0.933 Not
3.Contractors bankrupting or insolvent Financial 0.243 Not
4.Increment of material prices Political 0.051 Not
5.Lack of experience in the line of work Managerial 0.815 Not
6.Wrong cost estimation project charact. 0.254 Not
7.Lack of capital Financial 0.258 Not
8.Working at hot (dangerous) areas Environmental 0.980 Not
9.Low margin of profit due to competition Financial 0.809 Not
10.Difference of local currency exchange
Financial 0.389 Not
with contract currency
82
In most of the construction companies the final decision goes back to the directors as
mention before, Therefore, he always thinks very deeply in any decision in order not to
affect his company because of wrong decisions. So there is no relationship between who
has final decision and the main groups and most important factors as clear in tables 4.18
and 4.19.
The construction industry is an important part of the national and state economies. In
order to continue to be a successful part of that economy, owners and contractors must
have a clearer understanding of their rights, duties and obligations to each other now
and for future projects (Wittbrodt et al., 2009).
The construction contracting business has the second highest failure rate of any
business, exceeded only by restaurants (Clough and Sears as cited Enshassi et al., 2006).
The results of the study of the situation of construction contracts termination in Gaza
Strip in the last ten years are: Most of our companies work in several types of works
like building, roads and sewage and water, with classification degree first or second,
their experience more than ten years, the average volume of executed projects annually
is located between 1 to 2 million dollars, the number of permanent employees in the
companies located between 10 to 15 or less than ten, (86%) of companies exposed to
construction contract termination and the number of contracts terminated are located
between 1 to 3 contracts, most of the ( 62%) refer to the termination to the donors and
they solve the dispute resulting from contracts termination by negotiation, most of
companies make documentation for problems which face it to benefit from it in the
future, (92%) of employees satisfied or very satisfied about the administrative level in
their companies, the person who has the final decision in the company is directors
(73.97%) especially in the finical issues and the project mangers or site engineers in
managerial issues. The most critical factors causes project termination in Gaza Strip are
closure, lack of resources, contractors bankrupting or insolvent, increment of material
prices, lack of experience in the line of work, wrong cost estimation, lack of capital,
working at hot (dangerous) areas, low margin of profit due to competition and
difference of local currency exchange with contract currency.
83
Chapter 5
Conclusion and Recommendations
This chapter includes the conclusions, practical recommendations that may prevent or
even reduce construction contracts termination, and proposed additional studies in the
subject in the future.
5.1 Conclusion
Most of construction companies work in several types of works like building, roads
and sewage and water, with classification degree first or second. Their experience more
than ten years, the average volume of executed project in annually is located between 1
to 2 million dollars. The number of permanent employees in the companies located
between 10 to 15 or less than ten.
Around 86% of companies exposed to construction contract termination and the number
of contracts terminated are located between 1 to 3 contracts. Most of the contracts
termination ( 62%) refer to the donors. Negotiation is method to solve the resulting
dispute from contracts termination. Most of companies make documentation for
problems which used to proof their rights.
92% of employees were satisfied or very satisfied about the administrative level in their
companies. The person who have the final decision in the company is directors (74%)
especially in the financial issue and the project mangers or site engineer in managerial
issues.
40% of the most important factors affecting the construction contracts termination are
related to financial issue while 30% of the most important factors are related to political
issue.
The findings obtained from correlation test between groups and the mean is a strong
positive relationship. It can be said that the groups are consistent , valid, reliable to
measure.
The test mad to find relationships between the company independent factors and
termination that there is a significant relation between wrong cost estimation and the
project volume and difference of local currency exchange with contract currency and
the project volume.
5.2 Recommendations
a. For Government
1. The government must take the risk when the Donors delay the dibs of the contractors
And try to save a new resource or internal fund.
2. The government have award contracts to the most suitable estimated cost and not
necessarily to the lowest bidder.
3. The government is recommended to connect the contract price with index because of
changeable political conditions.
4. The contract clauses should be modified and improved to meet the impact of closure
and siege of Gaza Strip and not to allocate the whole impacts on the contracting
companies. These contracts are supposed to make companies make profits.
5. The government and donors must coordinate and cooperate with contractors. In
addition, they must support contracting sector as a fundamental component of
Palestinian economy.
85
b. For Contractors Union
1. The contractors union should conduct continuous training programs with co-
operation with the Islamic University to improve managerial and financial practices to
explain the internal and external factors affecting the construction industry.
2. The contractors union should be defend the interests and good the PCU members,
maintain the tradition and honor related to practicing construction contracting
profession and assist in solving the disputes arising between and among members and
others.
3. The contractors union should clarify the rights of for PCU members, regulations and
laws related to construction industry when they exposed to contracts termination.
c. For Contractors
1.Top management must positively react to changes of managerial and financial
polices.
2. Contractors are recommended to have qualified and quantified technical staff with
appropriate experience of the project in order to be able to follow the different
technical and managerial aspects of the project. The staff will be more effective if it is
consisted of enough numbers of engineers, technicians, and foremen, so the
responsibilities would be shared between all of them.
4. The contracting companies should prepare effective cost estimate and should not look
to increase the number of projects that cannot be controlled by its staff.
86
5.3 Proposed further studies
1. The factors affecting the construction contracts termination studied from contractor 's
respective only. So it is important to repeat this study and take and add owner and donor
respective and comparison among them.
2. This study was conducted during the ongoing siege Gaza Strip. It is better to repeat
this study in usual environment to compare to what extent the impact of siege has on
contractors.
3. It is necessary to repeat this research every 5 years to observe the new trends of
contractors.
87
References
Abdal-Hadi, M. (2010), Factors affecting accuracy of pre-tender cost estimate in Gaza
Strip, MSc. Dissertation. Islamic University of Gaza Strip, Palestine.
Abu Mousa, J. (2005), Risk management in construction projects from contractors and
owners" perspectives, MSc. Dissertation. Islamic University of Gaza Strip.
Albert, C. (2001), Design and build project success factors multivariate analysis,
Journal of Construction Engineering and Management, Vol. 132, BSCE, Mar/Apr.
Al-Najjar, J. (2008), Factors influencing time and cost overruns on construction projects
in the Gaza Strip, MSc. Dissertation. Islamic University of Gaza Strip, Palestine.
Al-Shanti, Y. (2003), A cost estimate system for Gaza Strip construction contractors,
MSc. Dissertation. Islamic University of Gaza Strip, Palestine.
Altman D.G. (1991), Practical Statistics for Medical Research. Chapman & Hall,
London, pp.285 – 288.
Arora, M (1995), Project management: One step beyond, Civil Engineering, pp 66-68.
Article, Coping With Termination, (2008), Master builder, UAE construction scene,
pp 76-78.
88
Anderson, L. (2010), The top three causes of project failure, LMN consulting group Inc.
Balachandra, R., Friar, J., 1997. Factors for success in R&D projects and new product
innovation: a contextual framework. IEEE Transactions on Engineering Management
Vol. 44 (3), pp. 276–287.
Belassi, W., Tukel, O. (1996), A new framework for determining critical success/failure
factors in projects, International Journal of Project Management, Vol. 14, No. 3,
pp.141-151.
Belout, A., Gauvreau, C. (2004), Factors influencing project success: the impact of
human resource management, International Journal of Project Management, Vol. 22,
pp.1–11.
BaniHani, W., Hajeer, S. (2007), Why GIS projects fail, Yarmouk University, Irbid,
Jordan.
Banks, J., Carson, J. S. II, Nelson, B. L., and Nicol, D. M. (2000), Discrete event system
simulation, Prentice international series in industrial and systems engineering.
Bonneville purchasing instructions, (BPI ). (2007), Part 24, Construction and demolition
contracts, pp 1-24.
Bryde, D., Robinson, L. (2005), Client versus contractor perspectives on project success
criteria, International Journal of Project Management, Vol. 23, pp. 622–629.
Bucero, A. (2005), Project Know-How, PM Network, May 2005 issue, [Electronic],
pp 20-22.
89
Bunni, N. (2000), Recent developments in dispute resolution under the FIDIC
Contracts, First International Conference on Engineering Arbitration,
Bahrain.
Cheung, S.O. and Yeung, Y.W. (1998), The effectiveness of the dispute
Resolution advisor system: a critical appraisal, International Journal of
Project Management, Vol. 16, No. 6, pp. 367-374.
Cheung, O. (1999), Critical factors affecting the use of alternative dispute resolution
processes in construction. International Journal of Project Management. Vol. 17( 3),
pp. 189-194.
Clough, R.H. and Sears, G.A. (2000). Construction Contracting. USA: John Wiley and
Sons, Inc.
David V., Kreutzwiser R. and Loe, R. (2003), Selecting appropriate dispute resolution
techniques: a rural water management example. Journal of Applied Geography,
Vol.23(3), pp. 89–113.
Dilts, D., Pence, K. (2006), Impact of role in the decision to fail: An exploratory study
of terminated projects, Journal of Operations Management, Vol. 24, pp. 378–396.
90
Dvir, D. (2005), Transferring projects to their final users: The effect of planning and
preparations for commissioning on project success, International Journal of Project
Management, Vol. 23, pp 257–265.
El Karriri, A., Yasin, M., Alhabeel, A. (2011), Investigating key drivers for contract
termination in construction project in Gaza strip , The Islamic University Journal
Vol.19, No.1, pp. 179-195.
El-Sayegh, S. (2008), Risk assessment and allocation in the UAE construction industry,
International Journal of Project Management, Vol. 26, pp 431–438.
EPM (Engineering project management), Project termination,
<<http://www.imse.hku.hk/imse3002/Overview%20HTML/7.htm>>, Accessed on
April 2011.
Gauthier, T. (2001), Detecting trends using spearman 's rank correlation coefficient,
Environmental forensics, Vol. 2, pp 359-363, USA.
Halim M., Jaafar M., Osman O., Akbar S. (2010), The contracting firm’s failure and
financial related factors: A case study of malaysian contracting firms, International
Research Journal of Finance and Economics, Vol. 52, pp.1450-2887.
91
Hamdia, A. (2008), Investigation of critical success factors for construction sector in
Gaza Strip from the contractor's perspective, MSc. Dissertation. Islamic University of
Gaza Strip.
Iyer K., Chaphalkar N. , Joshi G., (2008), Understanding time delay disputes in
construction contracts, International Journal of Project Management, Vol. 26, No. 2,
pp. 174-184.
Lam, K., Wang, D., Lee, P., Tsang, T. (2007), Modeling risk allocation decision in
construction contracts, International Journal of Project Management, Vol. 25,
pp. 485–493.
Loo, R. (2002), Journaling: A learning tool for project management training and team-
building, Project Management Journal; Dec 2002 issue, vol. 33, no. 4, [Electronic],
pp 61-66.
92
Medda, F. (2007), A game theory approach for the allocation of risks in transport public
private partnerships, International Journal of Project Management, vol.25,
pp. 213-218.
Meredith, J. (2000), Project management: a managerial approach, New York: Wiley, pp.
541–3.
NAO, (2008), Good practice contract management framework, section 1-3, National
Audit Office, London.
Ogunlana, S., Siddiqui, Z.,Yisa, S., Olomolaiye, P. (2002), Factors and procedures used
in matching project managers to construction projects in Bangkok, International Journal
of Project Management, Vol. 20, pp. 385–400.
93
Palestine central bureau of statistics (PCBS), Reports (2004), <<www.pcbs.gov.ps>>,
Accessed on April 2009.
Reddy, G., Andrew, T. (2005), Construction project failures: Towards systems thinking
strategies for Improving the construction delivery process, Durban Institute of
Technology and University of Johannesburg.
Reed, B. (2001), Making things happen (better) with project management, May/Jun
2001 issue, 21, 3, [Electronic], pp 42-46.
Rosenau & Githens (2005), Successful Project Management, 4th Edition, Wiley and
Sons, USA, p300.
Sauser, B., Reilly, R., Shenhar, A. (2009), Why projects fail? How contingency theory
can provide new insights – A comparative analysis of NASA’s Mars Climate Orbiter
loss, International Journal of Project Management, Vol. 27, pp. 665–679.
94
Seid, K. (2008), Study of problems of construction condition of contract for public
works in Ethiopia, Addis Ababa University, Ethiopia.
Spirer H. (1983), “Phasing Out the Project,” in D. I. Cleland and W. R. King (eds.),
Project Management Handbook (New York: Van Nostrand Reinhold).
Project Planning & Control, Lecture 11, Project audits, termination & review,
<<http://webpages.sdsmt.edu/~djensen/TM%20665/Lectures/TM%20665%20Lecture%
2011.ppt>>, Accessed on May 2011.
Thomset, R. ( 2002), Radical Project Management, Prentice Hall PTR, USA, p260.
95
Wideman, M, Wideman Comparative Glossary of Project Management,
<< http://www.maxwideman.com/pmglossary/PMG_O01.htm >>, Accessed on
September 2003.
Wittbrodt R., Eaton L.(2009), Project suspension: What owners & contractors need to
know - now, Id. at 464-65., California.
Wood G. L., and Haber J. (1998), Nursing research: methods, critical appraisal, and
utilization, Mosby.
Yates, David (2003), Can claims and disputes (in construction contracts) be
prevented or reduced?, Building Journal, Hongkong China.
Yi, H., Zhao, Y., Qi, J. (2006), Failure factors in Chinese construction enterprises
Business and management, School of Business Administration, North China Electric
Power Univ., Beijing, China.
Yng Ling, F., Meng Poh, B. (2008), Problems encountered by owners of design–build
projects in Singapore, International Journal of Project Management, Vol. 26,
pp.164–173.
Zou, P., Zhang, G., Wang, J. (2007), Understanding the key risks in construction
projects in China, International Journal of Project Management, Vol. 25 , pp. 601–614.
96
Annex 1
ﺑﺳم اﷲ اﻟرﺣﻣن اﻟرﺣﯾم
إﺳﺗﺑﺎﻧﺔ
ﺣول دراﺳﺔ اﻟﻌواﻣل اﻟﻣؤﺛرة ﻋﻠﻰ إﻧﻬﺎء اﻟﻌﻘود اﻹﻧﺷﺎﺋﯾﺔ ﻓﻲ ﻗطﺎع ﻏزة ﺑﺷﻛل ﻏﯾر طﺑﯾﻌﻲ
ﯾوﻧﯾو 2011
97
إﺳﺗﺑﺎﻧﺔ
ﺣول دراﺳﺔ اﻟﻌواﻣل اﻟﻣؤﺛرة ﻋﻠﻰ إﻧﻬﺎء اﻟﻣﺷﺎرﯾﻊ اﻹﻧﺷﺎﺋﯾﺔ ﻓﻲ ﻗطﺎع ﻏزة ﺑﺷﻛل ﻏﯾر طﺑﯾﻌﻲ
ﻧﺷﻛر ﺗﻌﺎوﻧﻛم وﻣﺳﺎﻫﻣﺎﺗﻛم ﻓﻲ ﺗﻌﺑﺋﺔ ﻫذا اﻻﺳﺗﺑﯾﺎن اﻟذي ﯾﻌﺗﺑر ﺟزء ﻣن اﻟﺑﺣث اﻟﺗﻛﻣﯾﻠﻲ ﻟﻧﯾل درﺟﺔ
اﻟﻣﺎﺟﺳﺗﯾر ﻓﻲ إدارة اﻟﻣﺷروﻋﺎت اﻟﻬﻧدﺳﯾﺔ .ﻣن ﺧﻼل اﻹﺳﺗﺑﺎﻧﺔ ﻧرﺟو اﻟﺗﻌرف ﻋﻠﻰ اﻟﻌواﻣل اﻟﻣؤﺛرة
ﻋﻠﻰ إﻧﻬﺎء اﻟﻣﺷﺎرﯾﻊ اﻹﻧﺷﺎﺋﯾﺔ ﻓﻲ ﻗطﺎع ﻏزة ﺑﺷﻛل ﻏﯾر طﺑﯾﻌﻲ ﺧﻼل اﻟﺳﻧوات اﻟﻌﺷر اﻟﻣﺎﺿﯾﺔ.
آﻣﻠﯾن أن ﯾﻧﺗﺞ ﻋن ﻫذﻩ اﻟدراﺳﺔ اﻟﺗﻘﻠﯾل ﻣن ظﺎﻫرة إﻧﻬﺎء اﻟﻣﺷﺎرﯾﻊ اﻹﻧﺷﺎﺋﯾﺔ ﻓﻲ ﻗطﺎع ﻏزة ﺑﺷﻛل
.3اﻟﻌواﻣل اﻟﻣؤﺛرة ﻋﻠﻰ إﻧﻬﺎء اﻟﻣﺷﺎرﯾﻊ اﻹﻧﺷﺎﺋﯾﺔ ﻓﻲ ﻗطﺎع ﻏزة ﺑﺷﻛل ﻏﯾر طﺑﯾﻌﻲ.
اﻟﻣﻌﻠوﻣﺎت اﻟواردة ﻓﻲ اﻻﺳﺗﺑﯾﺎن ﯾﺗم اﻻﺳﺗﻔﺎدة ﻣﻧﻬﺎ ﻟﻐرض اﻟﺑﺣث اﻟﻌﻠﻣﻲ ﻓﻘط وﻟن ﺗﻧﻘل ﻷي ﺟﻬﺔ
أﺧرى ،وﯾﺗم اﻟﺗﻌﺎﻣل ﻣﻌﻬﺎ ﻛﻣﻌﻠوﻣﺎت ﻣﻧﻔﺻﻠﺔ ﻋن ﻣﺻدرﻫﺎ وﻟن ﺗﺳﺗﺧدم ﻷي أﻏراض أﺧري.
98
إﺳﺗﺑﺎﻧﺔ ﺗﻬدف إﻟﻰ دراﺳﺔ اﻟﻌواﻣل اﻟﻣؤﺛرة ﻋﻠﻰ إﻧﻬﺎء اﻟﻣﺷﺎرﯾﻊ اﻹﻧﺷﺎﺋﯾﺔ ﻓﻲ ﻗطﺎع ﻏزة ﺑﺷﻛل
ﻏﯾر طﺑﯾﻌﻲ
□ ﻣﻦ 5-3ﺳﻨﻮات .5ﻋﺪد ﺳﻨﻮات اﻟﺨﺒﺮة ﻟﻤﻦ ﯾﻘﻮم ﺑﺘﻌﺒﺌﺔ اﻻﺳﺘﺒﯿﺎن □ :ﻣﻦ 3-1ﺳﻨﻮات
□ أﻛﺜﺮ ﻣﻦ 10ﺳﻨﻮات □ ﻣﻦ 10-5ﺳﻨﻮات
.7ﻣﻌﺪل ﻗﯿﻤﺔ اﻟﻤﺸﺎرﯾﻊ اﻟﺘﻲ ﯾﺘﻢ ﺗﻨﻔﯿﺬھﺎ ﺳﻨﻮﯾﺎ )ﺑﺎﻟﺪوﻻر( □ :أﻗﻞ ﻣﻦ 1ﻣﻠﯿﻮن □ ﻣﻦ 1إﻟﻰ 2ﻣﻠﯿﻮن
□ ﻣﻦ 2إﻟﻰ 3ﻣﻠﯿﻮن □ أﻛﺜﺮ ﻣﻦ 3ﻣﻠﯿﻮن
99
ﻓﻘرة )ب( :ﺗﻘﯾﯾم واﻗﻊ إﻧﻬﺎء اﻟﻣﺷﺎرﯾﻊ اﻹﻧﺷﺎﺋﯾﺔ ﻓﻲ ﻗطﺎع ﻏزة.
.1ھﻞ ﺗﻌﺮﺿﺖ ﺷﺮﻛﺘﻜﻢ ﻹﻧﮭﺎء ﺑﻌﺾ اﻟﻤﺸﺎرﯾﻊ ﺳﺎﺑﻘﺎ ﺑﺸﻜﻞ ﻏﯿﺮ طﺒﯿﻌﻲ ؟
ﻻ ﻧﻌﻢ
.4ھﻞ ﺗﺤﺎول اﻟﺸﺮﻛﺔ اﻻﺳﺘﻔﺎدة ﻣﻦ اﻷﺧﻄﺎء اﻟﺴﺎﺑﻘﺔ اﻟﺘﻲ أدت ﻟﺤ ﺪوث إﻧﮭ ﺎء اﻟﻤﺸ ﺎرﯾﻊ اﻟﺴ ﺎﺑﻘﺔ
ﺑﺸﻜﻞ ﻏﯿﺮ طﺒﯿﻌﻲ؟
ﻻ أﺣﯿﺎﻧﺎ ﻧﻌﻢ ،داﺋﻤﺎ
100
.7ھﻞ أﻧﺖ راض ﻋﻦ ﻣﺴﺘﻮى إدارة اﻟﻤﺸﺎرﯾﻊ ﻟﺪى ﺷﺮﻛﺘﻜﻢ ؟
ﻏﯿﺮ راض ﻣﺤﺎﯾﺪ راض راض ﺟﺪا
ﻓﻘرة )ج( :اﻟﻌواﻣل اﻟﻣؤﺛرة ﻋﻠﻰ إﻧﻬﺎء اﻟﻣﺷﺎرﯾﻊ اﻹﻧﺷﺎﺋﯾﺔ ﻓﻲ ﻗطﺎع ﻏزة ﺑﺷﻛل ﻏﯾر طﺑﯾﻌﻲ
ﻓﻲ اﻟﺟدول اﻟﺗﺎﻟﻲ ﻫﻧﺎك ﻋدد ﻣن اﻟﻌواﻣل اﻟﻣﻬﻣﺔ اﻟﻣؤﺛرة ﻋﻠﻰ إﻧﻬﺎء اﻟﻣﺷﺎرﯾﻊ اﻹﻧﺷﺎﺋﯾﺔ ﻓﻲ ﻗطﺎع
ﻏزة ﺑﺷﻛل ﻏﯾر طﺑﯾﻌﻲ ،اﻟرﺟﺎء اﺧﺗﯾﺎر درﺟﺔ اﻷﻫﻣﯾﺔ اﻟﺗﻲ ﺗراﻫﺎ ﻣﻧﺎﺳﺑﺔ ﺑوﺿﻊ إﺷﺎرة" "Pﻟﺗﻌﺑر
ﻋن ﻣدى اﻷﻫﻣﯾﺔ.
درﺟﺔ اﻷھﻤﯿﺔ
ﻏﯿﺮ ﻣﮭﻢ ﺟﺪا
ﻏﯿﺮ ﻣﮭﻢ
ﻣﮭﻢ ﺟﺪا
اﻟﻌﻮاﻣﻞ اﻟﻤﺆﺛﺮة
ﻣﺘﻮﺳﻂ
ﻣﮭﻢ
101
ﺛﺎﻧﯿﺎ :ﻋــــــﻮاﻣـــــﻞ ﻣﺎﻟﯿﺔ
.1ﺗﺪﻧﻲ اﻟﺮﺑﺢ ﺑﺴﺒﺐ اﻟﻤﻨﺎﻓﺴﺔ
.2رأس اﻟﻤﺎل ﻏﯿﺮ ﻛﺎﻓﻲ
.3ﺗﻐﯿﺮ ﺳﻌﺮ ﺻﺮف اﻟﻌﻤﻠﺔ اﻟﻤﺤﻠﯿﺔ ﺑﺎﻟﻨﺴﺒﺔ ﻟﻠﻌﻤﻼت
اﻟﻤﺴﺘﺨﺪﻣﺔ ﻓﻲ اﻟﻌﻘﻮد
.4ﺗﺄﺧﯿﺮ اﻟﻤﺎﻟﻚ ﻓﻲ دﻓﻊ اﻟﺪﻓﻌﺎت اﻟﻤﺎﻟﯿﺔ ﻓﻲ وﻗﺘﮭﺎ
.5إﻓﻼس اﻟﻤﻘﺎول
.6ﻧﻈﺎم ﺗﺮﺳﯿﮫ اﻟﻌﻄﺎء ﻋﻠﻰ اﻗﻞ اﻷﺳﻌﺎر
.7ﺣﺴﺎب ﻓﻮاﻗﺪ اﻟﻤﻮاد
.8ﻗﺪرة اﻟﻤﻘﺎول ﻋﻠﻰ ﻣﻔﺎوﺿﺔ اﻟﻤﺎﻟﻚ ﻋﻠﻰ اﻟﻤﻄﺎﻟﺒﺎت
.9زﯾﺎدة ﺣﺠﻢ اﻟﻤﺸﺮوع
.10ﻋﺪد اﻟﻌﻤﺎل اﻟﻤﻮﺟﻮدون ﻓﻲ اﻟﻤﻮﻗﻊ ﺑﺪوام ﻛﻠﻲ
.11ﺗﻨﻈﯿﻢ اﻟﻮﻗﺖ واﻟﺘﻜﻠﻔﺔ ﻟﻠﻤﺸﺮوع ) اﻟﺘﺪﻓﻖ اﻟﻨﻘﺪي و اﻟﺠﺪول
اﻟﺰﻣﻨﻲ(
ﺛﺎﻟﺜﺎ :ﻋــــــﻮاﻣـــــﻞ ﺳﯿﺎﺳﯿﺔ
.1ﻋﺪم وﺟﻮد ﺗﻮﻗﻌﺎت واﺿﺤﺔ ﻟﺪى اﻟﺸﺮﻛﺔ
.2اﻟﻤﺸﺎﻛﻞ اﻟﺪاﺧﻠﯿﺔ ﻣﺜﻞ اﻻﻧﻘﺴﺎم واﻟﺘﻮاﺻﻞ ﺧﺎرﺟﯿﺎ
.3ﺗﻐﯿﺮ اﻷﻧﻈﻤﺔ واﻟﻘﻮاﻧﯿﻦ اﻟﺪاﺧﻠﯿﺔ ﻟﻠﺒﻠﺪ
.4اﻟﺰﯾﺎدة ﻓﻲ أﺳﻌﺎر اﻟﻤﻮاد
.5ﺳﯿﺎﺳﺔ اﻟﺒﻨﻮك
.6إﻏﻼق اﻟﻤﻌﺎﺑﺮ
.7ﻧﻘﺺ اﻟﻤﻮاد ﻣﻦ اﻷﺳﻮاق اﻟﻤﺤﻠﯿﺔ
.8ﺻﻌﻮﺑﺔ اﻟﺤﺼﻮل ﻋﻠﻰ ﺑﻌﺾ اﻟﺘﺼﺎرﯾﺢ
اﻟﻼزﻣﺔ ﻟﻠﻌﻤﻞ
.9ﺗﻐﯿﺮ ﻣﻤﻮﻟﻲ اﻟﻤﺸﺎرﯾﻊ ﻓﻲ اﻟﻘﻄﺎع
.10اﻟﺘﻀﺨﻢ ﻓﻲ اﻟﻌﺎﻟﻢ
راﺑﻌﺎ :ﻋــــــﻮاﻣـــــﻞ ﺑﯿﺌﯿﺔ
.1أﺣﻮال اﻟﺠﻮ اﻟﻤﻨﺎﺧﯿﺔ اﻟﻤﻌﺎﻛﺴﺔ
.2اﻟﺒﯿﺌﺔ اﻻﺟﺘﻤﺎﻋﯿﺔ ﻟﻠﺴﻜﺎن ﺑﺎﻟﻘﺮب ﻣﻦ اﻟﻤﺸﺮوع
.3اﻟﻨﻈﺎم اﻟﻀﺮﯾﺒﻲ ﻓﻲ اﻟﺒﻼد) اﻟﻘﻮاﻧﯿﻦ ،ﻧﻈﺎم اﻟﻤﺤﺎﺳﺒﺔ
اﻟﻀﺮﯾﺒﯿﺔ ،اﻟﻔﺎﺗﻮرة اﻟﺼﻔﺮﯾﺔ ...اﻟﺦ(
.4اﻟﻌﻤﻞ ﻓﻲ اﻟﻤﻨﺎطﻖ اﻟﺨﻄﺮة)ﻣﺠﺎورة ﻟﻤﻮاﻗﻊ اﻟﺠﯿﺶ
اﻹﺳﺮاﺋﯿﻠﻲ(
.5ھﺒﻮط ﻓﻲ اﻟﺤﺎﻟﺔ اﻻﻗﺘﺼﺎدﯾﺔ ﻓﻲ اﻟﺒﻼد
102
.6ﺗﻐﯿﺮ ﻓﻲ اﻟﻤﻮارد ) اﻟﻤﺎل و اﻟﻤﻜﺎن و اﻟﻤﺼﺎدر اﻟﺒﺸﺮﯾﺔ(
.7ﻧﻘﺺ اﻟﻤﺤﻜﻤﯿﻦ اﻟﻤﺨﺘﺼﯿﻦ ﻓﻲ ﺣﻞ اﻟﻨﺰاﻋﺎت اﻟﮭﻨﺪﺳﯿﺔ
.8أﻋﻤﺎل ﻏﯿﺮ ﻣﺘﻮﻗﻌﺔ )رﯾﺎح ﺷﺪﯾﺪة ،زﻟﺰال(....،
.9ﺑﻌﺪ اﻟﻤﺸﺮوع ﻋﻦ اﻟﻤﻘﺮ اﻟﺮﺋﯿﺴﻲ ﻟﻠﺸﺮﻛﺔ
ﺧﺎﻣﺴﺎ :ﻋــــــﻮاﻣـــــﻞ ﺗﺘﻌﻠﻖ ﺑﺎﻟﻤﺸﺮوع
.1اﻟﺘﻨﻮع ﻓﻲ اﻟﻤﺸﺎرﯾﻊ ) ﻣﺒﺎﻧﻲ و طﺮق و(...
.2ﺣﺠﻢ وﻗﯿﻤﺔ اﻟﻤﺸﺮوع
.3طﻮل ﻓﺘﺮة ﺣﯿﺎة اﻟﻤﺸﺮوع
.4زﯾﺎدة ﻋﺪد اﻟﻤﺸﺎرﯾﻊ ﻟﺪى اﻟﻤﻘﺎول
.5ﻋﺪم ﺗﻮﻗﻊ ﻓﺘﺮة اﻟﻤﺸﺮوع ﺑﺸﻜﻞ ﻣﻨﺎﺳﺐ
.6ﻣﻜﺎن اﻟﻤﺸﺮوع
.7اﻟﺘﻐﯿﺮ ﻓﻲ ﺗﻌﻘﯿﺪات اﻟﻤﺸﺮوع ) ﻓﻨﯿﺔ ،إدارﯾﺔ (...،
.8ﺟﻮدة اﻟﻌﻤﻞ اﻟﻤﻄﻠﻮﺑﺔ
103
Annex 2
A questionnaire aims to investigation of factors affecting on termination of
construction projects in Gaza Strip
8. Number of labors
□ Less than 10 □ From 10 to less than 15
□ From 15 to 20 □ More than 20
104
Part B : Evaluation the current situation in Gaza Strip
□ Yes □ No
If the answer is Yes
□ From 1 t o 3 □From 3 t o 5
□ From 5 to 10 □ More than 10
3. To whom you refer the unnatural project termination ?
□ Contractor □ Owner
□ Donor □ Project manager
4. How you are solving the resulting dispute from unnatural project termination ?
□ Negotiation □ Mediation
□ Arbitration □ Litigation
5. Benefits from Previous Information?
105
Part C : Project termination factors ( Please tick "P" to importance degree to the
following like you see )
Important
Important
Very Low
Medium
High
Low
Item
1. Managerial Factors
1. Lack of experience in the line of work
2. Company organization
3. Frauds
4. Neglect
5. Inaccurate quantities
6. Unmanaged cash flow
7. Resource management
8. Poor communication between involved parties
9. Ability to put plans to work
10. Ability to use computer in management
11. Ability to work as a team
12. Unclear goals
2. Financial Factors
1. Low margin of profit due to competition
2. Lack of capital
3. Difference of local currency exchange with contract
currency
4. Client delay in the contractor financial payments.
5. Contractors bankrupting or insolvent
6. Evaluation of profit yearly
7. Material wastages
8. Ability to negotiating claims with clients.
9. Increment of project size
10. Average number of full time employees
11. Cost and time organization (cash flow and schedule )
106
3. Political Factors
1. Lack of clear expectations
2. Internal political troubles; as: rebellion, civil war, or
disorder.
3. Change in regulatory problems
4. Increment of material prices
5. Banks policy
6. Closure
7. Lack of resources
8. Difficulty to get permits
9. Change in funding source
10. World inflation
4. Environmental Factors
1. Adverse climate conditions
2. Social environment
3. Accounting and tax practices
4. Working at hot (dangerous) areas
5. National slump in economy
6. Change in resources (people, materials, funds)
7. No specialized arbitrators to help settle fast
8. Acts of God
9. Fare of project position to company
5. Project Characteristic Factors
1. Change in the type of work
2. Size & value
3. Life cycle period
4. Increase number of projects
5. Wrong estimation for the total time of the project.
6. Project position
7. Change in overall project complexity
8. Quality of work
9. Wrong cost estimation
107