NLC Tender
NLC Tender
Volume-1 of 2
TENDER DOCUMENT
FOR
Installation of 2 x 10 MW (AC) Grid interactive Solar PV Power Project integrated with
8 MWhr. Battery Energy Storage System at Andaman includes Operation and
Maintenance of the entire system for ten years after one year warranty period
Last date of Remitting Tender fee & 23.03.2018 at 16.00 hrs. IST
Registration
Last Date & Time of submission of Physical 27.03.2018 at 14.30 hrs. IST
forms in sealed cover (i.e. Bid Guarantee,
Letter of undertaking and Check list for
compliance of important Tender Conditions.)
Date & Time of opening of Physical forms 27.03.2018 at 15.00 hrs. IST
sealed in sealed Cover.
Date & time of opening of e-Bids (Cover – II) 27.03.2018 at 15.00 hrs. IST
(i.e. QR documents ,Integrity pact, Techno-
Commercial details and Price schedule)
Page 2 of 328
INDEX
Page 3 of 328
21. Agency commission 35
22. Vital Clauses 35
23. Conditions of Contract 35
Section - E
Specimen of Formats
Page 4 of 328
SECTION - A
(Newspaper)
NLC INDIA LIMITED
(FORMERLY NEYVELI LIGNITE CORPORATION LIMITED)
1.0 Online Bids in English are invited by NLC INDIA LIMITED, NEYVELI for the
following:
Tender No. CO CONTS/0006G/ PV Solar- BESS/ICB/Andaman /e-conts/2018,
dt.24.02.2018.
Name of the work Installation of 2 x 10 MW (AC) Grid
interactive Solar PV Power Project
integrated with 8 MWhr. Battery
Energy Storage System at Attam Pahad and
at Dolly Gunj, Port Blair, South Andaman.
The scope of work also includes Operation
and Maintenance of the entire system for
ten years after one year warranty period.
2.0 For further details such as Qualifying Requirements, Detailed Scope of work etc. and
Tender Document please log on to our website: www.nlcindia.com or Central Public
Procurement Portal (CPPP) of Government of India, web site : www.eprocure.gov.in or
contact the Chief General Manager / Contracts, NLC India Ltd., Corporate Office,
Block-1, Neyveli - 607 801, Cuddalore District, Tamil Nadu, India. Phone: 04142-
252210, 251620, Fax: 04142-252026 / 252645/ 252646.
Page 5 of 328
(Web)
(Newspaper)
NLC INDIA LIMITED
(FORMERLY NEYVELI LIGNITE CORPORATION LIMITED)
OFFICE OF THE CHIEF GENERAL MANAGER / CONTRACTS
CORPORATE OFFICE, NEYVELI - 607 801
INTERNATIONAL COMPETITIVE BIDDING
Through e-tender and e-reverse auction
NOTICE INVITING BIDS
1.0 Online Bids in English are invited by NLC INDIA LIMITED, Neyveli for the
following:
1.1.3 The points for discussion during Pre-Bid Conference shall be furnished in advance, at
least two days before the scheduled date of pre-bid Conference, both in hard and soft
copy (editable copy) to the undersigned and also to the following E-mail ID:
gmconts_co@nlcindia.com, gmconts@gmail.com,gmconts_co@rediffmail.com.
Note:
i. For further details such as Qualifying Requirements, Scope of work, etc. and Tender
Document please visit our website: www.nlcindia.com or Central Public Procurement
Portal (CPPP) of Government of India, website : www.eprocure.gov.inor contact Chief
General Manager / Contracts, Corporate Office, NLC India Ltd., Block-1,
Neyveli - 607 801. Phone: 04142 - 252210, 251620, Fax 04142 – 252026 /
252645/ 252646. E-Mail ID: gmconts_co@nlcindia.com, gmconts@gmail.com,
gmconts_co@rediffmail.com.
.
6
Page 6 of 328
ii) Amendments /Errata /corrigendum/clarifications, if any issued for the tender
shall form part and parcel of the tender document. Amendments/Errata/
corrigendum/clarifications will be posted in NLCIL’s web site:
www.nlcindia.com and Central Public Procurement Portal (CPPP) of
Government of India, website: www.eprocure.gov.in. Bidders are requested to
visit NLCIL’s web site: www.nlcindia.com or Central Public Procurement
Portal (CPPP) of Government of India, website: www.eprocure.gov.inand note
the amendments before submission of offer. Any ignorance on the part of the
firms in not seeing the website will not be an excuse. NLCIL shall not be
responsible if any Bidder omits to notice any amendments/Errata / corrigendum
/ clarification. Amendments /Errata / corrigendum / clarification will be
numbered serially. The bidders are requested to sign all the Amendments /
Errata / Corrigendum / Clarifications issued for the tender and enclose along
with the bid as these form part and parcel of tender document.
2.0 QUALIFYING REQUIREMENTS
PRE-QUALIFICATION REQUIREMENTS (PQR) :
2.1(a) Bidder should have executed contracts of Design/Engineering, Supply,
Erection/Supervised erection, commissioning of Solar PV Power Plant(s) with
cumulative capacity of 10MWp or above as on the original scheduled date of tender
opening and out of which at least one Solar PV Power Plant shall be of minimum
5MWp capacity or above and should be in successful operation for at least one year
within the last 7 years as on the original scheduled date of tender opening.
AND
2.1(b) Bidder should have executed contracts of Design/Engineering, Supply,
Erection/Supervised erection, commissioning of Battery Energy storage system with
cumulative capacity of 1.0MWhr. or above as on the original scheduled date of tender
opening and out of which at least one Battery Energy Storage System shall be of
minimum 0.5MWhr. capacity or above and should be in successful operation for at
least one year within the last 7 years as on the original scheduled date of tender
opening.
2.2 Bidder who doesn’t fulfill the qualifying requirements stipulated in clause 2.1 (a) and
(b) above by himself can also participate provided the bidder collaborates with not more
than two firms and together they fully meet the qualifying requirements stipulated in
clause 2.1 (a) and (b) above and the Collaborator (s) should furnish along with the bid
valid collaboration agreement to execute this project and a back-up Bank Guarantee as
required in the relevant clauses.
OR
Bidder can also be a leader of a consortium consisting of not more than three firms,
such that together they meet the Qualifying Requirements stipulated in clause 2.1 (a)
7
Page 7 of 328
and (b) above and the members of the consortium should furnish back-up Bank
Guarantee as required in the relevant clauses. In case of bidding by a Consortium, the
consortium partners shall necessarily identify a leader of the Consortium who will
furnish the Consortium Agreement and the consortium partners shall execute a Joint
Deed of Undertaking in which the partners are jointly and severally liable to the Owner
for successful performance of the contract.
OR
Bidder can also be a Joint Venture Company, provided the qualifying requirement in
clause 2.1 (a) and (b) above is met by any one or more partners of the Joint Venture
(JV) Company. Each partner of the JV Company on the basis of whom the JV
Company gets qualified shall have minimum 26% equity in the JV Company and
should furnish back-up Bank Guarantee as required in the relevant clauses.
2.3 The Bidder or the Leader of the Consortium or the major partner of JV Company shall
have Positive Net Worth as per the latest audited financial statements.
2.4 Average Annual Turn Over of the Bidder, combined Average Annual Turn Over of the
Bidder and Collaborator(s), combined Average Annual Turn Over of the Consortium
partners and the combined Average Annual Turn Over of all the promoters of the Joint
Venture Company, as the case may be, shall not be less than Rs.48.648 Cr. in the
preceding three (3) consecutive financial years as on the original scheduled date of
tender opening.
3.0 Other Conditions:
3.1 The Bidder or the Bidder with Collaborator(s) or the Consortium or the Joint Venture
Company, as the case may be shall attach documentary evidence to prove that the
qualifying requirements mentioned in Clause 2.1 (a) and (b) above are met by him /
them, along with the bid in the form of end user certificate together with full contact
details for verification. The Bidder shall submit End User Certificate which is subject
to verification for qualification. The end user certificates showing the experiences of
their own installations or subsidiary or group companies or companies under the same
Management is also acceptable. A confirmation from the firm which is having the
experience in this regard is to be enclosed along with end user certificate.
In case the bidder furnishes the end user certificates of their subsidiary or group
companies or companies under the same Management, in addition to End User
Confirmation, NLC reserves the right to inspect such installations where such
certificates are obtained by the Bidder, only if the Bidder facilitates necessary
Page 8 of 328
inspection of such installation by the purchaser. However, cost pertaining to the
purchaser’s personnel for such inspection shall be borne by the purchaser.
3.2 In case of participation by the Bidder with Collaborator(s), the bidder shall furnish a
copy of valid Collaboration Agreement along with the bid, for the services offered
jointly and such agreement shall be valid till completion of all the contractual obligations
including O&M Contract. In case of participation by the Bidder as a Consortium, the
bidder shall furnish a copy of valid Consortium Agreement and Joint Deed of
Undertaking along with the bid, for the services offered jointly and such agreement shall
be valid till completion of all the contractual obligations including O&M Contract. In
case of participation by the Bidder as a Joint Venture Company, the bidder shall furnish a
copy of valid Joint Venture Agreement along with the bid, for the services offered jointly
and such agreement shall be valid till completion of all the contractual obligations
including O&M Contract. In all the above cases, the percentage value of the respective
portion of the work is to be indicated in the Techno commercial bid.
3.2(a) The successful bidder meeting the Qualifying Requirements, shall furnish a Contract
Performance Guarantee (CPG) in the form of an on-demand Bank Guarantee for the
faithful performance of the contract for a value of 10% of the total contract value
after the award of LOA.
3.2(b) If the successful bidder is meeting the Qualifying Requirements with
Collaborator(s), in addition to the CPG as mentioned in Cl. 3.2(a) above, each
Collaborator shall also furnish a back up Bank Guarantee for 5% of their respective
portion of the scope of work. In case the respective portion of the scope of work is
less than 1% of the total contract value, then back up Bank Guarantee for a minimum
of 0.05% of the total contract value shall be furnished.
3.2(c) If the successful bidder is the leader of a consortium, in addition to the CPG as
mentioned in Cl. 3.2(a) above, each of the consortium partners other than the leader
shall furnish a back up Bank Guarantee for 5% of their respective portion of the
scope of work. In case the respective portion of the scope of work is less than 1% of
the total contract value, then back up Bank Guarantee for a minimum of 0.05% of
the total contract value shall be furnished.
3.2(d) If the successful bidder is a JV Company meeting the Qualifying Requirement, in
addition to the CPG as mentioned in Cl. 4.5.3(a) above, each partner of the JV
Company on the basis of whom the JV company gets qualified shall also furnish a
back up Bank Guarantee for 5% of their respective portion of the scope of work. In
case the respective portion of the scope of work is less than 1% of the total contract
value, then back up Bank Guarantee for a minimum of 0.05% of the total contract
value shall be furnished.
Page 9 of 328
3.3 The bidder or the bidder with collaborator(s) or all individual firms in the
Consortium or all partners in the Joint Venture Company, as the case may be, shall
furnish their audited profit and loss accounts and balance sheets for the preceding
three (3) financial years from the original scheduled date of tender opening.
3.4 NLCIL reserves the right to ask the bidders to furnish the experience certificate
authenticated by the Indian Embassy in that country for installation outside India and
to furnish the experience certificate attested by a Notary Public for installation
within India.
3.5 NLCIL reserves the right to consider any foreign installations as experience, only if
the Bidder facilitates necessary inspection of such installation by NLCIL. However,
cost pertaining to the purchaser’s personnel for such inspection shall be borne by the
purchaser.
3.6 NLCIL reserves the right to inspect the plant(s) referred to by the bidders as well as
the original documents submitted in support of their claim to assess its veracity.
3.7 The bidder shall furnish major legal cases and their statutory liabilities if any.
iii. ‘L1’means the lowest tender or lowest bid or the lowest quotation received in a
tender, bidding process or other procurement solicitation as adjudged in the
evaluation process as per the tender.
iv. ‘Margin of purchase preference’ means the maximum extent to which the price
quoted by a local supplier may be above the L1 for the purpose of purchase
preference.
Minimum local content: The minimum local content shall be 50%.
Margin of Purchase Preference: The margin of purchase preference shall
be 20%.
10
Page 10 of 328
4.2 Verification of local content:
i. The local supplier at the time of tender, bidding or solicitation shall be required to
provide self-certification that the item offered meets the minimum local content and
shall give details of the location(s) at which the local value addition is made.
ii. The local supplier shall be required to provide a certificate from the statutory auditor or
cost auditor of the company (in the case of companies) or from a practicing cost
accountant or practicing chartered accountant (in respect of suppliers other than
companies) giving the percentage of local content.
iii. False declarations will be in breach of the Code of Integrity under Rule 175(1)(i)(h) of
the General Financial Rules-2017, Ministry of Finance, Govt. Of India for which a
bidder or its successors can be debarred for up to two years as per Rule 151 (iii) of the
General Financial Rules-2017, Ministry of Finance, Govt. Of India along with such
other actions as may be permissible under law.
iv. A supplier who has been debarred by any procuring entity for violation of this Order
shall not be eligible for preference under this Order for procurement by any other
procuring entity for the duration of the debarment. The debarment for such other
procuring entities shall take effect prospectively from the date on which it comes to the
notice of other procurement entities”.
The scope of work for installation of 2 x 10 MW (AC) Grid interactive Solar PV Power
Project integrated with 8 MWhr. Battery Energy Storage System at Attam Pahad and at
Dolly Gunj, Port Blair, South Andaman with associated 33 KV Switchyard and grid
interconnection at the take off points of Electricity Department of Andaman & Nicobar
Administration including Design, Engineering, Manufacture, Inspection at supplier’s
works, supply, insurance, transport, storage, erection, testing, commissioning.
The scope of work also includes Operation and Maintenance of the entire system for
ten years after one year warranty period.
11
Page 11 of 328
6.0 TIME SCHEDULE:
The scope of work, covered under this tender shall be performed as per the time
schedule given below, reckoning from the date of Letter of Award.
7.0 All other terms and conditions along with technical details regarding qualifying
requirements, time schedule, bid guarantee, validity of bids and instruction to bidders,
etc., are contained in the Tender Documents.
8.0 Bids submitted by Tele-fax or E-Mail and the off line bids received shall be rejected.
9.0 NLCIL reserves the right to reject any tender or all tenders received at its discretion
without assigning any reason whatsoever.
10.0 Collaborator / Consortium Partner/JV Partner/ of a Bidder for this tender cannot be a
Bidder for this Tender.
11.0 The Micro and small scale Units registered under single point registration scheme of the
NSIC/covered under MSMED Act,2006/MSME are permitted to participate without
Tender fee, provided that the request for the same is received in time with a copy of
valid certificate of registration and the product range mentioned in the certificate is the
same or similar to our requirements. Copies of necessary certificates duly attested by
any Notary public (or) Gazetted Officers (or) practicing Chartered Accountant with
seal and date shall only be accepted. They are also are exempted from furnishing Bid
Guarantee, provided that such Micro and Small Scale Units are registered under single
point registration scheme of NSIC/covered under MSMED Act, 2006/MSME and the
same is valid on the scheduled date of tender opening and the product range mentioned
in the certificate is the same or similar to our requirements.
12
Page 12 of 328
SECTION - B
QUALIFYING REQUIREMENTS
13
Page 13 of 328
SECTION - B
QUALIFYING REQUIREMENTS:
1.2(a) Bidder who doesn’t fulfill the qualifying requirements stipulated in clause 1.1 (a) and
(b) above by himself can also participate provided the bidder collaborates with not
more than two firms and together they fully meet the qualifying requirements stipulated
in clause 1.1 (a) and (b) above and the Collaborator (s) should furnish along with the
bid valid collaboration agreement to execute this project and a back-up Bank Guarantee
as required in the relevant clauses.
OR
Bidder can also be a leader of a consortium consisting of not more than three firms,
such that together they meet the Qualifying Requirements stipulated in clause 1.1 (a)
and (b) above and the members of the consortium should furnish back-up Bank
Guarantee as required in the relevant clauses. In case of bidding by a Consortium, the
consortium partners shall necessarily identify a leader of the Consortium who will
furnish the Consortium Agreement and the consortium partners shall execute a Joint
Deed of Undertaking in which the partners are jointly and severally liable to the Owner
for successful performance of the contract.
OR
Bidder can also be a Joint Venture Company, provided the qualifying requirement in
clause 1.1 (a) and (b) above is met by any one or more partners of the Joint Venture
(JV) Company. Each partner of the JV Company on the basis of whom the JV
Company gets qualified shall have minimum 26% equity in the JV Company and
should furnish back-up Bank Guarantee as required in the relevant clauses.
1.3 The Bidder or the Leader of the Consortium or the major partner of JV Company shall
have Positive Net Worth as per the latest audited financial statements.
1.4 Average Annual Turn Over of the Bidder, combined Average Annual Turn Over of the
Bidder and Collaborator(s), combined Average Annual Turn Over of the Consortium
partners and the combined Average Annual Turn Over of all the promoters of the Joint
Venture Company, as the case may be, shall not be less than Rs.48.648 Cr. in the
preceding three (3) consecutive financial years as on the original scheduled date of
tender opening.
14
Page 14 of 328
1.5 OTHER CONDITIONS:
1.5.1 The Bidder or the Bidder with Collaborator(s) or the Consortium or the Joint Venture
Company, as the case may be shall attach documentary evidence to prove that the
qualifying requirements mentioned in Clause 1.1 (a) and (b) above are met by him /
them, along with the bid in the form of end user certificate together with full contact
details for verification. The Bidder shall submit End User Certificate which is subject
to verification for qualification. The end user certificates showing the experiences of
their own installations or subsidiary or group companies or companies under the same
Management is also acceptable. A confirmation from the firm which is having the
experience in this regard is to be enclosed along with end user certificate.
In case the bidder furnishes the end user certificates of their subsidiary or group
companies or companies under the same Management, in addition to End User
Confirmation, NLC reserves the right to inspect such installations where such
certificates are obtained by the Bidder, only if the Bidder facilitates necessary
inspection of such installation by the purchaser. However, cost pertaining to the
purchaser’s personnel for such inspection shall be borne by the purchaser.
1.5.2 In case of participation by the Bidder with Collaborator(s), the bidder shall furnish a
copy of valid Collaboration Agreement along with the bid, for the services offered
jointly and such agreement shall be valid till completion of all the contractual
obligations including O&M Contract. In case of participation by the Bidder as a
Consortium, the bidder shall furnish a copy of valid Consortium Agreement and Joint
Deed of Undertaking along with the bid, for the services offered jointly and such
agreement shall be valid till completion of all the contractual obligations including
O&M Contract. In case of participation by the Bidder as a Joint Venture Company, the
bidder shall furnish a copy of valid Joint Venture Agreement along with the bid, for the
services offered jointly and such agreement shall be valid till completion of all the
contractual obligations including O&M Contract. In all the above cases, the percentage
value of the respective portion of the work is to be indicated in the Techno commercial
bid.
1.5.3(a)The successful bidder meeting the Qualifying Requirements, shall furnish a Contract
Performance Guarantee (CPG) in the form of an on-demand Bank Guarantee for the
faithful performance of the contract for a value of 10% of the total contract value after
the award of LOA.
1.5.3(b)If the successful bidder is meeting the Qualifying Requirements with Collaborator(s),
in addition to the CPG as mentioned in Cl. 1.5.3(a) above, each Collaborator shall also
furnish a back up Bank Guarantee for 5% of their respective portion of the scope of
work. In case the respective portion of the scope of work is less than 1% of the total
contract value, then back up Bank Guarantee for a minimum of 0.05% of the total
contract value shall be furnished.
1.5.3(c)If the successful bidder is the leader of a consortium, in addition to the CPG as
mentioned in Cl. 1.5.3(a) above, each of the consortium partners other than the leader
shall furnish a back up Bank Guarantee for 5% of their respective portion of the scope
of work. In case the respective portion of the scope of work is less than 1% of the total
contract value, then back up Bank Guarantee for a minimum of 0.05% of the total
contract value shall be furnished.
15
Page 15 of 328
1.5.3(d) If the successful bidder is a JV Company meeting the Qualifying Requirement, in
addition to the CPG as mentioned in Cl. 1.5.3(a) above, each partner of the JV
Company on the basis of whom the JV company gets qualified shall also furnish a back
up Bank Guarantee for 5% of their respective portion of the scope of work. In case the
respective portion of the scope of work is less than 1% of the total contract value, then
back up Bank Guarantee for a minimum of 0.05% of the total contract value shall be
furnished.
1.5.4 The bidder or the bidder with collaborator(s) or all individual firms in the Consortium
or all partners in the Joint Venture Company, as the case may be, shall furnish their
audited profit and loss accounts and balance sheets for the preceding three (3) financial
years from the original scheduled date of tender opening.
1.5.5 NLCIL reserves the right to ask the bidders to furnish the experience certificate
authenticated by the Indian Embassy in that country for installation outside India and to
furnish the experience certificate attested by a Notary Public for installation within
India.
1.5.6 NLCIL reserves the right to consider any foreign installations as experience, only if the
Bidder facilitates necessary inspection of such installation by NLCIL. However, cost
pertaining to the purchaser’s personnel for such inspection shall be borne by the
purchaser.
1.5.7 NLCIL reserves the right to inspect the plant(s) referred to by the bidders as well as the
original documents submitted in support of their claim to assess its veracity.
1.5.8 The bidder shall furnish major legal cases and their statutory liabilities if any.
16
Page 16 of 328
SECTION – C
17
Page 17 of 328
SECTION – C
A.Software Requirements
Refer to NLCIL’s portal (econts.nlcindia.com) for System Requirements
B. Digital Certificate
Bidder should have a legally valid CLASS III Digital Certificates (i) Digital
Signature, non-repudiation certificate (used for Signing) and (ii) Key
Encipherment Certificate (used for encrypting Bid Document) with
Organisation name from any of the licensed Certifying Authorities (CA)
operating under the Root Certifying Authority of India (RCAI), Controller of
Certifying Authorities (CCA) of India.
Ensure that all necessary trust certificates and drivers are installed as per CA’s
instruction and working properly.For detailed guidance about browser and Java
configuration the bidders are advised to go through the guide available in the
portal.
2.0 Registration:
The process involves Bidder registration with NLCIL website under e-contracts portal.
Only after successful registration, the Bidder(s) can submit his/their bids electronically.
Bidders are required to make their own arrangement for bidding from a computer
connected with Internet. NLCIL shall not be responsible for making such
arrangements.
Interested bidders are required to pay the Tender fee and register in the URL and click
on “New Bidder” and fill up the registration form with their details like Bidders
address, user ID and Password, Tender fee details etc., and attach a scanned copy of
Tender fee details with UTR No., Remitted Bank, Amount, Date etc., and submit.
Kindly note that Bidder name will be captured from Digital Signature Certificate
(DSC). Bidders are advised to keep note of the same. It may be noted that no separate
user id and password will be provided by NLCIL. However, the bidders who have
already participated in this portal can directly login with their valid user id and
password and fill up the registration form with details of Tender fee etc.Acceptance or
Rejection of Registration request for the Tender will be intimated by a separate e-mail
message.
After the Tender fee payment and successful registration, the bidder can login with
their user ID, password & DSC and participate in the e-Tender. Tender fee is non-
refundable.
18
Page 18 of 328
3.0 Payment of Tender Fee
The payment towards Tender fee is to be remitted in favour of NLC India Limited by
NEFT/RTGS or e-payment to NLCIL’s bank account as per following detail.
Bank Details : State Bank of India, Branch: Neyveli Main
Account Details :NLCIL Account No.10895129204,
Beneficiary Name : NLC India Limited. Estt.A/c in State Bank of India,
Branch: Neyveli Main
IFSC Code No. : SBIN0000958
Tender fee will be deemed to have been submitted by the bidder if and only if the same
is received (credited) in the above bank account within the stipulated time. Cash
payments will not be accepted.
4.0 Bidding Process:
The entire bidding process is divided into Two Stages i.e. Stage-I and Stage-II.
Stage-I bidding will be through e-Tender, in addition to submission of Physical forms
in sealed cover as brought out in clause 6.1.1 of Invitation to Bid and Stage-II bidding
will be through e-reverse auction.
Stage-I, e-Tender
Preparation of Bid
The Bidder will be able to prepare his Pre Qualifications Bid, TECHNICAL BID,
COMMERCIAL BID and Initial PRICE BID online using the respective forms. For
Guidelines please refer to the help in the Portal.
Bidder can edit and save his offer any number of times till closing time of the bid.
However, once he submits his bid he will not be able to edit it.
If bidder wants to edit his submitted bid then he has to first delete his submitted offer
and then edit his offer and resubmit. Only submitted bids will be considered for
evaluation. Any saved bids that are not submitted will be deleted by the system after the
due date of opening.
Bidder can attach files containing company profile details, scanned copies of dealership
certificate, scanned copies of technical drawings, etc., which are required for the
enquiry. The documents attached should be in PDF format.
File Size: 5MB is the maximum size of a single file that can be attached.
e-bid Submission and Signing
Submission of e-bids onlineis a two-step process. In the first step, the Techno
Commercial bid and Initial Price Bid have to filled and submitted. In the second step,
these bids have to be digitally signed using Bidder’s Digital Signature Certificate.
Bidder cannot submit any offer after the due date and time stipulated in the e-Tender.
All bids submitted by Bidder can be viewed by clicking on the link Submitted bids
provided in the left menu of the corresponding Bidder's home page.
All notices and correspondence to the bidder(s) shall be sent by email message during
the process till finalization of tender. Hence the bidders are required to ensure that their
email address provided at the time of registration is valid and updated. Non receipt of
email will not entitle any bidder to lodge any claim and no complaint in this regard
shall be entertained. Bidders are also requested to ensure validity of their DSC (Digital
Signature Certificate).
19
Page 19 of 328
Bidders are advised to see the web site regularly to remain updated with latest
information to ensure that they do not miss out any corrigendum / addendum uploaded
against the said e-tender after downloading the e-tender document. The responsibility
of downloading the related corrigendum, if any, will be that of the bidders.
5.0 Process of e-Tender:
5.1 On the scheduled date and time of tender opening, Tender Opening Committee will
open the Physical forms in sealed coverfirst and shall confirm details of payment
towards cost of Tender document (Tender fee), Bid Guarantee as in NIB, compliance of
Letter of Undertaking. The bids confirming to all the above is treated as Responsive
bids and Cover -II of the responsive bidders only will be opened.
5.2 Cover-II will be opened on the same day. For evaluation purpose, prices quoted in
Schedule of Prices alone shall be taken into consideration. Price Bids will be checked
by NLCIL for arithmetical accuracy. Errors, if any, will be resolved in the following
manner, and it shall not be necessary to make a reference to the concerned Bidder(s) for
such purpose:
(i) where there is a discrepancy between the unit rate and the line item total
resulting from multiplying the unit rate by the quantity, the unit rate as quoted
will govern.
(ii) where there is a discrepancy between figures and in words of an unit rate, the
unit rate as quoted in words will govern.
(iii) If there is any discrepancy between the amount quoted in words and figures, the
amount quoted in words will be considered.
5.3 If a bidder desires to be present at the time of Tender Opening, he shall depute his
representative(s) (not more than two persons) in time with due authorization for
participating in the Tender Opening
5.4 Stage-II : E-Reverse Auction :The Reverse Auction, if required, will be conducted
among the shortlisted bidders with a start price and decremented value. The Reverse
auction procedure is detailed under the heading “Reverse auction” (Annexure - B).
6.0 Bidding in e-Tender & Reverse auction:
a. In all cases, bidder should use their own ID and Password along with Digital
Signature at the time of submission of their bid.
b. The e-tender floor shall remain open from the pre-announced date & time and for as
much duration as mentioned above.
c. All electronic bids submitted during the e-tender and e-reverse auction process shall
be legally binding on the bidder. Any bid will be considered as the valid bid offered
by that bidder and acceptance of the same by the Purchaser will form a binding
contract between Purchaser and the Bidder for execution of work.
d. It is mandatory that all the bids are submitted with digital signature certificate
otherwise the same will not be accepted by the system.
e. NLCIL reserves the right to cancel or reject or accept or withdraw or extend this
bidding process (e-tender and e-reverse auction) in full or part as the case may be
without assigning any reason thereof.
20
Page 20 of 328
f. The server time shall be treated as final and binding. Bids recorded in the server
before the bid closing time will only be treated as valid bid. Bidders are, therefore,
advised to submit their bids well before the closing time of e-tender / e-reverse
auction. If any bid reaches the server after the bid closing time as per server time,
the same will not be recorded and no complaint in this regard shall be entertained.
g. Bidders are advised to exercise caution in quoting their bids in e-tender and
e-reverse auction to avoid any mistake. Bids once submitted can’t be recalled.
h. Any order resulting from this bidding process shall be governed by the terms and
conditions mentioned in the NIB.
21
Page 21 of 328
SECTION –D
INVITATION TO BID
22
Page 22 of 328
SECTION –D
INVITATION TO BID
1.0 INVITATION:
NLC India Limited, Neyveli a Navratna Government of India Enterprise registered
under Indian Companies Act 1956 hereinafter referred to as “PURCHASER” invites
Sealed bids in English (one original and six identical copies) for installation of 2 x 10
MW (AC) Grid interactive Solar PV Power Project integrated with 8 MWhr. Battery
Energy Storage System at Attam Pahad and at Dolly Gunj, Port Blair, South Andaman
with associated 33 KV Switchyard and grid interconnection at the take off points of
Electricity Department of Andaman & Nicobar Administration including Design,
Engineering, Manufacture, Inspection at supplier’s works, supply, insurance, transport,
storage, erection, testing, commissioning.
The scope of work also includes Operation and Maintenance of the entire system for
ten years after one year warranty period.
3.1 The scope of work for for installation of 2 x 10 MW (AC) Grid interactive Solar PV
Power Project integrated with 8 MWhr. Battery Energy Storage System at Attam Pahad
and at Dolly Gunj, Port Blair, South Andaman with associated 33 KV Switchyard and
grid interconnection at the take off points of Electricity Department of Andaman &
Nicobar Administration including Design, Engineering, Manufacture, Inspection at
supplier’s works, supply, insurance, transport, storage, erection, testing,
commissioning.
The scope of work also includes Operation and Maintenance of the entire system for
ten years after one year warranty period as detailed under Technical Specification (Vol.
II).
23
Page 23 of 328
4.0 BID GUARANTEE:
4.1 The amount shall be as specified in the Notice Inviting Bid and in the form of Demand
Draft or Banker’s cheque drawn in favour of NLC India Ltd., on any Bank in Neyveli or
payable at par by a Bank in Neyveli or NEFT/RTGS mode to NLCIL’s Account No.
10895129204, Beneficiary Name: NLC India Limited, Estt.A/c in State Bank of India,
Branch: Neyveli Main (IFS Code No. SBIN0000958) and the remittance details with
UTR No./DD/ Banker’s cheque shall be enclosed with the bid in Part I failing which the
offer is liable for rejection. The Bidder is to note that the Bank Commission charges
will be to the account of the bidder and the net amount transferred to NLCIL’s account
shall be equal to the amount specified in the Notice Inviting Bid.
4.2 The Bid Guarantee can also be in the form of an Irrevocable Bank Guarantee from any
Nationalised Bank / Scheduled Bank in India except Bank of China.
4.3 The Bid Guarantee shall be valid for 10 (ten) months from the date of tender opening
Part -I.
4.4 The Bid Guarantee deposited in any manner shall not bear any interest.
4.5 The Bid Guarantee furnished in the form of Demand draft / Banker’s Cheque / Bank
Guarantee, the scanned copy shall be uploaded and the original copy of the same shall
be furnished as brought out in the Clause 6.1.1.
4.6 The firms registered with NSIC/covered under MSMED Act,2006/MSME are
exempted from furnishing Bid Guarantee, provided that such Micro and Small Scale
Units are registered under single point registration scheme of NSIC/covered under
MSMED Act, 2006/MSME and the same is valid on the scheduled date of tender
opening and the product range mentioned in the certificate is the same or similar to our
requirements. Copies of necessary certificates duly attested by any Notary public (or)
Gazetted Officers (or) practicing Chartered Accountant with seal and date shall only be
accepted.
24
Page 24 of 328
6.0 BID SUBMISSION AND OPENING:
6.1.1 All bids, including all attachments / enclosures shall be prepared in English language
only and submit online in the NLCIL web site.
Bidders are requested to furnish the following documents in Original in a sealed cover
(Physical Forms) within the last date of receipt of Bids.
(i) Details of payment towards Tender fee
(ii) Bid Guarantee
(iii) Letter of undertaking
(iv) Check list for compliance of important Tender Conditions.
6.1.6 The bid guarantee shall also have provision for extension by the banker upon request by
the bidder. The bidder shall arrange for extension of validity upon request from NLC
India Ltd., Neyveli.
25
Page 25 of 328
Confirmation of BG under the through “Structured Financial Messaging System (SFMS)”
“The Bank Guarantee issued by the issuing Bank of Behalf of Bidder/ Contractor / Supplier in
favour of “Name of Company” shall be in paper form as well as issued under the “Structured
Financial Massaging System”. The details of beneficiary for issue of BG under SFMS
platform is furnished below:-
The above particulars are to be incorporated by the issuing bank properly while issuing
BG under SFMS mode to avoid any problem in future.
6.1.7 The Bid Guarantee shall be forfeited if:
a. the bid is unilaterally revoked /revised / modified / withdrawn before expiry of
bid validity period ,by the bidder(s); or
b. the price(s) have been unilaterally increased or altered after the bid opening and
during validity of offer, by the bidder; or
c. In case, any certificate submitted by the Bidder(s) is found to be not genuine, or
forged / bogus; or
d. on issue of LOA by NLCIL to the bidder, the bidder omits or refuses to accept
the said LOA within the stated period and /or execute the Contract agreement;
or
e. the successful bidder, after issue of LOA, omits or fails to submit Contract
Performance Guarantee within the specified period.
6.1.8 Without prejudice to any other remedies available at law,
i. in the event of any of the contingencies mentioned in Clause 6.1.7(a) to (c),
NLCIL shall have the right, at their discretion, to reject the bid without notice to
the Bidder(s);
ii. in the event of the contingency mentioned in Clause 6.1.7 (d) & (e),NLCIL shall
have the right to cancel the LOA/Contract, without notice to the Bidder
iii. in addition on (i) and (ii) above, NLCIL shall also have the right to de-bar the
defaulting Bidder(s) for a period to be specified, from participating in any of
NLCIL tenders and NLCIL reserves the right to inform the matter to other
PSUs/statutory Bodies and the decision of NLCIL in this regard shall be final
and binding on the Bidder(s).
26
Page 26 of 328
6.1.9 Return of Bid Guarantee
(i) For unsuccessful Bidders:
For unsuccessful bidders, bid guarantee /EMD shall be returned to such Bidders
within 15 days from the date of approval for placement of order on the
successful Bidder. If any bidder who does not agree to extend the validity of
the bid, bid guarantee shall be returned on request.
For successful bidder whose bid has been accepted and LOA is issued, the bid
guarantee / EMD shall be returned within fifteen days from the date of
acceptance of Bank Guarantee for Contract Performance.
(iii) In all the above transactions, the documents shall be sent by Registered post
/Speed Post.
6.1.10 All Bank Guarantees except Bid Guarantee are to be furnished directly by the Banker
to NLCIL either by Reg. Post/Speed Post/Courier.
6.1.11 The Online bid with regard to Technical and Commercial aspects shall contain the full
details of the profile of the bidder(s) in addition to the following:
(i) Duly filled in online forms.
(ii) Audited Annual reports for the last 3 years comprising of Audited Balance
Sheets and Profit and Loss Accounts, duly certified by the statutory auditors and
the documentary evidence with respect to Annual turnover.
(iii) Any amendment / corrigendum / errata for the Tender Document shall also be
signed by the Bidder as a token of acceptance of the same and enclosed in
Cover-II of the Bid.
6.1.12 If the Audited Annual Reports are not in English language, certified English translated
copies be attached duly signed by the Company Auditor.
6.1.13 To assist in the scrutiny, evaluation and comparison of bids, the Purchaser may, at its
discretion, seek from any or all bidders, clarification(s) of his / their Bids, including
break-downs of unit rates, technical information, documents and materials after the
Tender Opening. No change in the final price or substance of the Bid shall be
permissible.
6.2. PRICE
6.2.1 The ‘Schedule of Prices’ duly and correctly filled in by the bidder shall be submitted
online in the Specified Form.
27
Page 27 of 328
6.2.2 Price given should cover the entire scope of work and should be as per price format.
The bidder shall quote his price for entire scope of work on firm price basis only. The
bidder quoting a system of prices other than that specified, run the risk of summary
rejection of the bid.
6.2.3 The Bidder shall quote his price against each item of the schedule as indicated in the
price format. The bidder shall quote the prices only once after considering all the pros
and cons.
6.2.4 All entries shall be in English language only.
6.2.5 The price shall be quoted in Indian Rupees/ USD / Euro and shall remain valid till the
completion of entire work.
6.2.6 Price Bids will be checked by Purchaser for arithmetical accuracy. Errors, if any, will
be resolved in the following manner, and it shall not be necessary to make a reference
to the concerned Bidder(s) for such purpose:
i) where there is a discrepancy between the amounts in figures and in words, the
amount in words will govern; and
ii) where there is a discrepancy between the unit rate and the line item total resulting
from multiplying the unit rate by the quantity, the unit rate as quoted will govern.
iii) where there is a discrepancy between figures and in words of an unit rate, the unit
rate as quoted in words will govern.
7.0 GENERAL
7.1 In general, no request for postponement or extension of time shall be permitted for the
last date for remitting Tender fee, date of closing of online e-tender, Date of submission
of physical forms (Cover-I), Date of opening of physical forms (cover – I), Date of
opening of e-bids (Cover- II), etc. However, the Purchaser has the right to decide.
7.2 Bids received in incomplete shape shall be liable for rejection.
7.3. NLC India Limited takes no responsibility for transmission delays, loss or non-receipt
of bid documents or any letters sent by post / courier, either way, and also reserve the
right to reject any bid in part or full without assigning any reasons therefore.
7.4. Notwithstanding any information and data, which may be contained in these tender
documents, the bidder has to make independent inquiries and generally obtain his own
information on all matters that may in any way affect prices, risks and obligations of the
Contractor under the Contract.
7.5. The submission of any bid connected with these documents and specifications shall
constitute an agreement that the Bidder shall have no cause of action or claim against the
Purchaser for rejection of his Bid. The Purchaser shall always be at liberty to reject or
accept any bid or bids or part thereof at his sole discretion and any such action will not
be called into question and the bidder shall have no claim in that regard against the
Purchaser.
7.6. Bids once submitted shall not be returned and shall remain property of the Purchaser.
7.7 Unilateral revision or withdrawal of offer by the bidder within the subsistence of the
validity period of offer shall not be permitted. Violation of this condition shall result in
rejection of the bid without notice, besides forfeiture of EMD/ Bid Guarantee as the
case may be. In addition to the above, such bidder shall also be debarred either
28
Page 28 of 328
permanently or for a fixed period, at the discretion of NLCIL from participating in any
of the NLCIL’s future tenders.
9.1 Requests for clarifications received after the stipulated time as indicated in 10.2 shall
not be considered. The NLCIL shall endeavor to render / communicate their
clarifications in writing to the bidder without delay. After receipt of such clarifications,
the bidder may submit his bid but within the time and date as indicated in the tender.
All such clarifications and the relevant exchange of correspondence between the parties
in this regard shall form part of the tender specifications and contract documents.
29
Page 29 of 328
11.0 Single Bidder Responsibility
The bidder shall specifically indicate in his bid that he assumes full responsibility for
the scope of work in accordance with specifications, quality and time schedule of the
complete tender and guarantee the satisfactory performance as a whole.
12.0 No Claim for Compensation for Submission of Bid
12.1 The submission of any bid connected with these documents and specifications shall
constitute an agreement that the Bidder shall have no cause of action or claim against
the NLCIL for rejection or non-acceptance of his Bid. The Purchaser shall always be at
liberty to reject or accept any bid or bids or part thereof at his sole discretion and any
such action will not be called into question and the bidder shall have no claim in that
regard against the Purchaser.
12.2 The Bidder whose bid is not accepted shall not be entitled to make any claim on
account of costs, charges and expenses incidental to or incurred by such Bidder, as a
result of or in connection with his submission of bid or the consideration of the bid by
NLCIL, even if NLCIL elects to modify/withdraw/abandon the Invitation to Bid.
13.0 Policy of bids under consideration
Bids shall be deemed to be under consideration immediately after they are opened and
until such time the NLCIL makes official intimation of award/rejection to the Bidder.
While the Bids are under consideration, Bidders and/or their representatives or other
interested parties are advised to refrain from contacting, by any means, the NLCIL
and/or his employees/representatives on matters related to the Bid under consideration.
The NLCIL if necessary will obtain clarifications on the Bids, by requesting for such
information from any or all the Bidders either in writing or through official discussions.
The Bidder(s) will not be permitted to change the final price or substance of the Bid
after the same has been opened. Unilateral revision or withdrawal of bids by the bidder
within the subsistence of the validity period of offer shall not be permitted.
14.1 PURCHASER shall always be at liberty to reject or accept any bid or bids or part
thereof at his sole discretion and any such action will not be called into question and
the bidder shall have no claim in that regard against the PURCHASER.
14.2 The Purchaser does not pledge itself to accept the lowest bid, and reserves the right to
reject such bids for reasons to be recorded in writing. The other bids will be retained as
given. The decision of NLCIL in this regard shall be final and binding on the bidders
and the bidders shall not be entitled to any notice in this regard or to any compensation
whatever.
After opening of the bid, if NLCIL desires to have discussion, the bidder shall be in a
position to depute, at short notice, his representative(s) having full authority for
finalizing technical parameters as well as Commercial Terms and Conditions of the
Contract.
30
Page 30 of 328
16.0 Evaluation of Bids
16.1 The following procedures would be followed for evaluation of bids.
16.2 On the scheduled date and time of tender opening, Tender opening committee will
open the Cover -I first and shall confirm, details of payment towards cost of Tender
document(Tender fee), EMD/Bid Guarantee as in NIB, compliance of Letter of
undertaking. The bids confirming to all the above is treated as Responsive bids and
online Cover-II of the responsive bidders will be opened on the same day.
16.2.1 In the Schedule of Prices, the Bidders shall quote against each activity.
16.3 For conversion of FC to INR, the B.C selling rate prevailing on the date of opening of
price bid shall be adopted.
The following procedure will be adopted regarding the loading:
i) For FOB supplies, payments made through Letter of credit, interest loading for the
60% payment for equipment shall be done for evaluation purpose at prime lending
rate of SBI together with statutory levies if any as on the date of price bid opening
for the duration of 3 months in case of imports from Asia, Africa, Europe,
Australia and 4 months in case of America. However if the bidder wants to take
FOB payment on receipt of materials at Indian Port, this loading will not be made
and the bidder shall indicate it specifically in their bid.
ii) For FOB supplies L.C opening charges and usance charges incurred in India will
be loaded.
The bids will be evaluated based on the total evaluated site cost per MW plus O&M
charges per MW for Ten years i.e., evaluated price. The bidders will be ranked
starting from the lowest evaluated price in the ascending order after bringing them to
the same platform.
iv. The summary price table i.e Schedule-1 to 7 submitted online will be considered
for evaluation. Any discrepancies arises between online price submitted and price
mentioned in the scan copy uploaded, the online price will be considered.
16.4 From the above ranking, the bidder whose bid becomes H1 with the highest evaluated
price shall be eliminated, subject to ensuring minimum four(4) bidders participation
in the reverse auction i.e., H1 will be eliminated if five (5) or more bidders participated
in the tender.
In case, participation is less than or equal to four(4), all the bidders will be qualified
for the reverse auction.
In case more than one bidder turn out to be H1 bidders (with the same evaluated
price), all H1 bidders will be eliminated subject to ensuring four (4) bidders
participation in the reverse auction. Due to such elimination of H1 bidders, if the
available eligible bidders get reduced to less than four (4), all will be included
without elimination.
All the short listed bidders for Reverse Auction will be intimated about their eligibility
for participation in Reverse Auction. Thereafter Reverse auction will be conducted.
31
Page 31 of 328
16.4.1 Terms and conditions of Reverse Bidding/Auction is enclosed as Annexure-D. The
date and time of Reverse Bidding/Auction will be intimated. At the end of Reverse
Auction, the price ranking status of bidders will be ranked as RL1, RL2, RL3…,
starting from the lowest offered price in the ascending order.
16.4.1.1 If RL1 is not from a local supplier, the lowest bidder among the local suppliers will be
invited to match the RL1 price subject to local supplier’s quoted price falling within
the margin of purchase preference and the contract shall be awarded to such local
supplier subject to matching the RL1 price.
In case such lowest eligible local supplier fails to match the RL1 price, the local
supplier with the next higher bid within the margin of purchase preference shall be
invited to match the RL1 price and so on and contract shall be awarded accordingly.
In case none of the local suppliers within the margin of purchase preference matches
the RL1 price, then the contract may be awarded to the RL1 bidder.
After completing the reverse auction, the lowest offered bidder (RL1) will be
evaluated for QR& Techno-commercial conditions.
If the lowest offered bidder (RL1) satisfies all QR / Techno-commercial conditions,
the bidder will be considered for placement of order.
If the lowest offered bidder (RL1) fails to qualify on QR / Techno-commercial
conditions, the next ranked bidder (RL2) will be evaluated for QR& Techno-
commercial conditions.
If the bidder RL2 satisfies all QR / Techno-commercial conditions, this bidder will be
considered for placement of order .This awarded price will be taken as the lowest
offered price.
This process will be repeated in the order of ranking till the eligible bidders are
exhausted.
16.4.2 The order value for the successful bidder shall be calculated as follows:
The closing price (CP) in the Reverse Auction is the lowest offered evaluated price per
MW of the successful bidder in the Reverse Auction.
The ratio (R), between this closing price and the originally evaluated price per MW of
the successful bidder (EP) will be calculated as R= CP/EP.
The order value for the successful bidder will be calculated in the above ratio(R) of the
quoted price of the successful bidder as below:
32
Page 32 of 328
(i) In case, the RL1bidder fails to submit requisite documents as per NIT or if any of the
information / declaration furnished by RL1 bidder is found to be wrong during
evaluation of documents submitted by the bidder, which changes the eligibility status
of the bidder (for the first time) consider as defaulted, then his bid shall be rejected
and EMD or Rs. 1 Lakh, whichever is lower of RL1bidder will be forfeited.
(ii) If the RL1 firm is disqualified in a subsequent tender, then the bids shall be rejected
and entire EMD amount will be forfeited.
16.4.4 If the bidder fails remit the amount as stipulated above in clause 16.4.3 (i) & (ii) they
will be either debarred or banned for a specific period as deemed fit.
17.0 Local Conditions
i) Minimum wages for Contract labour shall be paid as applicable in that region from
time to time. Claims and objections due to ignorance of site conditions will not be
considered after submission of Bid.
ii) The Bidder is required to carefully examine the Technical & General Specification,
Terms and Conditions, Commercial and Erection conditions of Contract, drawings
and other details relating to work given in the Tender Document and fully acquaint
himself as to all conditions and matters which may in any way affect the work or
the cost thereof. The Bidder shall be deemed to have on his own and independently
obtained all necessary information for the purpose of preparing the Bid and his bid
as accepted shall be deemed to have taken into account all contingencies as may
arise due to such information or lack of the same.
iii) The Bidder shall be deemed to have exhaustively examined the Tender documents,
to have obtained all information and clarifications on all matters whatsoever that
might affect the carrying out of the work and to have satisfied himself as to the
adequacy of his Bid. He is deemed to have known the scope, nature and magnitude
of the work and the requirements of materials and labour involved etc. and as to all
work he has to complete in accordance with the Contract whatever be the defects,
omissions or errors that may be found in the Tender/Bid Documents.
iv) The Bidder shall be deemed to have acquainted himself with the Indian Income Tax
Act, 1961, Indian Companies Act, 1956, Indian Customs Act, 1962, Indian
Electrical Act, Factories Act, Pollution Control Regulation and other related Acts &
Laws prevalent in India and as amended from time to time. The Purchaser shall not
entertain any request for clarifications from the Bidders regarding such local
conditions.
v) Any neglect or omission or failure on the part of the Bidder in obtaining necessary
and reliable information as stated above or on any other matter affecting the Bidder
shall not relieve him from any risks or liabilities or the entire responsibility for
completion of the work in accordance with the Tender Documents.
18.1 The Bid must contain the name, residence and place of business of the person or
persons making the Bid must be signed and sealed by the Bidder with his full signature.
The name of the person/persons signing should be typed or printed below the signature
and each page of the bid shall be properly authenticated by appending
signatures/initials and seals, if any.
33
Page 33 of 328
18.2 Bid by a Corporation/Company must be signed with the legal corporate name of the
Corporation/Company by the President, Managing Director or by the Secretary or any
other person or persons authorised to submit bid on behalf of such Corporation/
Company and shall contain the Official seal of the Company.
18.3 A Bid by a person who affixes to his signature the word ‘President’, ‘Managing
Director’, ‘Secretary’, ‘Agent’, or other designation without disclosing his Principal
will be rejected. Satisfactory proof of authority of the person signing on behalf of the
Bidder shall be furnished with the Bid.
18.4 The Bid/offer shall be submitted only in the real/registered/trading name of the Bidder
and anonymous/pseudonymous shall be rejected.
18.5 Any corrections or other changes in the bid documents shall be duly authenticated by
appending signatures/initials and seals, if any, of the person signing the Bid.
18.5.1 Bids not conforming to the above requirements will be disqualified.
19.0 Award of Criteria
[
19.1 The Purchaser will award the contract to the bidder who meets the Qualifying
Requirements, determined as substantially responsive and lowest evaluated price.
19.2 The Purchaser reserves the right to accept or reject any bid and to annul the bidding
process and reject all the bids at any time prior to Award of Contract, without thereby
incurring any liability to the affected Bidder/Bidders and not obliged to inform the
grounds of such action.
19.3 The Purchaser will be the sole Judge in this regard.
20.0 Integrity Pact Programme:
NLCIL is committed to have most ethical business dealing with the Vendors, Bidders
and Contractors of goods and services and deal with them in a transparent manner with
equity and fairness.
In order to achieve these goals, NLCIL is implementing the Integrity Pact Programme
in co-operation with Central Vigilance Commission (CVC) and renowned International
Non-Governmental Organisation, Transparency International India (TII).
The Integrity Pact Programme covers the following aspects:
34
Page 34 of 328
As on date, the Independent External Monitors are:
Sl. Name and Address Phone No. and e-mail
No.
1 Shri. M.N. Krishnamurthy, I.P.S(Retd.) Ph.No.080 – 25427282 ((R )
Former DGP of Kerala, Mobile No. 9591110000
3C-910, HRBR Layout, Email:krishnamurthymn19@gmail.com
Kalyan Nagar, Bangalore- 560 043.
2 Shri Najib Shah, Ph.No.080 – 49518850
Ex.Chairman, Mobile No. 9311706358
Central Board of Excise and Customs, Email: najibshah@hotmail.com
32, Prestige Mayberry, Nagondanahalli
Main Road, Whitefield Main Road,
Bangalore – 560 066.
3 Shri S.Srinivasan, IAS (Retd.), Ph No. 080 – 22930107 (Res)
Former Secretary of GOI & Member Mobile 9483536100
(Finance), Dept. of Space / Atomic Email: s.srinivasan1980@gamil.com
Energy/ Earth Sciences,
Flat No. D-5-107, Block No.5,
V Floor KendriyaVihar, B B Road
(Bangalore – Bellary Road) Yelahanka,
Bangalore – 560 064.
35
Page 35 of 328
Section -E
SPECIMEN FORMATS
36
Page 36 of 328
SCHEDULE OF PRICES
GENERAL INSTRUCTIONS TO BIDDERS
ANNEXURE-A
1.0 The Bidder shall furnish their prices only in the online form ‘schedule of prices’.
1.0 PREAMBLE
1.1 This section covers the price schedule to be filled up by the BIDDER for the entire
scope of work.
1.2 After Reverse Auction, the BIDDER shall furnish price-breakup as per the format in
respective currency as per the ratio indicated in Section D, Cl.16.4.2.
1.3 The BIDDER shall carefully scrutinise the specification and drawings and include price
for all items of work in the price schedule. This is a turn key lump sum contract and
over and above the prices quoted, no extra claim will be admissible. All piping, cabling,
earthing, roads and pathways, with in the terminal points are deemed to have been
included within the quoted price.
i) The BIDDER shall note that the list of items indicated in the price schedule are
not necessarily exhaustive and the price quoted shall be inclusive of all
necessary equipment, accessories, gauges, instruments, etc., labour, duly
supplied, constructed, installed, tested, commissioned and handed over to the
Purchaser in perfect working conditions.
ii) It is incumbent on the successful BIDDER to arrange for and obtain necessary/
approval from the concerned appropriate authority for the complete installation
included in the scope of supply, construction, installation and commissioning.
The installation will be deemed to have been completed only when all such
approval is obtained and handed over to NLCIL.
iii) The prices for supply items shall be quoted as delivered at site including
packing & forwarding, loading and freight up to door delivery at site. The
services provided at site shall be on turnkey basis. All prevailing applicable
taxes and duties shall be indicated separately along with the quoted price.
iv) The prices shall be firm throughout the contract period in force.
v) While quoting for taxes and duties, the bidders shall consider all prevailing laws
and concession available and quote accordingly. Where any concessional taxes
have been considered the same shall be considered in the bid. The rate of taxes
and duties adopted shall be indicated in Schedule -8 of prices.
vi) The price quoted in the schedule of price for 10 years operation and
maintenance for Solar PV Power Plant (Schedule 6) and the schedule of price
for operation and maintenance for BESS (Schedule 7) added together shall not
be less than 15% of the total quoted price.
If the schedule of price for 10 years operation and maintenance for Solar PV Power
Plant (Schedule 6) and the schedule of price for operation and maintenance for BESS
(Schedule 7) added together is less than 15% of the total quoted price, the offer will be
summarily rejected.
37
Page 37 of 328
SUMMARY OF PRICE TABLE
Note: This format of price tables are given for guidance and understanding to quote the
price. Bidders are requested to quote the price in the online price schedule form only.
PART - A : SUPPLY AND SERVIES
Sl.No. Description Item Total Price
(In Rupees/ FC)
1 SCHEDULE-1 Schedule of prices for Site
Preparation
2 SCHEDULE-2 Schedule of prices for Plant and
Equipment (Solar PV Plant and
33KV Switchyard)
SCHEDULE-3 Schedule of prices for Plant and
Equipment (BESS)
3 SCHEDULE-4 Schedule of prices for
Installation &commissioning
4 SCHEDULE-5 Schedule of prices for Civil and
structural works
SUB-TOTAL(A)
GRAND TOTAL(Part-A+Part-B)
Signature:
Name:
Designation:
Company:
Date:
38
Page 38 of 328
Scan copy to be uploaded online
SCHEDULE OF PRICES-SITE PREPARATION - SCHEDULE-1
Signature:
Name:
Designation:
Company:
Date:
39
Page 39 of 328
Scan copy to be uploaded online
SCHEDULE OF PRICES FOR PLANT AND EQUIPMENT (Solar)
SCHEDULE-2
Signature:
Name:
Designation:
Company:
Date:
40
Page 40 of 328
Scan copy to be uploaded online
SCHEDULE-3
Signature:
Name:
Designation:
Company:
Date:
41
Page 41 of 328
Scan copy to be uploaded online
Signature:
Name:
Designation:
Company:
Date:
42
Page 42 of 328
Scan copy to be uploaded online
SCHEDULE- 5
1.2 Total price for civil works (sum of items 1.0 + 1.1)
Signature:
Name:
Designation:
Company:
Date:
43
Page 43 of 328
Scan copy to be uploaded online
SCHEDULE OF PRICES FOR OPERATION AND MAINTENANCE,FOR 10 YEARS
AFTER ONE YEAR WARRANTY PERIOD FOR SOLAR POWER PLANT
SCHEDULE-6
Signature:
Name:
Designation:
Company:
Date:
44
Page 44 of 328
Scan copy to be uploaded online
SCHEDULE OF PRICES FOR OPERATION AND MAINTENANCE,
FOR 10 YEARS AFTER ONE YEAR WARRANTY PERIOD FOR BATTERY
ENERGY STORAGE SYSTEM (BESS)
SCHEDULE-7
Signature:
Name:
Designation:
Company:
Date:
45
Page 45 of 328
Scan copy to be uploaded online
SCHEDULE-8
The bidder shall give below the details of the prevailing rates and classification of component
in accordance with the CD/GST. The details of any other taxes and duties applicable shall be
furnished.
A)GST
-----------------------------------------------------------------------------------------------------------------
Sl.No. Materials GST Classification Rate of GST
adopted
-----------------------------------------------------------------------------------------------------------------
----------------------------------------------------------------------------------------------------------------
B) CUSTOMS DUTY
-----------------------------------------------------------------------------------------------------------------
Sl.No. Materials Classification Rate of CD
Adopted
Signature:
Name:
Designation:
Company:
Date:
46
Page 46 of 328
Annexure – B
REVERSE AUCTION
2. Schedule for Reverse Bidding: After Price e-Bids are opened online, date and time of
start of Reverse Auction shall be intimated to all the eligible bidders. Scheduled
duration of Reverse Auction shall be normally one hour.
3. Auction extension time: If a valid bid is placed within Ten (10) minutes of End Time
of the Reverse auction (RA), then RA duration shall get automatically extended for
another Ten (10) minutes from the existing end time. It may be noted that the auto-
extension will take place only if a valid bid comes in those last Ten (10) minutes. If a
bid does not get accepted as the lowest bid, the auto-extension will not take place even
if that bid might have come in the last Ten (10) minutes. The above process will
continue till no bid is received in last Ten (10) minutes which shall mark the
completion of Reverse Auction. However, bidders are advised not to wait till the last
moment to enter their bid to avoid complications related to internet connectivity, their
network problems, system crash down, power failure etc.
(b)The ratio (R), between this closing price and the originally evaluated price per
MW of the successful bidder (EP) will be calculated as R= CP/EP.
47
Page 47 of 328
(c) T heorder value for the successful bidder will be calculated in the above
ratio(R) of the quoted price of the successful bidder as below:
Order value =
R * Grand Total
(PART-A +PART-B)
Correspondingly the individual price schedules will be arrived based on the above
ratio (R).
5. System Requirement
48
Page 48 of 328
Annexure - C
LETTER OF UNDERTAKING
From:
(Name & Address of Bidder)
……………………………
……………………………….
……………………………….
1. With reference to the aforesaid tender for (Name of Work to be filled up) I/we,
____________________ Ltd., (the Company) having our Registered Office at
______________________________________________ hereby give the following
declarations and undertaking.
2. I/We have read and understood all the terms and conditions of the tender and hereby agree
and undertake to confirm all the technical and commercial conditions of this tender without
any deviation.
3. I/We also confirm and certify that all the relevant documents have been submitted in
conformity to the Qualifying Requirements specified in the tender.
4. I/We hereby agree and undertake that NLC India Limited shall have the right to reject the
offer and take penal action against us, if any deviation is noticed during evaluation of the
tender in contradictory to this letter of undertaking.
5. The information and documents provided by us are correct and authentic to the best of our
knowledge.
6. I/We attached duly filled in Check list for Compliance of Important Tender Conditions.
Authorized Signatory
(Name & Designation)
Encl.:- Check List.
Place:
Date :
Company Seal
49
Page 49 of 328
Annexure - D
Check list for Compliance of Important Tender Conditions
(to be attached with the Letter of Undertaking)
Bidders to submit their bid accepting all the terms and conditions of the Tender and the
required / relevant documents wherever required, as per the formats given below:
PQR QUESTIONNAIRE:
Signature of Bidder.
50
Page 50 of 328
ANNEXURE - E
1. This guarantee should be furnished by a Nationalized Bank / Scheduled Bank (other than
Bank of China) authorized by Reserve Bank of India in the format as given below.
2. This bank guarantee should be furnished on stamp paper of value not less than Rs.80/- as
per Stamp Act.
3. The stamp paper should have been purchased in the Name of the Bank executing the
guarantee.
Dear Sirs,
In accordance with your ‘ Invitation to Bid’ under your Tender No.:…………………. dated
…………… M/s. ………………………….. hereinafter called the Bidder, having its
Registered Office/ Head Office at ………………………. with the following Directors on their
Board of Directors / partners of the firm.
1 …………………………… 2 ……………………………
3 …………………………… 4 ……………………………
5 …………………………… 6 ……………………………
7 …………………………… 8 ……………………………
9 …………………………… 10 ……………………………
51
Page 51 of 328
a the bid has been unilaterally revoked / revised / modified / withdrawn
before expiry of bid validity period, by the Bidder(s) ; or
b. The price(s) have been unilaterally increased or altered after the bid
opening and during validity of the offer, by the Bidder; or
c. On issue of LOA by NLC to the bidder, the bidder has omitted or refused
to accept the said LOA within the stated period and/ or execute the
Contract agreement; or
the amount of …*…………..to the said NLC India Limited without any reservation, protest,
demur and recourse. Any such demand by the NLC India Limited shall be conclusive and
binding on the bank irrespective of any dispute or difference raised by the Bidder.
The guarantee shall be irrevocable and shall remain valid upto …@………………… If any
further extension of this guarantee is required the same shall be extended on receiving
instruction from M/s. ………………………….. on whose behalf this guarantee is issued.
In witness where of the Bank, through its authorized Officer has set its hand and stamp on
this………..day of ………….at………………..
52
Page 52 of 328
(To be executed on plain paper and applicable for all tenders of value above Rs 1 crore)
INTEGRITY PACT:
Between
NLC India Limited (NLCIL) hereinafter referred to as "The Principal”
and
............................................. hereinafter referred to as ''The Bidder/ Contractor"
Preamble:
The Principal intends to award, under laid down organizational procedures, contract/s for
………………………… The Principal values full compliance with all relevant laws and
regulations, and the principles of economic use of resources, and of fairness and transparency
in its relations with its Bidder/s and Contractor/s.
In order to achieve these goals, the Principal cooperates with the renowned international Non-
Governmental Organization ''Transparency International" (TI). Following TI's national and
international experience, the Principal will appoint an external independent Monitor who will
monitor the tender process and the execution of the contract for compliance with the principles
mentioned above.
Definitions:
In pursuance of the above Pact, for the purposes of this provision, the Principal defines the
relevant terms set forth therein as under:
1) “Contract” means the contract entered into between the Principal and Bidder (or
Bidder) / Contractor for the execution of work mentioned in the preamble above.
2) “Contractor” means the bidder or Bidder whose tender (bid) has been accepted by the
principal or Company whose tender (bid) has been accepted and shall be deemed to
include his/its/their successors, representatives, heirs, executors and administrators
unless excluded by the Contract.
3) “Coercive practice” means harming or threatening to harm, directly or indirectly,
persons or their property to influence their participation in the procurement process or
affect the execution of a contract: In order to achieve these goals, the Principal
proposes to appoint one or more External Independent Monitor/s who will monitor the
tender process and the execution of the contract for compliance with the principles
mentioned above.
4) “Collusive practice” means a scheme or arrangement between two or more bidders, with
or without the knowledge of the Principal designed to establish bid prices at artificial,
noncompetitive levels; and
5) “Corrupt practice” means the offering, giving, receiving or soliciting of anything of
value to influence the action of a public official in the procurement process or in
contract execution;
6) “External Independent Monitor” means a person, hereinafter referred to as EIM,
appointed, in accordance with Section 7 below, to verify compliance with this
agreement.
7) “Fraudulent practice” means a misrepresentation of facts in order to influence a
procurement process or the execution of a contract to the detriment of the Principal and
includes collusive practices among Bidders (Prior to or after bid submission) designed
to establish bid prices at artificial, non competitive levels and to deprive the Principal of
the benefits of free and open competition;
8) “Party” means a signatory to this agreement.
53
Page 53 of 328
9) “Purchaser” means NLC India Limited, Neyveli, incorporated under the Companies
Act 1956, having their registered Office at Chennai, 600 010 and includes their
successors.
10) “Bidder or Bidders” means the person, firm or company submitting a tender (bid)
against the invitation to Tender (bid) and includes his/its/their staff, consultants, parent
and associate and subsidiary companies, agents, consortium and joint venture partners,
sub-contractors and suppliers, heirs, executors, administrators, representatives,
successors.
(1) The Principal commits itself to take all measures necessary to prevent corruption and to
observe the following principles:
1 No employee of the Principal, personally or through family members, will in
connection with the tender for, or the execution of a contract, demand, take a promise
for or accept, for him/herself or third person, any material or immaterial benefit which
he/she is not legally entitled to.
2. The Principal will, during the tender process treat all Bidders with equity and reason.
The Principal will in particular, before and during the tender process, provide to all
Bidders the same information and will not provide to any Bidder confidential/additional
information through which the Bidder could obtain an advantage in relation to the
tender process or the contract execution.
3. The Principal will exclude from the process all known prejudiced persons.
(2) If the Principal obtains information on the conduct of any of its employees which is a
criminal offence under the relevant Anti-Corruption Laws of India, or if there be a
substantive suspicion in this regard, the Principal will inform its Vigilance Office and
in addition can initiate disciplinary actions.
(1) The Bidder / Contractor commits itself to take all measures necessary to prevent
corruption. He commits himself to observe the following principles during his
participation in the tender process and during the contract execution.
1. The Bidder / Contractor will not, directly or through any other person or firm, offer,
promise or give to any of the Principal's employees involved in the tender process or
the execution of the contract or to any third person any material or immaterial benefit
which he/she is not legally entitled to, in order to obtain in exchange any advantage of
any kind whatsoever during the tender process or during the execution of the contract.
2. The Bidder / Contractor will not enter with other Bidders into any undisclosed
agreement or understanding, whether formal or informal. This applies in particular to
prices, specifications, certifications, subsidiary contracts, submission or non-submission
of bids or any other actions to restrict competitiveness or to form cartels in the bidding
process.
3. The Bidder /Contractor will not commit any offence under the relevant Anticorruption
Laws of India: further the Bidder /Contractor will not use improperly, for purposes of
competition or personal gain, or pass on to others, any information or document
provided by the Principal as part of the business relationship, regarding plans, technical
proposals and business details, including information contained or transmitted
electronically.
54
Page 54 of 328
4. The Bidder / Contractor will, when presenting his bid, disclose any and all payments he
has made, is committed to or intends to make to agents, brokers or any other
intermediaries in connection with the award of the contract.
5. The Bidder / Contractor of foreign origin shall disclose the name and address of the
Agents / representatives in India, if any. Similarly the Bidder / Contractor of Indian
Nationality shall furnish the name and address of the foreign principals, if any.
(2) The Bidder / Contractor will not instigate third persons to commit offences outlined
above or be an accessory to such offences.
If the Bidder, before contract award has committed a transgression through a violation
of Section 2 or in any other form such as to put his reliability or credibility as Bidder
into question, the Principal is entitled to disqualify the Bidder from the tender process
or to terminate the contract, if already signed, for such reason.
(1). If the Bidder / Contractor has committed a transgression through a violation of Section
2 such as to put his reliability or credibility into question, the Principal is entitled also
to exclude the Bidder /Contractor from future contract award processes. The imposition
and duration of the exclusion will be determined by the severity of the transgression.
The severity will be determined by the circumstances of the case, in particular the
number of transgressions, the position of the transgressors within the company
hierarchy of the Bidder and the amount of the damage. The exclusion will be imposed
for a minimum of 6 months and maximum of 3 years.
(2) A transgression is considered to have occurred if the Principal after due consideration
of the available evidence, concludes that no reasonable doubt is possible.
(3) The Bidder accepts and undertakes to respect and uphold the Principal's absolute right
to resort to and impose such exclusion and further accepts and undertakes not to
challenge or question such exclusion on any ground, including the lack of any hearing
before the decision to resort to such exclusion is taken. This undertaking is given freely
and after obtaining independent legal advice.
(4) If the Bidder / Contractor can prove that he has restored / recouped the damage caused
by him and has installed a suitable corruption prevention system, the Principal may
revoke the exclusion prematurely, provided such systems has been audited by an
independent agency.
(1) If the Principal has disqualified the Bidder from the tender process prior to the award
according to Section 3, the Principal is entitled to demand and recover from the Bidder
liquidated damages equivalent to Earnest Money Deposit / Bid Security.
(2) If the Principal has terminated the contract according to Section 3 or if the Principal is
entitled to terminate the contract according to Section 3, the Principal shall be entitled
to demand and recover from the Contractor liquidated damages equivalent to Security
Deposit /Performance Bank Guarantee.
55
Page 55 of 328
Section 5 - Previous transgression
(1) The Bidder declares that no previous transgressions occurred in the last 3 years with
any other Company in any country conforming to the TI approach or with any other
Public Sector Enterprise in India that could justify his exclusion from the tender
process.
(2) If the Bidder makes incorrect statement on this subject he can be disqualified from the
tender process or the contract, if already awarded, can be terminated for such reason.
Section 6 - Equal treatment of all Bidders / Contractors/ Subcontractors
(1) The Bidder / Contractor undertakes to demand from all subcontractors a commitment in
conformity with this Integrity Pact, and to submit it to the Principal before contract
signing.
(2) The Principal will enter into agreements with identical conditions as this one with all
Bidders, Contractors and Subcontractors.
(3) The Principal will disqualify from the tender process all bidders who do not sign this
Pact or violate its provisions.
Page 56 of 328
(6) The Monitor will submit a written report to the Chairperson of the Board of the
Principal within 8 to 10 weeks from the date of reference or intimation to him by the
'Principal' and, should the occasion arise, submit proposals for correcting problematic
situations.
(7) Monitor shall be entitled to compensation on the same terms as being extended to /
provided to Outside Expert Committee members / Chairman as prevailing with
Principal.
(8) If the Monitor has reported to the Chairperson of the Board a substantiated suspicion of
an offence under relevant Anti-Corruption Laws of India, and the Chairperson has not,
within reasonable time, taken visible action to proceed against such offence or reported
it to the Vigilance Office, the Monitor may also transmit this information directly to the
Central Vigilance Commissioner, Government of India.
(9) The word 'Monitor' would include both singular and plural.
10) The Monitor can be removed from his office, before the expiry of his tenure only with
the approval of the Board of the Principal.
This Pact begins when both parties have legally signed it. It expires for the Contractor
12 months after the last payment under the respective contract, and for all other Bidders
6 months after the contract has been awarded.
If any claim is made / lodged during this time, the same shall be binding and continue
to be valid despite the lapse of this pact as specified above, unless it is discharged /
determined by Chairperson of the Principal.
(1) This agreement is subject to Indian Law. Place of performance and jurisdiction is the
Registered Office of the Principal, i.e. Chennai / Neyveli. The Arbitration clause
provided in the main tender document / contract shall not be applicable for any issue /
dispute arising under Integrity Pact.
(2) Changes and supplements as well as termination notices need to be made in writing.
(3) If the Contractor is a partnership or a consortium this agreement must be signed by all
partners or consortium members.
(4) Should one or several provisions of this agreement turn out to be invalid, the remainder
of this agreement remains valid. In this case, the parties will strive to come to an
agreement to their original intentions.
………………………………… …………………………….
For the Principal for the Bidder /Contractor
Place …………. Witness1 ……………………
Date ………….. Witness 2 …………
57
Page 57 of 328
ANNEXURE - F
LIST OF FORMS
58
Page 58 of 328
LIST OF FORMS
I. QUALIFICATION REQUIREMENT FORM
1. QUALIFICATION REQUIREMENT
1.0 The bidder shall meet the following qualifying requirements related to solar
PV Power Plants and Battery Energy Storage System. (a) Bidder should have
executed contracts of Design/Engineering, Supply, Erection/Supervised
erection, commissioning of Solar PV Power Plant(s) with cumulative capacity
of 10MWp or above as on the original scheduled date of tender opening and
out of which at least one Solar PV Power Plant shall be of minimum 5MWp
capacity or above and should be in successful operation for at least one year
within the last 7 years as on the original scheduled date of tender opening.
AND 2.1(b) Bidder should have executed contracts of Design/Engineering,
Supply, Erection/Supervised erection, commissioning of Battery Energy
storage system with cumulative capacity of 1.0MWhr. or above as on the
original scheduled date of tender opening and out of which at least one Battery
Energy Storage System shall be of minimum 0.5MWhr. capacity or above and
should be in successful operation for at least one year within the last 7 years as
on the original scheduled date of tender opening.
1.1 Whether bidder is submitting as his own or with Collaborator(s) or with
Consortium or is a Joint Venture Company?
1.2 Please specify the cumulative capacity of Grid Interactive Solar PV Power
Plants in MWp have executed for Design/Engineering, Supply,
Erection/Supervised erection, commissioning as on the original schedule date
of Tender opening
1.3 Out of 10 MWp cumulative capacity please specify the capacity of at least
one plant which is connected to Grid and in successful operation for at least
one year as on the original scheduled date of Tender opening and within the
last 7 years
1.4 Please specify the period in months of 5MWp capacity or above of Grid
Interactive Solar PV Power Plants is in successful operation.
1.5 Please specify the cumulative capacity of Battery Energy Storage System
executed contracts of Design/Engineering, supply, Erection/Supervised
erection, commissioning of Battery Energy storage system as an original
schedule date of Tender opening
1.6 Out of 1.0MW Hr please specify the capacity at least one Battery Energy
storage system is in successful operation for period of at least one year as on
the original schedule date of Tender opening and within last 7 years
1.7 Please specify the period in months of 0.5 Mwhr capacity of Battery Energy
storage system is in successful operation.
1.8 Upload documentary evidence along with the bid in the form of user
certificate together with full contact details for verification for having
executed cumulative capacity 10MWp and one plant which is connected to
grid of 5MWp capacity or above is in successful operation for at least one
year as on the original scheduled date of tender opening and within the last 7
years
59
Page 59 of 328
1.9 Upload documentary evidence along with the bid in the form of user
certificate together with full contact details for verification for having
executed cumulative capacity of Battery Energy storage system 1.0 MWhr
and one plant which is 0.5 MWhr capacity or above is in successful operation
for at least one year as on the original scheduled date of tender opening and
within the last 7 years
2.0 Bidder who doesn’t fulfill the qualifying requirements stipulated in clause 2.1
(a) and (b) above by himself can also participate provided the bidder
collaborates with not more than two firms and together they fully meet the
qualifying requirements stipulated in clause 2.1 (a) and (b) above and the
Collaborator (s) should furnish along with the bid valid collaboration
agreement to execute this project and a back-up Bank Guarantee as required in
the relevant clauses. OR Bidder
can also be a leader of a consortium consisting of not more than three firms,
such that together they meet the Qualifying Requirements stipulated in clause
2.1 (a) and (b) above and the members of the consortium should furnish back-
up Bank Guarantee as required in the relevant clauses. In case of bidding by a
Consortium, the consortium partners shall necessarily identify a leader of the
Consortium who will furnish the Consortium Agreement and the consortium
partners shall execute a Joint Deed of Undertaking in which the partners are
jointly and severally liable to the Owner for successful performance of the
contract. OR Bidder
can also be a Joint Venture Company, provided the qualifying requirement in
clause 2.1 (a) and (b) above is met by any one or more partners of the Joint
Venture (JV) Company. Each partner of the JV Company on the basis of
whom the JV Company gets qualified shall have minimum 26% equity in the
JV Company and should furnish back-up Bank Guarantee as required in the
relevant clauses
2.1 Whether bidder is with collaborator(s)?
2.2 If yes name of the Collaborator(s)
2.3 Please upload Collaboration Agreement obtained from each of the
Collaborator for this project
2.4 Whether bidder is a leader of a consortium consisting of not more than three
firms, such that together they meet the Qualifying Requirements
2.5 If yes mention name of the consortium partners
2.6 Please upload the Consortium Agreement and the consortium Joint Deed of
Undertaking in which the partners are jointly and severally liable to the Owner
for successful performance of the contract.
2.7 Whether bidder is a Joint Venture Company meeting QR by any one or more
partners of the Joint Venture Company
2.8 If yes name of the partners and indicate the equity share in the JV Company
3.0 The Bidder or Bidder with Collaborator or the Lead Member of Consortium
or major partner of JV company shall have Positive Net Worth as per the latest
audited financial Statements.
3.1 Whether the Bidder or Bidder with Collaborator or the Lead Member of
Consortium or major partner of JV company having Positive Net Worth as
per the latest audited financial Statement
4.0 Average Annual Turn Over of the Bidder, combined Average Annual Turn
Over of the Bidder and Collaborator(s), combined Average Annual Turn Over
of the Consortium partners and the combined Average Annual Turn Over of
all the promoters of the Joint Venture Company, as the case may be, shall not
60
Page 60 of 328
be less than Rs.48.648 Cr. in the preceding three (3) consecutive financial
years as on the original scheduled date of tender opening.
4.1 Upload audited profit and loss accounts and balance sheets for the precceding
three (3) financial years from the original schedule date of Tender opening of
the bidder or the bidder with collaborator(s) or all individual firms in the
consortium or all partners in the Joint Venture Company, as the case may be
61
Page 61 of 328
2.Schedule of places of Manufacture for Solar and BESS Equipment
62
Page 62 of 328
3. SCHEDULE OF BIDDER'S EXPERIENCE DETAILS OF SOLOR PROJECT
AND BESS
Sl. Purchaser/I Address Phone Fax Email Contract Exact Capacity of Scope of Date of Number of Whether Attach
No. nstitution No. No. id /PO ref. place/locati the PV work commissio years performance ment
Contact on of the Solar power covered ning successful certificate
name PV Solar plant / operation from the
Power BESS customer
Plant is in supplied enclosed
use
63
Page 63 of 328
4. BID GUARANTEE
Page 64 of 328
II. TECHNICAL FORMS
1. TECHNICAL FORMS
S. DESCRIPTION BIDDER'S
No RESPONSE
1.0 Please confirm acceptance of the Scope of Work stipulated in the tender
document?
2.0 Please confirm acceptance of the time schedule stipulated in the tender
document?
65
Page 65 of 328
III. COMMERCIAL FORMS
1. DOCUMENT STRUCTURE
66
Page 66 of 328
2. COMMERCIAL FORM
67
Page 67 of 328
3. CHECK LIST FOR BID SUBMISSION
1.0 Please ensure that all the attachments in the offer are only in English
language? If any document is in any other Language, the same shall be got
translated in English version duly authorized by the Notary Public or
Competent Authority by the Bidder and upload both the versions.
2.0 Have you read and filled all the forms?
3.0 Have you attached performance certificates?
4.0 Have you attached related work orders/agreements?
5.0 Have you attached audited annual reports?
68
Page 68 of 328
4. RATE OF TAXES & DUTIES
1 Port of shipment
2 GST rate adopted in %
3 Customs duty rate adopted in %
4 Whether FOB supplies payment is agreeable on receipt of materials at Indian
Port .
5 Upload scan copy of Schedule-8 (Rate of Taxes & Duties)
69
Page 69 of 328
5. FORM OF BID
1.0 Having carefully examined all the Tender Documents and its Amendments /
errata / Corrigendum / Clarifications issued till the date of tender opening,
we agree to Complete the WORKS in conformity with all the terms and
conditions stated in Tender Documents and its Amendments / Errata /
Corrigendum / Clarifications issued till the date of tender opening and as per
time schedule given in Tender Document. The Services offered are of best
and of latest technology and of international standards.
2.0 I / We declare and certify that I / We fully satisfy the Qualifying
Requirements and the documentary proof as called for, have been attached.
3.0 We undertake, in case our bid is accepted, to commence the work from the
date of Letter of Award and to complete and deliver the whole of the work
and responsibilities comprised in the contract within as per time schedule
given in Tender document.
4.0 We are submitting the Bid Guarantee as instructed by you. This Bid
Guarantee shall be governed as per the stipulations provided in the “
Invitation to Bid”.
5.0 We agree to abide by and keep our Bid valid initially for a period of 8 (eight)
months from the date of opening of Bid (Part I) by NLC India Ltd. (NLCIL)
formerly Neyveli Lignite Corporation Limited and it shall remain binding on
us and may be accepted at any time before the expiry of that period.
6.0 I/We, the undersigned have carefully examined and understood the Bidding
Documents including the amendments / errata / Corrigendum / Clarifications
issued till the date of tender opening. I / We hereby agree to carry out the
entire works as described in the specifications in conformity with the
specifications and Bidding documents, as per prices quoted by us in the
Schedule of Prices.
7.0 Should our Bid be accepted, we hereby agree to abide by and fulfill all
Terms and conditions of Tender Document as accepted by us and in default
thereof, to forfeit and pay to NLCIL or NLCIL’s successors, assignees or
authorized nominees such sum of money as are stipulated in conditions
contained in Tender Documents and agree to furnish Bank Guarantee for
Contract Performance as per the Proforma prescribed by NLCIL and
acceptable to NLCIL for a sum equal to 5% of the aggregate sum of contract
price within 30 days from the date of Letter of Award. We understand that
NLCIL is not bound to accept the lowest or any Bids received and NLCIL
has the right to reject any bid, without assigning any reason whatsoever.
8.0 This Bid together with written acceptance thereof shall constitute a binding
CONTRACT between NLCIL and ourselves till a formal contract is
executed.
9.0 We have noted the contents of clause2.6 in line with DIPP order dated
15.06.2017 and confirm compliance to the requirements.
10.0 We have enclosed necessary self-certification for local content furnishing the
details of the location(s) at ehcih the local value addition is made
11.0 We have enclosed a certificate from the statutory auditor / cost auditor of the
company (in the case of companies) or from a practicing cost accountant/
practicing charted accountant (in respect of suppliers other than companies)
giving the percentage of local content.
70
Page 70 of 328
6. SUMMARY OF PRICE TABLE
71
Page 71 of 328
Section - F
DRAFT CONTRACT AGREEMENT AND
COMMERCIAL CONDITIONS OF
CONTRACT
72
Page 72 of 328
SECTION - F
COMMERCIAL CONDITIONS OF CONTRACT
CONTENTS
73
Page 73 of 328
CONTRACT AGREEMENT
WHEREAS, the purchaser invited the CONTRACTOR to submit tender for scope of work for
installation of 2 x 10 MW (AC) Grid interactive Solar PV Power Project integrated with
8MWhr. Battery Energy Storage System at Attam Pahad and at Dolly Gunj, Port Blair, South
Andaman with associated 33 KV Switchyard and grid interconnection at the take off points of
Electricity Department of Andaman & Nicobar Administration including Design, Engineering,
Manufacture, Inspection at supplier’s works, supply, insurance, transport, storage, erection,
testing, commissioning.
The scope of work also includes Operation and Maintenance of the entire system for twenty
five years including one year warranty period.
The scope is indicative only and detailed scope of work is contained in the tender specification.
AND
WHEREAS, the CONTRACTOR submitted tender to the Purchaser for execution of the work
in accordance with the tender documents including technical specifications, schedule of items
and tender drawings.
AND
WHEREAS, the Purchaser has accepted the tender submitted by the CONTRACTOR for the
construction and completion of the scope of work.
It is clearly understood between the parties that the Contractor shall be solely responsible for
the completion of the scope of work.
74
Page 74 of 328
Article – 2
If the Contractor wishes to appoint Sub–Contractor during execution of the contract, the
Contractor shall take prior written approval of the Purchaser spelling out the scope of the work
proposed to be entrusted to the said Sub-Contractor together with the relevant experience and
other details of such proposed Sub-Contractor(s).
Article – 3
This Contract shall come into effect from the date of letter of Award.
Article – 4
The following schedules appended to this Contract shall be deemed to form and be read and
construed as part of this Contract:-
ANNEXURE-I to III
Article – 5
In addition to the aforesaid, the following documents shall be deemed to form and be read and
construed as a part of this Contract:-
Technical Specifications with drawings (Volume–II)
Quantities, quoted rate and amount quoted against each item
Bank Guarantee Proforma for Contract Performance Guarantee
Bank Guarantee Proforma for Advance Payment, LDBG, RMBG and Financial Back up
Guarantee
Schedule of References
Power of Attorney
Letter of Award
Quality Assurance Plan by the Contractor
Project Information
75
Page 75 of 328
Article – 6
All the words and expression used in this contract shall, unless repugnant to the context, have
the same meaning as are respectively assigned to them in Schedule – 1. All headings and
marginal notes to the Articles, Schedules, Annexure, Technical Specifications or to any other
part of the Contract are solely for the purpose of giving a concise indication and not a summary
of a contents thereof and they shall never be deemed to be part thereof or be used in the
interpretation or construction thereof.
Article – 7
The Contract shall be governed in accordance with the Law of India. The civil court having
original jurisdiction over Andaman& Nicobar Islands shall have exclusive jurisdiction to try
any matter arising out of this contract.
Article – 8
This Contract is executed in English language in two originals, each party receiving one duly
signed copy. Both these copies are authentic. The Contractor shall submit Twenty five (25)
photocopies of the entire Contract documents to the Purchaser for his use.
Name
Name
Designation
Designation
1. 1.
2. 2.
76
Page 76 of 328
SCHEDULE-I
1.0 DEFINITIONS
1.1 The following words and expressions as used in this Contract (as hereinafter defined)
shall have the meanings hereof assigned to them except where the context otherwise
requires
1.2 Acceptance shall mean the manifestations by the owner of his assent to the mutually
agreed terms of the offer by the bidder.
1.3 Agreement shall mean mutual understanding between the parties which creates
obligations between each other
1.4 ‘Approval of the Purchaser’ shall mean the written approval by the ‘Purchaser’ or
‘Consultant’ with respect to matters delegated to the consultant by the purchaser of a
document or drawing or other particulars or matters in relation to the Contract.
1.5 Base Date shall mean the working day of the calendar month, one month prior to the
date set for opening of tenders-Part-I.
1.6 Bid shall mean a valid offer made against any tender enquiry, indicating terms,
conditions and prices
1.7 Bidder / Tenderer shall mean a person/party/ firm/ company /consortium who
submits an offer/ bid against a tender enquiry.
1.8 Billing Schedule shall mean the item, description and Quantities arrived at after
detailed design and engineering are prepared. It generally occurs in lump sum Price
contracts, where rates are fixed up for such items, based on the Break up prices
indicated in the offer.
1.9 Codes and Standards shall mean such codes and Standards as prescribed in ISS/
DIN/ BSS as applicable to the equipments, components, plant, machinery,
consumables. ASM Test Codes –AIEE Codes– Indian Electricity Act, etc.
1.10 Commercial use' shall mean that use of the equipment for works, which the
`Contract' contemplates.
1.11 `Commissioning' shall mean subjecting the entire Solar Power Plant and BESS for
Preliminary operation, initial operation and carrying out adjustment/ modifications
necessary for smooth operation and exporting power to the grid.
1.12 Compensation shall mean anything as an equivalent as to make assessment for loss
or damage.
a. The consideration for services rendered by contract agreed or implied.
b. Remuneration for injury suffered, especially when it has resulted in measurable
loss or in expenditure Money paid for damage caused by any wrong or breach of
contract, to the person defrauded or injured.
1.13 ‘Completion of erection’ shall be defined as to be completion of erection of all the
materials and items of the equipment covered under the scope of Contract,
successful completion of functional tests
77
Page 77 of 328
1.14 Completion of Handing Over shall mean that completion certificate as indicated in the
technical specifications and conditions of contract.
1.15 Completion Time shall mean the period stated in the contract for the completion of
Works up to and including successful completion upto provisional takeover and shall
be reckoned from the date of Letter of Award.
1.16 Condition shall mean the conditions agreed between the parties and stipulated in the
Contract agreement.
1.17 Consequential damages means the damages, claimed in a tort or breach of contract
which do not normally follow from the tort or breach.
1.19 `CONTRACTOR' shall mean the successful BIDDER whose bid has been accepted
by the PURCHASER and on whom the `Contract' or `Purchase order' is placed
by the Purchaser and shall include his heirs, legal representatives, successors and
permitted assignees.
1.20 Contract shall mean and include this contract between the owner and Contractor for the
execution of the works as per agreed terms, conditions, specifications prices and
enforceable as per law.
1.21 Contract period shall mean the period / time schedule agreed in the contract during
which period the Contracted work shall be performed / executed, inclusive of any
period covered by extension(s), duly issued.
1.22 ‘Contract Price’ in relation to particular contract shall mean the total consideration to be
paid by the Purchaser to the Contractor.
1.23 "Contractor's works “or "Manufacturer's works” shall mean and include the land and
other places which are used by the CONTRACTOR/SUB-CONTRACTOR for the
manufacture of equipment.
1.24 Day shall mean the period between midnight to next midnight.
1.25 Delivery shall mean delivery of only such equipment, materials and supplies specified
in the Contract and manufactured and/or supplied by the Contractor in accordance with
the sequence of delivery schedule of the Contract and in case of construction and
erection work, delivery shall mean the approval of the owner to the said construction
and erection work.
1.26 Dimensions shall mean length, area, Volume etc. all expressed in metric system.
1.27 Drawing shall mean such drawings provided along with bid documents / furnished
during the progress of work by the Contractor and approved.
78
Page 78 of 328
1.28 `Date of Contract' shall mean the calendar date on which PURCHASER and the
CONTRACTOR have signed the `CONTRACT'.
1.29 `Design Charges' shall mean the charges payable for design and engineering of the
equipment.
1.30 "Effective date of Contract" shall mean the date of Letter of Award.
1.31 `ENGINEER' / Project Manager shall mean the Officer nominated by the Purchaser for
the performance of the Contract.
1.32 The term `Equipment Portion' of the Contract Price shall mean the Ex-works. Price of
the equipment components and goods including charges for design, manufacture,
shop-testing, packing and forwarding and loading into containers / carriers.
1.33 Erection shall mean the putting up of structures and/or installation of plant and
equipment under the Contract by the Contractor and/or under the supervision of the
Contractor and will include any service which the Contractor is required to perform at
the site with his own and/or other staff and/or labour and/or Sub-Contractor for the due
fulfilment of the Contract.
1.34 The term `Erection Portion' of the `Contract Price' shall mean the value of field
activities of the `Works’ including unloading, handling, storage till erection, erection,
commissioning and testing including supervision to be performed at "site" by the
Contractor.
1.35 Final take over will occur when the following are achieved.
a) All supplies and services completed as per contract.
b) Final balance documentation, if any, incorporating latest modifications in as
built drawings has been submitted by the contractor in requisite copies.
c) The contractor has rectified in a definite manner all objections/observations /defects
mentioned in the ‘Provisional acceptance certificate.
d) Successful completion of Performance Guarantee Test for the plant and acceptance
of PG Test Repot submitted.
e) Taking over of the site and the completed works after issue of completion
certificate by the Purchaser.
1.36 ‘Functional tests’ shall mean all activities undertaken after completion of erection and
shall include mechanical and electrical check outs, safety checks, calibration of
instruments and protection devices and such other tests carried out to ensure
functional reliability of various sub-supporting systems.
1.37 Guarantee/ Warranty period shall mean the period of 12 (twelve) months from the date
of provisional take over.
1.38 Words ‘imparting’ person shall include firms, Companies, Corporation, associations or
body of individuals whether incorporated or not. Words imparting masculine gender or
singular number shall also include the feminine gender and plural number and vice-
versa where the context so required or permits.
1.39 ‘Inspector’/ ‘Inspecting Engineer’ shall mean any person or persons, or any firm
nominated by or on behalf of the Purchaser or his duly authorised agent or Consultant
to inspect equipment, supplies, materials or any type of work under the contract.
79
Page 79 of 328
1.40 `Instructions' shall mean any drawings and/or instructions, oral and/or in writing
details, direction and explanations issued by the CONSULTANT or the PURCHASER
from time to time during the `CONTRACT PERIOD'.
1.41 Initial Operation shall mean all operations undertaken as part of “Commissioning” after
completion of “Preliminary Operation” It shall be the first integral operation of the
complete plant/system/ equipment covered under the “Contract” and shall include first
startup on no-load and/or partial load and/or full load runs for PV arrays, inverter and
electrical equipments and gathering of operational data, calibration, setting and
commissioning of control systems, and shut-down inspection and adjustment after
running of the plant/system/equipment covered under the Contract.
1.42 Letter of Award (LOA) shall mean the official communication issued by the owner
notifying legally to the bidder that his bid has been accepted on mutually agreed terms,
conditions and prices.
1.43 Liquidated damages, not as a Penalty, is agreed upon between parties in the Contract
towards time delay. Liquidated damages can also be prefixed towards shortfall in
performance parameters agreed in a Contract.
1.44 Manufacturer shall mean a person firm/company who manufactures and/or produces
Plant, Equipment, Component Spare Parts etc.
1.48 Notice shall mean any written Notice issued by the owner / Bidder / Contractor.
1.49 A Notice published by the owner with the intention to invite offer/ bid for his
requirements.
1.50 Particulars shall mean the following:
a) Specification
b) Drawing
c) Sealed pattern denoting a pattern sealed and signed by the Inspector.
d) Proprietary make denoting the product of an individual firm.
e) Any other details governing the construction, manufacture, supply and / or
erection as per the Contract.
80
Page 80 of 328
1.51 Performance Guarantee Test shall mean such tests as are prescribed in the Specification
to be done by the Contractor.
1.53 Plant, Equipment, Stores, Item or Material shall mean and include plant, equipment,
material, machinery or any part thereof to be provided for and the erection work to be
done by the Contractor under the Contract.
1.54 Price shall mean the price agreed in the contract between the parties towards the scope
of work.
1.56 Project shall mean the project specified in the tender documents and specification.
1.57 Purchaser/Owner shall mean and include NLC India Limited (NLCIL) and its different
functionaries entrusted with the responsibilities in relation to this contract in respect of
the area of responsibilities of such functionaries.
1.58 Provisional take over shall mean acceptance of prima facie and in principle subject to
completion of / fulfilment of certain conditions and entire plant is exporting power to
grid.. This is not a complete acceptance of work entitling the contractor to get full
payment or to assume that all the obligations and terms and conditions of the contract
have been fulfilled to the satisfaction of the Owner / Purchaser.
1.59 Site shall mean the land acquired and set for the location of the project / work.
1.61 Sub-contractor means a Contractor selected with the approval of the owner to carry out
certain part of the scope of work.
1.63 Sub-supplier means the supplier selected with the approval of the owner to supply
certain items included in the Scope of Work.
1.64 Supervision shall mean the successive control and directions given by the Contractor in
relation to Contract work during execution of the Contractor’s and/or his sub-
Contractor’s work.
1.65 SUCCESSFUL BIDDER/TENDERER shall mean the bidder whose bid is considered
for acceptance.
1.66 `Supply' shall mean the goods to be supplied by the Contractor under the `Contract'.
1.67 Tender shall mean the bidder’s offer with his terms, conditions, Specifications and
prices to perform the scope of work.
81
Page 81 of 328
1.68 Test shall mean such test / tests stipulated or considered necessary by the Inspecting
Officers.
1.69 Time shall be reckoned by months, weeks, days and hours, month being equivalent to
the Calendar month according to the Gregorian Calendar. The day or days unless
herein otherwise expressly defined shall mean Calendar day or days of 24 hours each.
1.70 Time of completion shall mean the time / period stated / agreed for completing the
scope of work specified in the contract.
1.71 The term `Transport Portion' of the Contract Price shall mean charges on all the
mode of transport envisaged under Contractor's scope including inter-carting
storage at any intermediate point.
1.72 Warranty shall mean Contractor’s assurance to the Purchaser that the goods or property
is or shall be as represented and if not it will be repaired and reconditioned or replaced
by the Contractor at his cost or expenses.
1.73 Weight shall mean the calculation of a load. It is to be stated in ton (1 ton = 1000
kilogram) and / or kilogram (1 Kilogram = 1000 gram).
1.74 Works shall mean plant, non-plant, buildings, Structures, Foundations and all plants,
Equipment, Components to be provided and other construction/ erection services that
the contract requires the contractor to provide.
1.75 Words importing persons shall include firms, Companies, Corporation, Words
importing masculine gender or singular number shall also include the feminine gender
and plural number and vice-versa where the context so requires or permits.
1.76 Terms and expressions not herein defined shall have the same meaning as are assigned
to them in the Indian Sales of Goods Act (1930), failing that in the Indian Contract Act
(1872) and failing that in the General Clauses Act (1897) and such others as mentioned
from time to time.
1.77 `Writing' shall include any manuscript, typewritten or printed statement, under or over
signature and/or seal as the case may be.
1.78 When the words `Approved', `Subject to Approval' `Satisfactory', `Equal to',
`Proper', `Requested', `As requested', `Where directed', `When Directed', `Determined
by', `Accepted', `permitted', or words and phrases of like import are used the
approval, Judgement, direction, etc. is understood to be function of the PURCHASER
or the CONSULTANT.
1.79 The various Acts and Regulations are normally available for sale from the
following address:
`Deputy Controller -Publication Department,
Government of India,
Civil Lines, Delhi - 110 006.
82
Page 82 of 328
SCHEDULE- 2
SCOPE OF SUPPLY AND SERVICES
2.1 SCOPE OF WORK:
The scope of work for supply and services Contract includes development of land,
design, engineering, manufacture, inspection at supplier’s works, supply, insurance,
transport, storage, erection, testing and commissioning of 2X10MW(AC) grid
interactive solar PV power project integrated with installed capacity of 8 MWhr. With
½ hr. backup Battery Energy Storage System to feed smoothened power to the grid
with associated 33kV switchyard and grid interconnection at the take off points of
Electricity Department of Andaman & Nicobar Administration (A&NA) with all
accessories at Attam Pahad and Dolly gunj areas in Port Blair, South Andaman.
The scope of work for O&M Contract includes Operation and Maintenance of the
entire system for ten years after one year warranty period.
a. The scope of Design, engineering, manufacture, inspection at supplier’s works,
supply, installation, testing and commissioning shall include
i) Solar PV Power Plant
Adequate number of Solar PV modules with cables, connectors and
module junction boxes,
module supporting structures,
string monitoring and combiner boxes,
power conditioning units,
Auxiliary Transformers,
Switchgears, cables,
HT switchgear, CT, PT,
Power Transformers,
LT panels, protective relays, Control and Metering panels, UPS, DC
system- Battery, Battery chargers to cater the needs of DC loads.
ii) Battery Energy Storage System
Battery cells /Modules
Power Conversion System, Battery Management System, Control panels
and HMI interfaces
Lightning Arrestor, CT, PT, Protective relays, Control and Metering
Panel, Surge Protection devices, Filters etc.
Panels, Switch gears, cables and distribution boards
Transformers
Data communication units
Auxiliary systems and ventilation systems
Fire Protection system and suppression system, safety equipments
Container unit
Mounting structures
Civil foundation works and platform as per Battery Manufacturer requirement.
Dike structures surrounding the battery units to protect the environment during
ruptures of BESS units if required.
83
Page 83 of 328
iii) Power Export Switchyard
33KV switchyard equipments,
SCADA and Energy Management system
Control room,
Data/voice communication system,
33KV transmission lines, towers, Metering station, 33KV cables,
LT panels, UPS, DC system-Battery, Battery charger (DC loads
required for switchgear),
Fire protection and suppression system, safety equipments,
Reactive power control for grid inter connection at the take off points
of Electricity Department of Andaman & Nicobar Administration
(ANA)as per grid requirements.
b. The scope of work includes all cabling, auxiliary power supply and distribution,
lighting, air conditioners, weather monitoring unit, earthing and lightning
protection as defined in the relevant Technical Specification sections.
c. The scope of civil construction work includes land development, removal of trees,
vegetation removal, site survey, soil investigation, site preparation, Site grading,
fencing, foundations for Solar PV module mounting structures, RCC building for
Power Collection Sub Stations, construction of 33KV Power Export switchyard
and RCC Building for control room, approach roads, internal roads, peripheral
roads, path ways, cable trenches, drains, Main Gate and security buildings &
watch towers, Sign Board, etc. as defined in the relevant Technical Specification
sections.
d. The Scope of work also includes facilities for arrangement, storage, construction
as well as O&M water supply, Module water washing network system with proper
drainage/ sewage system and disposal and construction power supply.
e. The scope of work shall also include the following :
i. Furnishing of all relevant drawings, data sheets, technical catalogues of
equipments / devices, QAP, MQP, FQP, type test certificates, Inspection
reports etc. as required for construction and O & M of the Solar Power Project.
ii. Supply of all spares, Consumable materials, replacements, tools and tackles
and accessories etc. which are necessary or useful for satisfactory and trouble-
free operation and maintenance of the plant during the entire period of O&M of
ten years.
f. The works to be performed on all equipment and accessories shall include but not
limited to the following:
i. Insurance, Transportation, unloading, receiving and storage at site.
ii. Arranging to repair and/or re-order all damaged or short-supply items.
84
Page 84 of 328
iii. Final check-up of equipment, erection, testing and commissioning and putting
the entire system including the power evacuation facility into successful
operation.
g. The scope of work shall also include coordination activities with respect to Grid
connectivity and establishing Energy Management Centre being implemented by
A&N Administration Electricity Department, system study, alteration required in
the grid take off points of the existing Panther I and Panther II feeders towers,
termination and support structures, gantries etc.
Scope of Supply
Plant & Equipment
The scope of supplies and services of the Contractor for Plant and Equipment is
described in Technical Specification and the relevant Annexure subject to General
Terms and Conditions of Contract in Schedule-10.
Scope of Services
Technical Services
The Contractor shall be responsible for the following services including those Services
stipulated elsewhere in the Tender Specification:
a) Detailed design and engineering
b) Technical services related to planning, procurement, manufacturing, inspection,
expediting, packing, shipping, storing, etc.
c) Project management services and complete feedback of data and information to
Purchaser regarding Contractor's scope of supply and services.
d) Time bound project co-ordination relating to transportation, insurance, claim
settlement, inspection, construction planning and scheduling, erection planning, field
construction engineering, testing, start up, trial run, commissioning and performance
guarantee tests. The Contractor shall bring his own/Sub-contractor/Sub-vendor
Specialists for the performance of the above mentioned works.
e) Total day to day supervision of construction including erection and specialised services,
if any.
f) Technical consultation/liaison/guidance relating to detail design and plant engineering
by its sub-contractors.
g) Quality control and adherence to the time schedule control of site work and other
works.
h) Start-up trial runs and commissioning services.
i) Demonstration of performance guarantee tests by deputing commissioning
engineers/specialists.
j) Clearance for installations including power evacuation system from the statutory and
other concerned authorities on behalf of Purchaser. The Contractor shall also assist in
preparing application forms, providing necessary drawings, documents, test certificates
etc., including necessary co-ordination with statutory and other concerned authorities.
k) Submission of complete as built drawings/documents, O&M Manuals etc., approved by
NLCIL. .
The Contractor shall be responsible for supply of all the drawings and technical documents &
information in respect of the plant & equipment. The Contractor shall deliver the drawings,
technical documents and information to the Purchaser and their authorized agency.
85
Page 85 of 328
Supervision
The Contractor shall depute Technical personnel/ Specialists from various disciplines for
the supervision of construction work under his scope of work. The above mentioned
Technical personnel/Specialists shall supervise the construction and commissioning of the
project so as to establish to the Purchaser that the guarantees as agreed by the Contractor
are fully met.
Construction & Erection Works
1. The Contractor shall provide all necessary construction and erection tools & tackles,
small hand tools, instruments, all commissioning instruments, bolts, nuts, washers, jigs
and fixtures, winches, alignment tools etc. and the material handling equipments such
as cranes, hoists etc., welding equipment and accessories, measuring instruments,
temporary supports and staging, consumables (e.g. welding gas, electrodes etc),
erection packs etc for erection of steel structures, and other equipment which may be
required for carrying out the construction and erection work efficiently within the time
schedule provided herein in the Contract. The Contractor shall ensure that proper
documentation is followed at entry gate of the premises for such items which shall be
carried back by Contractor after completion of work.
2. The Contractor shall carry out any and all such works, as may be required, to build the
project complete in all aspects as per the Contract Specification.
3. The Contractor shall make all necessary arrangements to deliver the equipment at the
project site by wagons/trucks/trailers/Light motor vehicles/lorries/ships/boats etc build
his own stores (covered, uncovered, air-conditioned, if necessary) for the proper storage
of equipment, maintain the stores and all related documents and records, transport the
equipment to site for erection purpose. Necessary security arrangements also shall be
made by the Contractor. Arrangements shall be made available by the contractor for
construction of stores and construction site office, labour colony, etc.
4. The Contractor shall be responsible for proper and neat storage and also undertake
conservation of all consignments including damaged boxes. During storage of
equipment, the Contractor shall take into account deterioration and carry out the re-
conservation of the complete equipment/parts/supplies as may be necessary as per the
storage instructions of the Manufacturer of equipment/components. The Contractor
shall also supply the consumables required for such re-conservation work and
repair/replace parts required thereof for the proper functioning of the equipment after
erection and commissioning.
5. The Contractor shall unpack and do visual checking against physical damages to the
equipment/cases, clean equipment before start of erection. Damage/ shortage, if any,
will be reported to the Purchaser and shall be rectified/replaced expeditiously, so as not
to upset the erection and commissioning schedule. Delay on account of settlement of
insurance claims by the Contractor shall not be considered as an excuse for delay in
completion of erection and commissioning.
6. The Contractor shall provide all necessary erection equipments including material
handling equipment such as cranes and hoists, compressors and other equipment and
instruments and consumables, all commissioning equipment and instruments, welding
equipment, winches, alignment tools, precision levels, the odolite, etc. which may be
required for carrying out the erection and commissioning work efficiently. All
instruments shall be properly calibrated before use. Unless otherwise specified, the
86
Page 86 of 328
above erection equipment/ materials shall be the property of the Contractor. However,
Purchaser's prior permission shall be required for removal of these erection equipment/
materials from the site. The Contractor shall ensure that proper documentation is
followed at entry gate for such items which shall be carried back by Contractor after
completion of work.
7. The Contractor shall provide all temporary ladders, scaffolding materials, platforms,
supports and other necessary facilities required for handling, erection, testing and visual
inspection of supplies at the point of installation and shall also provide necessary
packing plates, wedges, shims, leveling screws etc. required for erection of equipment
and structures.
8. The Contractor shall provide erection consumables like oxygen gas, acetylene gas,
argon gas, welding rods, filler wire, solder lugs, oil, grease, kerosene, cotton waste, etc.
required for erection of equipment and steel structures and required items for
commissioning activities.
9. The Contractor shall erect and maintain his own site offices and stores, as required for
the work and arrange for proper house-keeping and up-keep of the area.
10. The Contractor shall provide sufficient fencing/barricade, notice boards, signage and
lighting to protect and warn others as may be considered necessary by the Purchaser.
All materials used for providing these facilities shall be the property of the Contractor.
11. The Contractor shall mobilise adequate material handling equipment such as mobile
cranes, forklifts, trailers, dozers, winches etc in addition to other erection tools &
consumables keeping in view the erection schedule. The Contractor shall provide as per
time schedule from the date of Letter of Award, his scheme for mobilisation with Bar
Chart indicating clearly the resources, manpower and machinery proposed to be
deployed to ensure timely completion of work and quality of workmanship.
12. Underground services, if any to be diverted / protected shall be the responsibility of the
Contractor and shall be informed to the Purchaser. Approval from authorities required
for such works shall be obtained by the contractor. The compensation / statutory
payments if any for such works shall be borne by the contractor.
13. The Contractor shall organise the work in such a manner that work being carried out
simultaneously at site is not impeded and the workmen not endangered and shall
arrange all temporary access as required for the erection work.
14. The Contractor shall carry out base/primer and final painting of all Plant & Equipment,
Structures, Pipelines, etc. supplied. The painting including its process shall be carried
out as specified in the detailed technical specification. Where not specified, the same
shall be as per the standard codes & practices normally applicable and adopted
internationally for the type of Plant & Equipment offered.
15. Grouting of the equipment and steel structures on the foundations with approved non-
shrink-grouting compound shall be the responsibility of the Contractor. The grouting
materials shall be supplied by the Contractor.
16. All safety, health and pollution control measures as required to be adopted as per the
statutory regulations, guidelines, etc., The safety codes for projects issued along with
the tender or otherwise required or implied by local statutory regulations or practices
shall be strictly followed by the Contractor during the entire duration of execution of
the Contract. The Contractor shall set up a suitable safety organization of its own at
site, in this regard.
87
Page 87 of 328
17. The Contractor shall not dispose of, transport or withdraw any tools, tackles,
equipment, and material provided by him for the "contract" without taking prior written
approval from the Purchaser.
The Contractor shall undertake Performance Guarantee (PG) Test as defined in the relevant
clauses of the technical specification. In case the Contractor fails to demonstrate and prove
the Performance Guarantees and achieve the results as agreed in this Contract, the
Contractor shall rectify the Plant and Equipment and demonstrate the performance
guarantees failing which the Purchaser’s option of either to reject the equipment or to levy
LD will be exercised.
1. Water for Construction and for O & M shall be arranged at each location of project site by
the contractor. All payments towards arrangement and supply of water shall be borne by
the contractor. The Contractor shall make his own arrangements to lay and maintain
necessary distribution lines at his own cost. The contractor shall arrange for storage sumps,
pumps and distribution piping to various locations within the solar power plant. The
Contractor shall be responsible to store water in sufficient quantity to meet its requirements
in well built covered/protected water storage tanks / sumps.
The Contractor shall ensure that there is no wastage of water. He will also be responsible
for maintaining the taps, pipe lines etc. in proper condition. The Contractor shall obtain
prior approval of the Purchaser of his distribution scheme before laying the pipelines. Non
availability of water in the project site shall not be excuse for delay in completion of
Project. The contractor may at his own cost arrange suitable backup water supply.
Construction Power
1. The Contractor shall arrange construction power for the purpose of the construction and
erection for each location of project site /sites. All payments towards availing power
supply and usage charges and deposits shall be borne by the contractor. The Contractor
shall make his own arrangements for further distribution. The Contractor shall make his
own arrangements to lay and maintain necessary supply lines for temporary power. All
temporary wiring must comply with local regulations and relevant Indian Electrical Act
and will be subject to the Purchaser's inspection and approval before connection to supply
and later. Non-availability of power shall not be an excuse for delay in completion of
erection construction. Contractor may at his own cost arrange suitable back-up power.
2. The Contractor shall supply and install all distribution cables, wires and switches etc. of
rated capacity for the commencement of work from the source of power at his own cost.
The contractor shall employ Electricians having valid Electrical License for carrying out
the installations as well as for the maintenance works.
3. The Contractor shall facilitate the Purchaser or his authorised representative for inspecting
his temporary electrical installation as and when required. The Contractor will
immediately attend to the defects so pointed out during this inspection including
replacement of faulty cables, switches etc.
4. The Contractor shall be responsible for all damages, losses etc. due to fire or otherwise if it
is due to his negligence, improper installation, operation and/or maintenance of his part of
installations.
88
Page 88 of 328
Codes and Standards
All works to be executed and/or engineering services and technical services to be rendered
under this Contract, shall be completed in the manner set out in this Contract and in
accordance with the specified codes, Standards and best trade/ engineering practices.
Wherever the codes are not mentioned or in case of code discrepancies, relevant Indian
Standards / International Standards approved by Purchaser shall be followed.
Total Responsibility
The Contractor shall be solely responsible for the entire supplies, engineering services and
technical services, irrespective of whether supplies and services have been made/ rendered
by him directly or by his Sub-Contractor/ sub-vendors or all associates of this contract.
General
a) The bidder is required to carefully examine the Technical & General Specification,
Terms and Conditions of Draft Contract, drawings and other details relating to work as
given in the Tender Document and fully acquaint himself as to all conditions and
matters which may in any way affect the work or the cost thereof. The bidder shall be
deemed to have on his own and independently obtained all necessary information for
the purpose of preparing the Bid and his bid as accepted shall be deemed to have taken
into account all contingencies as may arise due to such information or lack of the same.
b) The bidder shall be deemed to have exhaustively examined the Tender documents
including the Draft Contract, to have obtained all information and clarifications on all
matters whatsoever that might affect the carrying out of the work and to have satisfied
himself as to the adequacy of his Bid. He is deemed to have known the scope, nature
and magnitude of the work and the requirements of materials and labour involved etc.
and as to all work he has to complete in accordance with the Contract whatever be the
defects, omissions or errors that may be found in the Tender/Bid Documents.
c) The bidder shall be deemed to have acquainted himself with the Indian Income Tax
Act, 1961, Indian Companies Act, 1956, Indian Customs Act, 1962, Indian Electricity
Act, CEA rules, A&N Electricity rules, CERC/JERC regulations, A&N regulations,
grid codes. MNRE guidelines, Factories Act, Pollution Control Regulation and other
related Acts & Laws prevalent in India and as amended from time to time. The
Purchaser shall not entertain any request for clarifications from the bidder regarding
such local conditions.
d) Any neglect or omission or failure on the part of the bidder in obtaining necessary and
reliable information as stated above or on any other matter affecting the bidder shall not
relieve him from any risks or liabilities or the entire responsibility of completion of the
work in accordance with the Contract.
Page 89 of 328
c) No imported material shall be allowed to be taken out other than imported tools and
tackles and instruments brought by the Contractor on draw back basis, provided he has
carried out necessary documentation at the time of bringing such items inside the Plant.
d) Replacements/ Disposal of materials during construction as well as O&M shall be
carried out by the contractor with utmost care without affecting the environment and all
the scrap shall be taken out by the contractor and shall be disposed as per the standards
and prevailing practices norms of A&N Islands.
e) Necessary permission from concerned authorities shall be obtained for disposal of any
item within the Island.
90
Page 90 of 328
SCHEDULE-3
3.0 CONTRACT PRICE:
3.1 The contract price shall be paid in currency or currencies in which the price has been
quoted. The contract price shall be firm till completion of contract period.
3.2 The total lumpsum prices quoted by the Contractor in his bid with additions and
deletions as may be agreed to before award of Letter of Award/ Contract, for the entire
scope of work, viz., design, manufacture, supply transportation, insurance, storage
Erection, commissioning and testing of the equipment etc. covered by detailed scope of
work of contract and in accordance with all terms, conditions, stipulations,
specifications, requirements and other conditions of the Contract and incorporated in
the Price Schedule and documents shall be treated as the Contract Price.
3.3 The Contract Price shall be deemed interalia to include and cover the cost of
deployment of construction equipment, temporary works, establishment of labour
camp, all materials and supplies, labour, insurance, fuel, stores, appliances, security
arrangements, safety and fire fighting arrangements (including those required
during construction, storage and erection) to be supplied/used by the Contractor and all
such other materials and services and actions that may be necessary or derived
or statutorily required in connection with the execution of the works as per the
Contract or any portion thereof complete in every respect and maintained as
detailed in the contract documents or as may be required in terms of the
Contract.
3.4 The Contract Price shall be deemed to include and cover the cost of all royalty and fees
for all articles, and processes, protected by letters patent or otherwise incorporated
in or used in connection with the work, also all royalties, rents and other payments
in connection with obtaining all materials for the work and the Contractor shall
indemnify and keep indemnified the Purchaser, which indemnity, the Contractor
hereby gives against all actions, proceedings, claims, damages, costs and
expenses arising from the incorporation in or use of work of any such articles,
processes or supplies.
3.5 Single Contract or Separate Contracts for Supplies, Services, Maintenance during
warranty period etc., may be entered with. However, the Separate Contacts shall have
necessary provisions to take care of Single Bidder responsibility, Liquidated Damages
(LD), Purchaser’s right to recover dues including LD from payment due under any of
the contracts, warranty and Performance Guarantee etc.,
In view of the above, any liabilities arising out of such Separate Contracts shall be
borne by the bidder/Contractors
However separate contracts will be entered in to for ten years operation and
maintenance.
3.6 The contract price shall be firm till completion of the contract period.
3.7 Contract Price Break-up
3.7.1 The Contract Price indicated in the Price Schedule shall be for the scope of work
and services detailed under scope covered under technical specification and for all
the contractual obligations of the Contractor if any, under the Contract.
3.7.2 The Contractor shall furnish the detailed billing break-up for each item for the
approval of Purchaser, which after the approval only, will be the basis for submission
of invoices for progress of payments.
91
Page 91 of 328
SCHEDULE-4
TIME SCHEDULE
4.1 TIME SCHDULE- Firm and Binding:
The basic considerations and the essence of the `Contract’ shall be the strict adherence
to the time schedule for performing the works in the contract. The time and the date of
completion of the project activities as stipulated in the Time Schedule of Tender
specification and accepted by the Purchaser shall be deemed to be the essence of the
Contract. The Contractor shall so organise his resources and perform this work as to
complete it not later than the date agreed to. The time to complete the Works contracted
for shall be reckoned from the date of issue of the “Letter of Award” to the
Contractor.
4.1.1Completion Time:
The contractor shall complete the design, engineering, manufacture, Inspection at
supplier’s works, supply, insurance, transport, storage, erection, testing and
commissioning of 2x10 MW (AC) grid interactive solar PV power project integrated
with installed capacity 8MWhr with ½ hr. backup BESS to feed smoothened power to
the grid associated 33 KV switchyard and grid interconnection at the takeoff points of
Electricity Department of Andaman & Nicobar Administration within 18 months from
the date of issue of LOA.
Within one month from the date of issue of Letter of Award, the Contractor shall
submit to the Purchaser the list of all drawings and documents by title, using the
approved numbering system and indicating the schedule of submission of
drawings in conformity with the time schedule. This list of submission and approval
shall be updated and submitted by the Contractor at the end of every month.
4.2.2 All the drawings and documents shall be prepared in accordance with contractual
requirements and also as per the best engineering practices. Approval in respect of
drawings shall be accorded by the Purchaser within two weeks of receipt of the same.
In case drawing is not complete and/or is not approved, the comments shall be
furnished to the Contractor within two weeks of receipt of drawing. Any
submission with gross omissions and/or errors will not be considered as a valid
submission. If any document/drawing were commented by Purchaser, the Contractor
has to incorporate the comments and resubmit the document within one week for
approval by the Purchaser. This review and / or approval of the drawings by the
Purchaser will not relieve the contractor of any of his responsibilities under this
contract.
92
Page 92 of 328
4.2.3 The sequence of submission of feedback data, delivery of structural, mechanical
equipment and electrical equipment, instrumentation, submission of erection instruction
and erection drawings and other supplies and services by the Contractor shall be as per
the L1 PERT network schedule.
4.3.1 Level-I PERT network of the project (submitted along with the bid) shall be
resubmitted by the Contractor for NLCIL approval and finalised within one month
from the date of Letter of Award. The approved L- 1 PERT will be annexed to at the
end of this schedule in the contract document.
4.3.2 Detailed Level-2 PERT network of all systems/sub systems/ discipline/ equipment etc.
incorporating activity-wise quantity shall be submitted and finalised within three
months from the date of Letter of Award. These-detailed networks shall be prepared
based on the milestones reflected in Level-I network, which shall be the basis for
performance of the Contract. The salient activities and their time schedule for the
project shall be as follows:
4.3.3 The Contractor shall submit detailed construction resource planning along with Level-2
networks.
4.3.4 The Contractor shall submit estimates of quantities/volume of work sub-system
wise, discipline wise, list and weights of equipment
(mechanical/electrical/instrumentation) etc during execution stage as per requirement.
4.3.5 All PERT network shall be furnished in MS Projects both in Hard copies and
Softcopies.
4.3.6 Detailed assignment schedules of foreign specialists Experts for rendering
technical services shall be submitted by the Contractor for the approval of the Purchaser
within three months from the date of Letter of Award. The bio-data of key
personnel shall be submitted within one month from the date of Letter of Award
and for others, within three months before their deputation.
4.3.7 Drawings of equipments shall be supplied at least one month before the shipment of the
equipment.
4.3.8 All “as built drawings” shall be submitted by the Contractor before Final Take Over.
93
Page 93 of 328
4.3.9 Erection Instructions for the Plant and Equipment shall be submitted by the Contractor
at least one month before the shipment of the respective Plant & Equipment.
4.3.10 The delivery of equipment shall be deemed to be completed when all equipment
and drawings/documentations have been supplied by the Contractor.
4.3.11 Erection of the system / equipment shall be deemed to be completed when all
equipment for the normal functioning of the plant / system are erected at site.
4.3.12 Completion of successful commissioning of the system/ equipment shall be deemed to
have taken place when the system/ equipment has been successfully commissioned as
per relevant Clauses of Schedule-10.
4.3.13 Demonstration of performance guarantee tests shall be deemed to have completed when
the Contractor has demonstrated and has achieved PG parameters as per Technical
Specification and Schedule-9.
4.3.14 The Contractor shall render timely and adequate technical services through his
Specialists to ensure completion of entire work and demonstration of performance
guarantee tests.
4.3.15 The Contractor shall prepare and submit in a time bound manner necessary drawings of
proper standard with best engineering practices. The Contractor shall be responsible for
obtaining timely approval of the drawings from the Purchaser to ensure completion of
work within the time schedule. Any delay due to incomplete submission and
consequent delay in approval shall be to the account of the Contractor. The Contractor
shall not claim any time extension on this ground.
4.3.16 The Contractor shall ensure to send all letters with authentication through FAX/E-mail
and a confirmation copy of the same through courier/Speed Post/Hand delivery. All
drawings and documents shall be sent through Courier/ Speed Post/Hand delivery.
4.4DELIVERY OF EQUIPMENTS, ITEMS ETC.
The delivery periods shall be reckoned from the date of Letter of Award.
4.4.1 The delivery of imported equipment and components including the foundation bolts and
inserts in respect of the plant and equipment shall be completed on FOB basis, as
given in the Overall time schedule.
4.4.2 Delivery of all indigenous equipments, and items shall be completed on FOR site basis
as given in the Overall Time schedule.
4.4.3 Delivery of all supplies shall be made strictly in sequence of erection at site
unless otherwise differently agreed to by Purchaser.
4.5MAINTAINING SPARES
The required spares shall be maintained and shall be dispatched along with the
consignment of the respective equipment. The required Mandatory spares shall be
maintained by the contractor at the stores after the Provisional Takeover.
94
Page 94 of 328
4.7.1 If the satisfactory commissioning of the entire capacity of the integrated system in the
manner prescribed is delayed beyond the stipulated dates, Liquidated Damages shall be
payable at the rate of 0.5% per week of delay or part thereof of supply and services
subject to a ceiling of 10% of the total value of contract for supply & services.
4.7.2 If the reason for the delay is solely attributable to the Purchaser, adequate time
extension will be given to the Contractor to the extent of delay attributable to
the Purchaser. Further in any delay in commissioning attributable to the contractor, the
losses incurred by NLCIL due to the withdrawal of subsidiary by GOI shall
compensated by the contractor.
4.7.3 If the reason for the delay is purely attributable to the Contractor, L.D. will be levied,
and extension of time may be granted.
4.7.4 If the decision regarding the reasons for the delay is required to be analysed
and the same can only be determined after completion of the work or if the
issue is likely to enter into dispute or requires in-depth study to fix the responsibility
for the delay, then extension of time will be given to the Contractor subject to levy of
L.D. if considered necessary. However, as a precaution the amount equivalent to
the maximum L.D. leviable would be withheld from the running bills at the
stage where the balance payment may not be able to cover the L.D. and other
obligations as per the provisions of the Contract.
4.7.5 In case this arrangement causes difficulty to the Contractor in cash flow and progress of
work, an amount up to 90% of the withheld amount can be released to the Contractor
against suitable Bank Guarantee for 100% of the withheld amount if requested
by Contractor.
4.7.6 However, 90% of the withheld/ leviable Liquidated Damage amount may be considered
by the Purchaser for release against submission and acceptance of LDBG as per
the format enclosed for 100% of the leviable LD amount.
4.8 Liquidated Damages for shortfall in Performance Guarantee values
For non-fulfilment of Performance Guarantee values the LD will be levied as indicated
in the Technical Specification.
4.9 Total Liability for Delay &shortfall in Performance Guarantee (PG) Values The
liquidated damages for (1) delay in commissioning (2)non-fulfilment of performance
guarantee values are independent and shall be applied separately. However, the
total liability of the Contractor towards delays and for shortfall in Performance shall be
limited to 17.5% of the total value of contract for supply & services.
4.9.1 The Purchaser may without prejudice to any method of recovery deduct the amount for
such Liquidated damages from any amount due or become due to the Contractor either
under this or any other Contract. Payment of Liquidated Damages shall in no
way relieve the Contractor from his Contractual obligations to complete the works or
from any of the obligations under this Contract. Any delay in the levy or recovery
of LD shall not constitute waiver of the right of the Purchaser under the Contract
towards levy and recovery of LD.
95
Page 95 of 328
4.10 IMPLEMENTATION STRATEGY
4.10.1 Time Schedule
The heads to be covered in the L1 PERT network schedules broadly are:
Submission of basic engineering and approval, issue of ordering specifications,
placement of orders of equipment, submission and approval of drawings for
Mechanical/ Electrical/Instrumentation equipment, etc. manufacture and supply of
equipment, civil and structural works, submission of erection drawings and
manuals, erection of mechanical/electrical equipment, testing and commissioning
etc. The major milestones for the principal items are to be highlighted in the
schedule.
4.10.2 The Contractor shall submit:
i) Level- 2 PERT network schedule including details of pre-construction activities and
execution work.
ii) Estimates of quantities/volume of work and other details such as list of
specifications, list of drawings, quantum of work discipline wise, list of
equipment (mechanical/ electrical/instrumentation) etc.
iii) Updated level II networks along with progress reports (formats to be mutually
finalised) shall be furnished as and when required.
4.11 CONSTRUCTION/ERECTION PLAN
4.11.1 The Contractor shall submit a write-up for construction/erection plan for the
plant &equipment under his scope of supply.
i. The plan will indicate a broad outline:
ii. The construction/erection techniques to be employed.
iii. Resource planning for deployment of construction / erection of
equipment/machineries.
iv. List of various construction equipment such as cranes, dumpers, etc. planned to be
mobilized with quantity & rated capacity/specification.
v. List of machinery, tools and tackles such as welding transformers, welding
generators/sets, gas cutting sets, drilling machines, chain pulley blocks, survey
instruments, etc. and indicate specification and quantity of each item
4.11.2 Deployment of manpower
The Contractor shall submit a list showing deployment of manpower of the
following categories indicating number of personnel, schedule and duration of
their posting at site, educational background, and experience.
i) Engineers to be engaged for design and engineering coordination, follow up and
expediting.
ii) Engineers and supervisors are to be directly attached to site work i.e.
civil construction, erection, testing, commissioning and demonstration of
performance guarantee values.
iii) Organization for implementation of the project.
4.12 PROGRESS MONITORING
4.12.1 It is proposed to have an effective system of progress monitoring to ensure
timely completion of all project activities. The guidelines laid down herein shall
ensure progress monitoring by the Purchaser.
96
Page 96 of 328
4.12.2 The intention is to dwell upon the progress of the activities related to
Engineering Procurement, Manufacturing, Dispatch, Site Erection, testing,
Commissioning and PG Test.
4.12.3 In the interest of the timely completion of the project, the area of monitoring can be
altered in consultation by the Purchaser with the Contractor. The Contractor shall
furnish adequate information in the monthly progress reports on the formats to
be mutually agreed upon. The Contractor shall submit the requisite no. of progress
reports in five (5) copies.
4.12.4 The Purchaser will invite the Contractor for monthly/fortnightly meetings to
review the progress of each activity, and depute Purchaser’s authorized
representatives for ascertaining/ expediting progress at Contractor’s works and
suggest remedial actions to bridge-up time gap if any between planned progress and
observed progress.
4.12.5 Progress report
a) A monthly progress report with exception report showing current status
of various activities including status of ordered/yet to be ordered items
shall be submitted to the Purchaser by the Contractor in five hard copies,
referring to the schedule of order, reasons for not achieving it and
remedial measures proposed.
b) The Contractor shall submit programme of execution both in the form of
activities in ‘Network’ as well as quantitative programme in terms of
month wise physical targets for various disciplines of work.
c) The Contractor shall submit computerised updated time analysis report every
month along with progress report. The updated PERT network drawing (both
Level I and Level II) are to be submitted in requisite no. of copies at
least once in every month. The format of the submission are to be mutually
discussed and agreed.
d) The monthly progress report shall indicate progress of activities again
sttargeted dates and targeted quantities in proforma as per the
requirement of the Contract for maintaining consistency of reporting and
for maintaining database by the Purchaser. Reasons for shortfalls, if any,
shall be clearly brought out and proposed remedial measures to arrest the
delays shall be indicated by the Contractor in the progress report, wherever
applicable.
e) Quantitative programme which is termed as “Work Plan” shall be
updated regularly at a mutually agreed interval of time and Principal Contractor
shall submit the same for Purchaser’s approval keeping in view the
balance time available to execute the balance of activities. Once if
approved, subsequent progress report shall indicate the revised targets.
f) The Contractor shall furnish information on site activities viz. daily progress
report, weekly receipt of equipment, monthly erection plan, etc. The Contractor
has also to indicate resource deployment at site, highlights of critical
areas and constraints in the daily progress report once in a week.
g) Other information related to site activities as may be required by the
Purchaser, shall also be submitted by the Contractor.
h) The Contractor shall submit progress photographs in 5 copies and also in
a Compact Disc (CD) every month relating to the progress in sequence of work
of all major site activities. The Purchaser will arrange necessary permission
for the same.
97
Page 97 of 328
i) The progress report will also highlight inspection status. The Contractor shall
submit one copy of the inspection certificate duly signed by
representatives/authorized agencies after inspection along with the progress
report.
4.13 OVERALL TIME SCHEDULE
The overall time schedule shall be as follows:
1. The time schedule for the scope of work up to commissioning shall be 18
months.
2. The time schedule for PG test shall be one year after provisional take over
which shall be in concurrence with one year warranty period O & M.
3. After successful completion of PG test and final take over, O & M shall be
carried out for balance 10 years.
After completion of above overall time schedule, entire system shall be handed over
to NLCIL in working condition.
4.14 EXTENSION OF TIME
4.14.1 The Contractor shall not be allowed for any extension of time for completion
except in the following cases:
i) Force Majeure – As per details stated in the Contract.
ii) Major changes or substantial addition to work ordered by the Purchaser
adversely affecting the completion time.
iii) Any other circumstance of any kind whatsoever which may occur making
the Contractor entitled to an extension of time which, however, shall be in the
absolute discretion of the Purchaser.
4.14.2 The Contractor, upon the happening of any such event as stated above shall
immediately inform the Purchaser but nevertheless use constantly his best endeavors
to prevent or make good the delay and shall do all that may be reasonably
required to the satisfaction of the Purchaser to proceed with the work.
4.14.3 Request for extension of time shall be submitted by the Contractor in writing
and the Purchaser, based on the merit, shall consider the request and convey his
decision to the Contractor in writing within a reasonable time.
4.14.4 The Contractor shall not be eligible for any extension of time on account of any
delay in procurement of materials.
98
Page 98 of 328
SCHEDULE- 5
5.0 TAXES & DUTIES
5.1 GST/CD
(b)If there is any delay in supplies due to Contractor’s fault, the rate prevailing
on the scheduled date of completion of supplies will apply for the belated
supplies and upward revision after the scheduled date will be to the
Contractor’s account.
iii. Details of items, tariff no. with break-up values for despatches shall be
indicated separately in the PRICE SCHEDULE with rate of taxes in percentage
and total amount of taxes.
5.1.1 Customs Duty if any, shall be reimbursed at actuals subject to ceiling indicated in the
schedule of price. However, the purchaser shall not be liable to clear the goods at Port.
5.2 GST
The Contractor shall register with statutory / tax authorities wherever required.
i. The Supplier / Contractor has to provide a copy of the GST Registration Certificate and
also mention their GST Registration No. and Date in each of their invoices / bills without
fail. No invoice or bill will be paid unless the GST Registration No. is mentioned
therein.
99
Page 99 of 328
ii. While claiming the GST payment, the contractor should furnish the requisite details in the
invoice as per statutory requirements
5.5.1 The Purchaser shall not be liable towards income tax of whatever nature including
variations, arising out of this Contract, as well as tax liability of the Contractor and
his personnel. Deduction of tax at source at the prevailing rate shall be effected by the
Purchaser before remittance as a statutory obligation. The Certificate for the tax
deducted at source shall be furnished by the Purchaser indicating the amounts deducted.
5.6.1 Income tax and cess, if any payable by the Contractor's / Sub-contractor's employees
shall be paid by the said employees directly and the purchaser shall not be liable to pay
the income tax and cess payable by the employees of the Contractor/ Sub-Contractor
and the purchaser is not responsible for filing the tax return of the Contractor's
employees/experts. The Purchaser is not responsible for any tax arrears of Contractors
employees who have been associating their service, towards this scope of work on any
circumstances whether they are in service or otherwise.
5.7.1 For imported supplies on F.O.B. basis Customs Duty, Port handling, clearance and
forwarding if any, shall be reimbursed at actuals subject to ceiling indicated in the
schedule of price. However the purchaser shall not be liable to pay such charges in
respect of items supplied by the Contractor on free of charge basis. For the domestic
supplies all charges regarding customs duties, if any, shall be to the account of the
Contractor.
5.7.2 The Purchaser shall bear any statutory variation (±) in CD tariff rate (i.e. between the
CD rate prevailed at the time of submission of the offer and the CD rate paid at the time
of actual imports) and also the variation in CD due to exchange rate fluctuation (i.e
between the Exchange rate prevailed at the time of submission of offer and the
Exchange rate prevailed at the time of actual imports). The variation (±) in CD tariff
rate and variation in CD due to exchange rate fluctuation will be regulated based on the
Bill of Entries of actual imports made by the Contractor and the variation will be
considered for the imports made within the agreed delivery schedule.
100
The payment to the Contractor for the supply, services & works under the Contract
will be made by the Purchaser as per the guidelines and conditions specified herein.
All payments made during the Contract shall be on account payment only. The final
payment will be made on completion of all the works and on fulfillment by the
Contractor of all his liabilities under the Contract to the satisfaction of the
Purchaser.
The Purchaser will make progressive payment as and when the payment is due as
per the terms of payment set forth herein. Payment will become due and payable by
the Purchaser within 30 days from the date of receipt of Contractor's
bill/invoice/debit note by the Purchaser provided the documents submitted are
complete and correct in all respects, and is accompanied with a checklist
substantiating the pay ability of the bill /invoice.
6.2.1 Notwithstanding any amount becoming due and payable to the Contractor by the
Purchaser, the Contractor shall not be entitled to any interest on delayed / overdue
payments.
6.3.1 The Contractor shall prepare and submit to the Purchaser for approval, a detailed
Billing Break Up (BBU) of the Contract Price component wise. This Contract Price
BBU shall be interlinked with the agreed detailed PERT Network of the Contractor
setting forth his starting and completion dates for the various key phases of works
prepared. Any payment except the advance payment under the Contract shall be
made only after the BBU is approved by the Purchaser. The aggregate sum of the
BBU shall be equal to the Lumpsum Contract Price. BBU shall be reviewed,
updated and submitted to the Purchaser, by the Contractor as and when required.
6.3.2 The Contractor shall submit to the Purchaser his Sequential delivery schedule for all
the equipment correlated to the sequence of erection within 1 month from the date
of Letter of Award (LOA). Such schedules shall be in line with the agreed detailed
PERT for all phases of the works of the Contractor. If required such schedules shall
be reviewed, updated and submitted to the Purchaser, by the Contractor as and
when required.
101
6.4.2. Except Initial Advance, all other payments shall be made only after signing the
contract. The terms of payment for the various price components of the Contract
price are detailed herein:
6.5.1 All Advance Payment shall be made as per the terms of payment within 90 days
from the date of LOA for F.O.B. (imported portion) and Ex-works (Indian portion)
supply and Site preparation works on fulfilling the conditions specified below:
i) Acceptance of Letter of Award (LOA)
iv)
On resubmission of detailed L1 PERT chart and acceptance thereof by
PURCHASER.
6.5.2 FOR SUPPLY, ERECTION, CIVIL WORKS, TESTING & COMMISSIONING
OF PV SOLAR:
6.5.2.1 The payment of contract price shall be regulated and paid as per price quoted in
various schedules i.e Schedule-1 to Schedule-5 in Volume-I and also as per break up
details furnished in their BBU.
102
6.7.2 Twenty five percent (25%) price of each item quoted in Schedule -2 and Schedule-3
shall be paid after installation of each item on Unit rate basis and certification of the
same by the Project Manager.
6.7.3 Ten percent (10%) price of Schdule-2 and Schedule-3 of the plant and Equipment shall
be payable on installation of the entire Solar PV Power Plant and BESS and after it is
tested and commissioned and exporting power to the Grid and against issue of
Provisional Acceptance Certificate by the Project Manager.
6.7.4 The final five percent (5%) price of Schdule-2 and Schedule-3 of the plant and
Equipment shall be payable on successful completion of Performance and Guarantee
tests as specified and issue of Final Acceptance Certificate by the Project Manager.
6.7.5 100% of Transport charges under price Schedule-2 and Schedule-3 shall be paid along
with 50% / 60% equipment charge against documentary evidence subject to the
lumpsum ceiling quoted.
6.7.6 100% Insurance charges shall be paid against documentary evidence and submission of
the Insurance Policy subject to the lumpsum ceiling quoted.
6.8 Advance Payment for Civil and Structural works and Installation and
commissioning:
6.8.1 If the Contractor willing to avail Advance Payment for Civil and structural works
storage, Installation and commissioning shall be paid as follows:
(ii) on making ready the storage area before despatch of first consignment of supply
and
103
(i) after the Contractor moves the required construction plant and machinery and
commences at site the first installation activity as per PERT network subject to
certification by the engineer of the Purchaser and
6.9.1 80% / 85% (If advance payment avail)90% in case of not availing advance the price
of the installation services quoted in Schdule-4 shall be payable on pro-rata basis after
completion of installation of equipment of the Solar PV Power Plant and after it is
made ready for hooking up to the Grid
6.9.2 Five percent (5%) price of the installation services quoted in Schdule-4 shall be
payable on pro-rata basis after completion of installation of equipment of the Solar
PV Power Plant and after it is tested and commissioned and exporting power to the
Grid .
6.9.3 The final five percent (5%) price of the installation services quoted in Schdule-4 shall
be payable on successful completion of Performance and Guarantee tests as specified
and issue of final Acceptance Certificate by the Project Manager.
6.10.2 5% of price component of the Schedule -5 shall be payable after completion of work
and certification of the same by the Project Manager.
6.10.3 Five percent (5%) of price component of the Schedule-5 shall be payable on
successful completion of Performance and Guarantee tests as specified and issue of
Final Acceptance Certificate by the Project Manager.
6.11 Schedule-6 & Schedule-7 Operation and Maintenance charges for 10 years after
warranty period for Solar Power Plant and BESS respectively:
6.11.1 After completion of Warranty period as defined in bid documents, the Operation
and Maintenance charges quoted in Schedule-6 & Schedule-7 for 10 years shall be
payable on pro-rata on quarterly basis on the certification of work by the Project
Manager after completion of each quarter. The total compensation for shortfall in
net energy shall be calculated on annual basis and deduction if any shall be carried
out from the quarterly payment of the year.
6.12 The O&M during warranty period for Solar and BESS is the responsibility of the
Contractor.
104
6.12.1 One hundred percent (100%) of GST/ Customs Duty shall be reimbursed against
invoices to the Contractor subject to ceiling quoted upon receipt of equipment at
site along with the 50%/ 60%payment of the respective items.
6.12.2 GST for the Operation and maintenance services and other applicable services will
be paid along with progressive payment subject to ceiling quoted in the price
schedule after completion of the respective portion of the works.
6.13 GENERAL:
6.13.1 The advance Bank Guarantee will be reduced progressively on quarterly pro-rata
basis as evidenced by the copy of invoice duly passed /approved by the Purchaser
for which the Contractor shall submit the request letters with necessary supporting
calculations.
6.13.2 All payments shall be paid only against submission of complete and correct
invoices and documents by the Contractor duly certified by the Purchaser except as
otherwise specified in the Contract. Payment shall be due and payable by the
Purchaser within a reasonable period, which will not normally exceed one month
from the date of receipt of complete and correct invoices. If it is not payable the
invoice will be returned to the Contractor stating the reasons for rejection within a
month from the date of receipt by the Purchaser.
6.13.3 All payments shall be released directly by the Purchaser to the Contractor except as
otherwise provided in the contract. If as per provisions of Contract any payments
are made directly by the Purchaser to the Associates, such payments shall constitute
a proper discharge of Purchaser's obligations for such payments to the Contractor.
6.13.4 All the progressive payments mentioned above shall be made by the Purchaser
based on the satisfactory progress of work as agreed.
6.13.6 The Purchaser reserves the right to encash Bank Guarantees if sufficiently
convinced of negligence and lack of dedication to work on the part of the
Contractor.
6.13.7 If the Contract is terminated due to default of the Contractor, the ‘Mobilization
Advance’ pay would be deemed as interest bearing advance at the rate applicable to
cash credit facility prevailing at the time of issue of NIT to be compounded
quarterly.
6.13.8 For delays in scope within the agreed time schedule, interest at the prevailing rates
applicable to cash credit facility will be charged on the unadjusted portion of
advance paid.
105
Inland transport charges for imported portion from Chennai port to the site will
be borne by the Contractor.
100% of the transport charges for indigenous supplies on pro-rata basis shall be
reimbursed on production of invoices and documentary evidence along with
50%/60% supply invoices after receipt of materials at site. However, the total
claim shall not exceed the ceiling quoted in the price schedule for inland
transport.
6.17 Insurance Charges
6.17.1 The Insurance premium in respect of Marine and inland transport shall be
prepaid by the Contractor and got reimbursed subject to production of
documentary evidence including the copy of respective policies.
6.17.2 The reimbursement of premium can be made at periodical intervals as per the
policy’s conditions. The premium receipt issued by the Insurance company shall
have to be produced for claiming reimbursement. After all the instalments of
premium are paid, the difference between lump sum insurance charges indicated
in the contract and the premium actually reimbursed to the contractor on
documentary evidence as referred above, shall be paid to the contractor on the
basis of invoices from the contractor, without supporting documents to
106
The payment shall be made direct to the Contractor by the Purchaser through
e-payment only. Payment, will become due and payable by the Purchaser
within a reasonable period which will not exceed one month from the date
of receipt of Contractor's bill / invoice / debit note by the Purchaser provided
the documents submitted are complete and correct in all respects. If it is not
payable the invoice will be returned to the Contractor stating the reasons for
rejection within a month from the date of receipt by the Purchaser.
6.19.2 Imported supply
In case of stage payment (50%/60%) in foreign currency for the supplies of
Equipment, the Purchaser will establish irrevocable Letter of Credit in favour of
the Contractor through the Purchaser’s Bank in India and payment will be
effected through Letter of credit. The Balance payment for supplies will be
made through direct disbursement method.
The payment for indigenous supplies, the inland transportation, insurance and
other lump sum charges shall be made direct to the Contractor by the Purchaser
wherever applicable through E-payment.
6.20.1 The Purchaser shall open an irrevocable Letter of Credit at the State Bank of
India or any principal Bank of NLC and advice through its foreign branches/
correspondents to be specified by the Contractor in due course. The Letter of
Credit will be kept valid for 3 months covering 50%/60% value of equipment.
Letter of Credit will be opened after the receipt of information from the
contractor regarding readiness of the shipment.
6.20.2 The bank charges incurred in India shall be to the account of the Purchaser and
all bank charges incurred in abroad shall be to the Contractor's account. Should
the Contractor need confirmation of LC, charges there of is to be borne by the
Contractor. The Purchaser will bear all bank charges in India for establishing/
renewal of L/Cs with State Bank of India or any principal Bank of NLC.
However, if extension of Letter of Credit become necessary for delay due to
107
a) Certificate by the Contractor that no further shipment will be made and the
supplies are completed in all respects.
b) Summary of all invoices for the equipment also showing the amount due and
amount claimed/received.
Two copies of each of the above documents shall be sent simultaneously to the Head of
Unit Finance / Neyveli.
In addition, 10 copies in each of the above documents shall be sent direct to the
GENERAL MANAGER/CONTRACTS after effecting the shipments, within 7 days
from the date of shipment.
108
iii. In respect of last consignment in addition to the above documents the following
certificate and document shall also be furnished.
a) Certificate by the Contractor/that no further shipment will be made and the supplies
are completed in all respects.
b) Summary of all invoices for the equipment also showing the amount due and
amount claimed/received.
i. Contractor’s signed commercial invoice, one copy showing 100% FOB price for
equipment/components supplied, deductions of 85% of payment already received,
and the balance 10% amount falling due provisional take over.
ii. Purchaser’s Certificate of successful completion of commissioning of the equipment.
The following documents in original shall be sent by Registered Post to the Head of the
unit Finance/New Project/CO,the General Manager/PBD as applicable within 10 days
from the date of despatch to enable the Purchaser to make progressive payment to the
indigenous supplier.
6.21.7 For 50%/60% payment
i. Certificate of receipt of materials at site as certified by the Purchaser-1 original +
two copies.
ii. Supply invoice -1 original + 2 copies
ix. In respect of last consignment in addition to the above documents the following
certificate and document shall also be furnished:
a. Certificate by the Contractor that no further supplies will be made and supplies
are complete in all respects.
b. Summary of all invoices for the equipment also showing the amount due and
amount claimed / received.
a) Certificate by the Contractor that no further supplies will be made and the
supplies are completed in all respects.
b) Summary of all invoices for the equipment also showing the amount due and
amount claimed/received.
110
111
CONTRACT SPECIFICATIONS
The Technical Specifications issued along with the Tender Specifications duly
modified and up-dated based on the changes/modifications agreed between the
Purchaser and the successful Bidder shall constitute Schedule-8 "Contract
Specifications" of this Contract and shall form an integral part of the Contract for all
purposes.
112
PG test report
On successful completion of demonstration of performance guarantees for the
plant following shall be supplied:
a) Performance Guarantee Evaluation Report.
b) Operation log book for 1 year
c ) Power export log for 1 year
114
10.1.1 GENERAL
i) All the Bank Guarantees shall be irrevocable. The Bank Guarantee shall be from
any Nationalised Bank or any Scheduled bank in India (other than Bank of China)
authorised by Reserve Bank of India to issue such Bank Guarantee. Except bid
guarantee, all bank guarantees are to be furnished directly by the banker to
NLCIL by RPAD/Courier to the following address:
ii) The Bank Guarantee shall be furnished as per respective format prescribed by the
Purchaser and shall be submitted on Non-judicial stamp paper of value Rs.80/-
and the stamp paper shall be in the name of the Bank.
iii) All the Bank Guarantees shall be payable on first demand, without demur,
irrespective of any dispute between the Bank and the Contractor to the
Purchaser without any condition or dispute whatsoever.
iv) The Contractor shall arrange to keep the several bank guarantees referred to
herein valid for the requisite duration by making timely request to the Bank or
Banks concerned. All the extension for Bank Guarantees also shall be on non-
judicial stamp paper of value Rs.80/- obtained in the name of Bank. All charges
connected with the bank guarantees shall be to the account of the
CONTRACTOR.
vi) The Purchaser shall have the right to encash the Bank Guarantees for non-
compliance of any or all the terms and conditions of the contract and also in terms
of the Joint Deed of Undertaking, if any, which the Contractor may enter into
along with other parties with the purchaser. Non -compliance of any or all the
terms and conditions of the contract by the Contractor, will be intimated to the
Contractor, specifying the reason with supporting documents, before encashment
of the Bank Guarantee.
vii) Confirmation of BG under the through “Structured Financial Messaging
System (SFMS)”
a. The Bank Guarantee issued by the issuing Bank of Behalf of Bidder/ Contractor
/ Supplier in favour of “Name of Company” shall be in paper form as well as
issued under the “Structured Financial Massaging System. The details of
beneficiary for issue of BG under SFMS platform is furnished below:-
115
Unit/ Contracts
Area/ Division branch /Corporate
Office
Beneficiary Bank, Branch & Address State Bank of India
Block-2,
Neyveli – 607801
IFSC Code SBIN0000958
The above particulars are to be incorporated by the issuing bank properly while issuing
BG under SFMS mode to avoid any problem in future.
The advance stipulated in the payment terms shall be made to the CONTRACTOR
by the PURCHASER subject to the CONTRACTOR providing a bank guarantee
for 110% of the advance amount as per the stipulations and on acceptance of
the said bank guarantee. This bank guarantee shall be valid till completion of the
supplies/ commissioning / scope of work, as the case may be with a grace period of 2
months thereafter.
ii) As a contract security, the successful Bidder to whom the work is awarded, shall be
required to furnish Contract Performance Bank Guarantee(s) covering the warranty
period in the form stipulated subject to approval of the Owner in-favour of the
Owner within 30 (Thirty) days from the date of Letter of Award. The Guarantee
amount shall be equal to 10% (Ten Percent) of the total contract price for supply
and services excluding O&M charges for 10 years and it shall guarantee the
faithful performance of the contract in accordance with the terms and conditions
specified in these documents and specifications. The guarantee shall be valid till the
expiry of 90 days beyond the actual date of final take over or after the end of the
116
iii) The PURCHASER shall have the right to encash the Contract Performance
Guarantee in full or part thereof for non-compliance of any or all the terms and
conditions of the contract and to recover any Liquidated Damages under the
contract as well as against defects in the equipment/ shortfall in guaranteed
generation and for failure to comply with any of the warranty obligations as
enumerated in the Contract.
iv) In case of part encashment, CPG shall be valid for the remaining period as per
contract for the balance amount or for the period as requested by owner.
v) The Contract Performance Bank Guarantee value shall be suitably adjusted towards
the variation in the Contract price.
vi) The 90% of Contract Performance Bank Guarantee value will be allowed to reduce
on the expiry of warranty period or after date of final take over or after the end of
the warranty period or after the end of the Performance Guarantee test whichever is
later subject to submission of CPG for O&M Contract. The remaining 10% of the
CPG value will be retained till the completion of 10 years O&M Contract and will
be returned to the contractor without any interest after 90 (ninety) days from
completion of 10 years O&M contract period.
If the delay is not purely attributable to the Contractor and requires detailed analysis,
the amount equivalent to the maximum L.D leviable would be withheld from the
running bills as indicated in Schedule 6. In case the Contractor faces difficulty in
cash flow and progress of work, an amount up to 90 % of the withheld amount shall
be released to the Contractor against a Bank Guarantee as per the format enclosed for
100 % of the withheld amount, if requested by the Contractor. The Bank Guarantee
shall be initially valid for 6 months and shall be suitably extended by the Contractor
till the LD issue is settled.
i) The final five percent (5%) payment of price indicated in Schdule-1, 2 &3 and final
five percent(5%) payment of the price indicated in Schdule-4 shall be payable on
successful completion of Performance Guarantee tests as specified and issue of
Final Acceptance Certificate by the Purchaser.
ii) In case of delay in Performance Guarantee test for reasons not attributable to the
Contractor, the final five percent (5%) payment of price indicated in
Schdule-1,2&3 and final ten percent (5%) payment of the price indicated in
Schdule-4 will be released at the latest by 6 months from the scheduled date of
completion of Performance Guarantee test against furnishing of RMBG and
acceptance of the same by the Purchaser.
117
iv) The Purchaser shall have the right to encash the RMBG for deficiency and default
in supplies and also for the recovery of L.D. in terms of the Contract.
ii) In case of bidder who undertakes to execute the Contract on the basis of a
consortium agreement the bidder shall furnish an Agreement/Letter of consent/Joint
deed of under taking in which the partners are jointly and severally liable to the
Owner for successful performance of the contract. The same shall be backed up
with a financial guarantee by the consortium partner/s directly furnished (format
enclosed vide Appendix-B) to the Purchaser for a value of 5% of their respective
portion of the contract value to be made by the consortium partner and initially
valid for 15 months beyond the scheduled date of Performance Guarantee Test
and shall be extended suitably to be valid till the expiry of 90 days beyond the
actual date of completion of performance test or after the end of the warranty
period, whichever is later.
iii) In case of bidder is Joint Venture Company, each partner of JV company shall
furnish Financial Back-up Bank Guarantee for a value of 5% of their respective
portion of the contract value to be made by the JV partner/s and initially valid
for 15 months beyond the scheduled date of Performance Guarantee Test and
shall be extended suitably to be valid till the expiry of 90 days beyond the actual
date of completion of performance test or after the end of the warranty period,
whichever is later.
v) The Purchaser shall have the right to encash the financial backup bank
guarantee for non-compliance of any or all the terms and conditions of the Joint
Deed of Undertaking as well as for shortfall in guaranteed output as enumerated in
the Contract.
10.2 INSURANCE
10.2.1 The Bidder shall at his own expense take out necessary insurance to-the supplies,
transit, personnel and all other related to the satisfaction of the NLCIL including all
third party risks as detailed below:
118
i) All Risk Insurance: The policy shall cover all risks and escalations, and revisions
without ceiling.
ii) Cargo Insurance: For supplies, the policy shall insure the goods originating from
the Contractor's / Supplier's warehouse to Plant's warehouse and up to completion
of erection and commissioning. This will be inclusive of supplies to and from
warehouse / factory of intermediate processors / suppliers. This policy will also
cover the replacement items, if any.
iii) Third Party Liability Insurance: The policy shall cover third party liability. The
third party liability shall cover the loss / disablement of human life (persons not
belonging to the Contractor) and also cover the risk of damages to others'
materials/equipment/ properties during construction, erection and commissioning
at site. The value of third party liability for compensation for loss .of human life
or partial / full disablement shall be of required statutory value but not less than
Rs.2 lakh per death, Rs.1.5 lakh per full disablement and Rs.1 lakh per partial
disablement and shall nevertheless cover such compensation as may be awarded
by a Court of Law in India or abroad and cover for damage to others' equipment
/surrounding property as approved by NLCIL.
iv) Automobile Liability Insurance: Covering use of vehicles / mobile equipment
used by the Contractor or its Sub Contractors (whether or not owned by them) in
connection with the-execution of the Contract
v) Contractor shall ensure that where applicable, its Sub-Contractor(s) shall take out
and maintain in effect adequate insurance policies for their personnel and
vehicles and for work executed by them under the Contract, unless such Sub-
Contractors are covered by the policies taken out by the Contractor.
119
i) The Contractor wherever applicable after proper painting, pack and crate all
equipments in such a manner to protect them from deterioration, damage, pilferage
etc., during transportation to Site. The Contractor shall be held responsible for any
damage caused due to improper packing.
ii) The Contractor shall notify the Purchaser about the date of each shipment from his
works and expected date of arrival at site furnishing the weight, dimensions and
contents of each packing.
iii) The Contractor shall be responsible for making necessary loading, unloading and
handling arrangements from port / his Works to site.
10.4 Marking
i) The equipment shall be packed suitably for marine transport /inland transport as
the case may be. The packages shipped by the foreign supplier shall be addressed
to the General Manager / Contracts, Corporate office, NLC India Limited,
Neyveli-607 801, Tamil Nadu, India.
ii) The Indian suppliers shall address the packages to the General Manager/PBD,
NLC India Limited, Neyveli- 607 801, Tamilnadu, India.
iii) In case of packaging and grating the under noted markings shall be stencilled , or
otherwise conspicuously marked on to opposite sides - case No, Gross Wt./ Nett
Wt., Order No. and Date.
iv) The contractor shall keep in each case the packing list fully item wised to show
case No., content, Gross Wt./ NettWt,. Machinery, Contract/ Supply Order No.
and date.
121
i) The Contractor shall inform the Purchaser about the programme of despatches as
contemplated by the Contractor to enable the Purchaser to have an effective
follow up. Part shipment is permitted. Transhipment is prohibited.
ii) The Contractor shall furnish a list of items with value of goods imported through
Ports in India and furnish detailed information.
iii) The terms of the contract shall be on FOB / CIF basis. The Contractor shall make
shipping arrangements on behalf of the Purchaser upto destination port (Port Blair at
Andaman). The Contractor shall give notice about readiness of cargo for shipment to the
Purchaser. While giving such notice of readiness of shipment, the Contractor shall
furnish the following to the Purchaser.
a. Contract No.
b. Brief description of material to be shipped.
c. Gross weight.
d. Net weight.
e. Dimensions of the Packages to be shipped.
f. Number of Packages.
g. Import Licence No., if any and L/C particulars.
.
iv) If situation warrants, the contractor can arrange air freight with prior approval of
the Purchaser. In such case the increase in freight and customs duties thereof
shall be to the account of Contractor.
v) All shipments will be done through approved vessels as per the `Institute of
London Classification Clause' of the Institute of London Underwriters as given
below.
iv) The Contractor shall send the following shipping documents With the Cargo -
Quality certificate (one copy) Packing list (6) copies comprises 2 copies in case
No.1 of each consignment of the goods and 4 copies in each case (three inside
the Box and one copy in a special packet at the outer side of the Box).
i) All Ex. works supplies with in India shall be handled and transported
including inter-carting, storage at any intermediate point from the shops of the
manufacturers' works to site/ stores through accredited/registered, reliable
dependable transport carriers.
ii) The Contractor shall assume complete, full and total responsibility for inland
transport of these items and charges thereof shall be indicated separately as a
fixed lump sum in the schedule of prices.
iii) The Contractor shall thoroughly study the transportation routes and available
transportation facilities and the Contractor shall take full responsibility for
transport of all supplies.
iv) For FOB items i.e., items imported, the inland transport from ports in India to
project site shall be the scope of the Contractor.
123
ii) The Purchaser shall not be responsible for any detention enroute of any
consignment arranged through any mode of transport and shall not also bear any
charges thereon. It shall be the responsibility of the Contractor to make
expeditious alternative arrangement, ensuring safety to the consignment in the
event of any such detention and the Contractor shall bear the complete charges
thereon.
10.6 Licences
10.6.1 Import Licence
For any portion of the supplies to be imported by the Contractor for incorporation in
manufacture of the equipment, the Contractor shall arrange the necessary import
including arrangements of licenses and Foreign Exchanges as may be required, on his
own.
124
Equipment furnished shall be complete in every respect with all mountings, fittings,
fixtures and standard accessories normally provided with such equipment, and/or
needed for erection, completion and safe operation of the equipment. They may
not have been specifically detailed in the respective specifications, unless included in
the list of exclusions. All similar standard components/parts of similar standard
equipment provided, shall be interchangeable with one another. The Contractor shall
not be eligible for any extra payment in respect of such mounting, fixtures and
accessories.
The Purchaser has the option to engage a consultant to follow up the progress, inspect
and examine the work during design, manufacture, supply, erection, functional tests
and safety checks, take over test and output guarantee tests or for any other purpose
in connection with the supply and services covered by this Contract. The Contractor
shall properly coordinate with the consultant in the execution of the contract.
The Contractor shall supply all drawings and documents to the Purchaser / Consultants
as per technical specification.
i) The Contractor shall be responsible for and shall pay for any alterations of the
works due to any discrepancies, errors or omissions in the drawings,
documents or other particulars supplied by him, whether such drawings or
particulars have been approved by the Purchaser or not, provided that such
discrepancies, errors or omissions be not due to inaccurate information or
particulars furnished to the Contractor by the Purchaser. If any dimensions
figured upon a drawing or plan differ from those obtained by scaling the drawing
or plan, the dimensions as figured upon the drawing or plan, shall be taken as
correct.
ii) The Contractor shall take all corrective measures arising out of discrepancies,
errors and omissions in drawings and other information within the time schedule
and without extra cost to the Purchaser.
iii) The Contractor shall also be responsible for any delay and/or extra cost if any, in
carrying out engineering and site works by other agencies arising out of
discrepancies, errors and omissions as well as of any late revision/s of drawings
and information submitted by the Contractor.
126
10.14.1 The Purchaser or his authorised agent / Consultant shall have the right of inspecting
and testing the contract work or any part thereof at any stage during the manufacture
and the Contractor on demand from the Purchaser shall carry out such tests in
appropriate manner in the presence and free of charge to Purchaser. Should the
Contractor himself not be in a position to carry out the tests, he shall, on the
Purchaser's demand prepare specimen and samples and send them at his own cost to
such testing stations as the Purchaser may specify and the cost of the test so effected
shall be to the Contractor's account. However, cost pertaining to the Purchaser's
inspection personnel shall be borne by the Purchaser.
10.14.2 The inspection, examination or testing carried out by the Purchaser shall not relieve
the Contractor from any of his obligations under this Contract. The inspection
procedure will be discussed and finalised.
127
128
10.16.2 Maps, layouts and photographs of the work or any part thereof including its
surrounding regions showing vital installation for national security of Owners
country shall not be published or disclosed to the third parties or taken out of the
country without prior written approval of the Owner and upon execution of secrecy
agreements satisfactory to the Owner with such third parties prior to disclosure.
10.16.3 The provisions of para 10.16.1 & 10.16.2 shall not apply to information:
i) Which at the time of disclosure are in the public domain- or which later on
become part of public domain through no fault of the party concerned.
ii) Which were in the possession of the party concerned prior to disclosure to him
by the other party, or
iii) Which were received by the party concerned after the time of disclosure without
restriction on disclosure or use from a third party who did not acquire such
information directly or indirectly from the other party.
10.17 REJECTION OF DEFECTIVE WORKS OR OTHER INSTALLATION
10.17.1 If the Contract work or any portion thereof, before it is accepted or taken over, be
defective or fails to fulfill the requirements of the Contract, the Owner shall give the
CONTRACTOR notice setting forth particulars of such defects or failure and the
CONTRACTOR shall forthwith make good the defects or alter the same to make it
comply with the requirements of the Contract. Should he fail to do so within a
reasonable time the Owner may reject and replace at the risk and cost of the
CONTRACTOR the whole or any portion of the work as the case may be, which is
defective or fails to fulfill the requirements of the Contract. However, such rejection/
replacement by the Owner shall not absolve the CONTRACTOR of his
responsibilities under this Contract.
129
10.17.4 The CONTRACTOR shall not be entitled to any extension of time or extra cost for
rejection as per 10.17.1 and 10.17.2 above.
10.18 NEGLIGENCE
10.18.1 If the CONTRACTOR shall neglect to execute the work with due diligence or
expedition or shall refuse or neglect to comply with any reasonable order given to
him in writing by the Owner in connection with the work or shall contravene the
provisions of Contract, the Owner may give notice in writing to the CONTRACTOR
calling upon him to make good the failure, neglect or contravention complained of
within such time as may be deemed reasonable and in default of this compliance
with the said notice, the Owner without prejudice to his rights under clause 10.18.2
hereto, may rescind or cancel the Contract as provided in Cl.10.36 holding the
CONTRACTOR liable for the damages that the Owner may sustaining this behalf.
The making good of the failure, neglect or contravention hereunder will be governed
by clause 10.17.1. In addition the Contractor shall refund all the amounts paid to him
by the Purchaser for all such work which may become in fructuous due to such
cancellation.
10.18.2 Should the CONTRACTOR fail to comply with such notice within a reasonable
period from the date of serving the Notice thereof in the case of failure, neglect or
contravention capable of being made good within that time or otherwise within such
time as may be reasonably necessary for the same making good then and in such case
without prejudice to the Owner's right under clause 10.18.1 hereto the Owner shall
have at his option the right to take the work wholly or in part out of the
CONTRACTOR's hands and may complete the work envisaged in the contract either
departmentally or by awarding a fresh Contract at a reasonable price with any other
persons to execute the same or any part thereof and provide other materials, tools,
tackle or labour for the purpose of completing the work or any part thereof
10.18.3 In such event the Owner shall, without being responsible to the CONTRACTOR for
fair wear and tear of the same, be entitled to seize and take possession and have free
use of all materials, tools, tackle or other things which may be on the site for use at
any time in connection with the work to the exclusion of any right of the
CONTRACTOR over the same and the Owner shall be entitled to retain and apply
and balance sum which may otherwise be then due on the Contract by him to the
CONTRACTOR or such part thereof as may be necessary to the payment of the cost
of execution of such work as aforesaid
10.18.4 If the cost of executing the work as aforesaid shall exceed the balance due to the
CONTRACTOR and the CONTRACTOR fails to make good the deficit the said
materials, "tools, tackle, construction plant or other things, the property of the
CONTRACTOR as may not have been used up in the completion of the works, may
be sold by the Owner and the proceeds applied towards the payment of such
difference and the cost of and incidental to such sale, any outstanding balance
130
10.19.1 The Contractor shall hold the equipments handed over to him by Purchaser, as
trustee on behalf of the Purchaser without having any lien or charge against the
equipment at any stage. For any loss or damage to the equipment and material till
these are finally taken over by Purchaser, the Contractor shall immediately
replace/repair the loss or damaged equipment entirely at his cost irrespective of the
extent and/or time of realisation of claims by him from the insurer/underwriters.
10.19.2 The title of ownership and property to all goods materials equipment etc. originating
in India shall pass to the purchaser as per the terms and conditions of this contract
after the Contractor has effected the despatch of the same to Project site and the
Contractor has prepared necessary documentation for handing over the same to
NLCIL's authorised representative provided however, such passing of titles of
ownership and property to the Purchaser shall not in any way absolved, dilute or
diminish the responsibility and obligations of the Contractor under this Contract
including loss or damage and all risks which shall vest with the Contractor till the
successful commissioning and final Take over as per the Contract.
10.20 Indemnity
10.20.1 The Contractor shall at all times indemnify and keep indemnified the Purchaser
against all claims which may be made against the Purchaser in respect of any
infringement of any rights protected by patent registration of design of trade mark. In
this connection, the Purchaser shall pass on all claims made against him to the
Contractor for settlement.
10.20.2 The Contractor assumes responsibility for and shall indemnify and save harmless the
Purchaser from all liability, claims, costs, expenses, taxes and assessments including
penalties, punitive damages, attorney's fees and court costs which are or may be
required to be paid by the Purchaser arising from any breach of the Contractor's
obligations under the Contract or for which the Contractor has assumed
responsibilities under the Contract including those imposed under any Contract local
or national law or laws, or in respect to all salaries, wages or other compensation or
all persons employed by the Contractor or his Associate(s)/Sub-Contractors or
suppliers in connection with the performance of any work covered by the Contract.
The Contractor shall execute, deliver and shall cause his Sub- Contractor and
suppliers to execute and deliver, such other further instruments and to comply with
all the requirements of such laws and regulation as may be necessary there under to
conform and effectuate the Contract and to protect the Purchaser.
131
ii) The said contractor hereby agreed to maintain the Solar PV Power Plant as per
conditions of O&M agreement and his possession in trust for the Purchaser as
their property until such time the O&M period is completed and the plant is
handed over back to the authorised representatives of the Purchaser as per the
terms of the Agreement.
iii) The said contractor further agree to hold the Purchaser harm less and free from all
liabilities for all losses, damages, etc., arising from any cause, whatsoever to the
material while in his possession, and further under takes to indemnify and
reimburse the Purchaser to the extent of loss or damage caused to the materials or
any loss or any claims to the Purchaser in respect of the said material during
O&M period.
132
133
Signature of the
Over lapping
Contractor/
Contractor
Hindrance
Purchaser
Purchaser
Duration
Delay by
Remedy
Sl. No.
10.25.2 The details of Hindrance Register along with the relevant factors will be taken into
consideration for determining extension of time to the contract /LD.
10.26.1 Definition: “Force Majeure” means any act, circumstance or event or a combination
of acts, circumstances and events which wholly or partially prevents or delays the
performance of obligations arising under this Agreement if such act, circumstance or
event is not reasonably within the control of and not caused by the fault or
negligence of the non-performing Party, and provided that such act, circumstance or
event is in one or more of the following categories:
iv) Civil disturbance including riot, terrorism, rebellion, sabotage and communal
clashes, war, civil commotion, Acts of God or the public enemy.
v) Piracy.
137
Provided that a Force Majeure act, circumstance or event shall not include economic
hardship, equipment failure/breakdown, or power failure/breakdown, or failure in
water supply other than as specifically set forth above.
If either Party is rendered wholly or partially unable to perform its obligations under
this Agreement because of a Force Majeure act, circumstance or event, that Party
shall be excused from whatever performance is affected by the Force Majeure act,
circumstance or event to the extent so affected, provided that
(a) Within five (5) Business Days after the occurrence of the inability to perform
due to a Force Majeure act, circumstance or event, the non-performing Party
provides a written notice to the other Party of the particulars of the occurrence,
including an estimation of its expected duration and probable impact on the
performance of its obligations hereunder, and continues to furnish periodic
reports with respect thereto, every 7 days, during the period of Force Majeure;
(b) the non-performing Party shall use all reasonable efforts to continue to perform
its obligations hereunder and to correct or cure as soon as possible the act,
circumstance or event constituting the Force Majeure;
(c) The suspension of performance shall be of no greater scope and no longer
duration than is reasonably necessitated by the Force Majeure act, circumstance
or event;
(d) The non-performing Party shall provide the other Party with prompt notice of
the cessation of the Force Majeure act, circumstance or event giving rise to the
excuse from performance and shall thereupon resume normal performance of
obligations under this Agreement with utmost promptitude;
(e) The non-performance of any obligation of either Party that was required to be
performed prior to the occurrence of a Force Majeure act, circumstance or event
shall not be excused as a result of such subsequent Force Majeure act,
circumstance or event.
(f) The occurrence of a Force Majeure act, circumstance or event shall not relieve
either Party from its obligations to make any payment hereunder for
performance rendered prior to the occurrence of Force Majeure or for partial
performance hereunder during periods of Force Majeure;
(g) The Force Majeure act, circumstance or event shall not relieve either Party from
its obligation to comply with Applicable Laws;
138
10.27.1 If any action in court is brought against the Purchaser or any officer or agent of
the Purchaser for the failure, omission or neglect on the part of the Contractor to
perform any acts, matters, covenants or things under the Contract or for damage or
injury caused by the alleged omission or negligence on the part of the Contractor,
his agents, representatives or his sub-Contractors or in connection with any claim
based on lawful demands of sub-Contractors, workmen, suppliers or employees,
the Contractor shall in all such cases indemnify and keep the Purchaser and/or his
representatives harmless from all losses, damages, expenses or decrees arising out
of such action.
10.27.2 The Purchaser shall have full power and right at his discretion to defend or
compromise any suit or pay claims or demand brought or made against him as
aforesaid whether pending or threatened, as he may consider necessary or
desirable and shall be entitled to recover from the Contractor all sums of money
including the amount of damages and compensation and all legal costs, charges
and expenses in connection with any compromise or award which shall not be
called into question by the Contractor and shall be final and binding upon him. If
the Purchaser decides not to defend or decides to compromise any suit or pay claim,
the Contractor will be kept advised before such action by the Purchaser.
10.29.1 All maps, plans, drawings, specifications, schemes and the subject matter contained
therein and all other information given to the Contractor by the Purchaser in
connection with the performance of the Contract Work shall be held confidential by
the Contractor and shall remain the property of the Purchaser and shall not be used
or disclosed to third parties by the Contractor for any purpose other than for which
they have been supplied or prepared. The Contractor may disclose to third parties,
upon execution of secrecy agreements, such part of the drawings, Specifications or
information if such disclosure is necessary for the performance of the Work.
139
10.31.1 Neither the inspection by the Purchaser or the Consultant or any of their officials,
employees, or agents nor any order by the Purchaser or the Consultant for
payment of money or any payment for or acceptance of the whole or any part of the
`works' by the Purchaser or the Consultant, nor any extension of time, nor any
possession taken by the Purchaser shall operate as a waiver of any provision of the
`Contract' or of any power herein reserved to the Purchaser or any rights to damages
herein provided nor shall any waiver of any breach in the `Contract' be held to be a
waiver of any other or subsequent breach.
140
10.32.3 In any case in which the Contractor has received instruction from the Purchaser
as to the requirement of carrying out the altered or additional substituted work
which will in the opinion of the Contractor, involve a claim for additional
payments, the Contractor shall immediately and in no case later than 30 days after
receipt of the instructions advise the Purchaser to that effect. But the Purchaser
shall not become liable for the payment of any charges in respect of any such
variations, unless the instructions for the performance of the same shall be
confirmed in writing by the Purchaser within 30 days of such advice after mutual
discussion and agreement.
10.32.4 If any variation in the works results in reduction of Contract price the parties shall
agree so in writing to the extent of any change in the price before the Contractor
proceeds with the change.
10.33.1 Royalties and fees for patents covering materials, articles, apparatus, devices,
designs, equipment or processes used in the works shall be deemed to have been
included in the Contract Price. The Contractor shall satisfy all demands that may be
made at any time for such royalties or fees and he alone shall be liable for any
damages or claims for patent infringements and shall keep the Purchaser,
indemnified in that regard. The Contractor shall at his own cost and expenses
defend all suits or proceedings that may be instituted for alleged
infringements of any patent involved in the works and, in case of an award of
damages the Contractor shall pay for such award. In the event of any suit or other
proceedings instituted against the Purchaser, the same shall be defended at the
cost and expenses of the Contractor who shall also satisfy/comply any decree,
order or award made against the Purchaser. But, it shall be understood that no
such machine, plant, work, material or thing has been used by the Purchaser for
any purpose or any manner other than that for which they have been furnished and
installed by the Contractor and specified under these specifications. Final
payment to the Contractor by the Purchaser will not be made while any such suit or
claim remains unsettled. In the event of any apparatus or equipment or any
part thereof furnished by the Contractor is in such suit or proceedings held to
constitute infringement, and its use is enjoined, the Contractor shall at his option,
and at his own expense, either procure for the Purchaser the right to continue the
use of the said apparatus/ equipment or part thereof, replace the equipment or
modify it so that it does not constitute infringement.
10.33.2 The Contractor shall indemnify and keep indemnified the Purchaser, his successors
or assigns for and against any and all claims, suits, damages,, losses, actions,
demands, costs, charges, royalties and expenses arising from or for infringement.
141
10.35.2 In addition, such action by the Purchaser as aforesaid shall not relieve the Contractor
of his liability to pay Liquidated Damages for delay in completion of `Works'.
10.35.3 The termination of the `Contract' under this clause shall not entitle the Contractor to
reduce the value of the Performance Guarantee nor the time thereof. The
Performance Guarantee shall be valid for the full value and full period as originally
stipulated in the `Contract'.
10.35.4 In case the Contractor defaults in timely furnishing of engineering data specified in
the Contract and this delays the performance by the Purchaser his part of the
Contract and as a consequence the Contract execution schedule is delayed the
responsibility for such delay will be that of the Contractor and he will become
liable for all damages as per Contract.
10.36.1 The Purchaser may suspend the work in whole or in part at any time by giving
Contractor notice in writing to such effect stating the nature, the date and the
anticipated duration of such suspension.
10.36.2 On receiving the notice of suspension as above, the Contractor shall stop all such
work which the Purchaser has directed to be suspended with immediate effect.
10.36.3 The Purchaser may at anytime cancel the suspension notice for all or any part of
suspended work by giving written notice to the Contractor specifying the part of
work to be resumed and the effective date of suspension withdrawal. The Contractor
shall resume the suspended work as expeditiously as possible after receipt of such
withdrawal of suspension notice.
10.36.4 In the event of suspension of work due to reasons attributable to (i) the Contractor or
(ii) Force Majeure Conditions the Purchaser will not be liable to the Contractor for
any cost-direct or indirect damage or loss or idle labour caused by such period of
suspension of work. The Purchaser shall not be liable to Contractor for any payment
towards watch & ward and any other expenditure, in such circumstances. If the
suspension is for reason attributable to the Purchaser, the Purchaser shall pay to the
Contractor, the cost as reimbursement to be agreed mutually.
10.37.1 The Purchaser reserves the right to terminate the Contract either in part or in full due
to reason other than those mentioned under clause entitled Contractor's Default. The
Purchaser shall, in such an event, give 15 (fifteen) days notice in writing to the
Contractor of his decision to do so.
145
10.37.3 In the event of such a termination, the Contractor shall be paid compensation,
equitable and reasonable dictated by the circumstances prevalent at the time of
termination. No consequential damages shall be payable by the Purchaser to the
Contractor in the event of termination.
10.37.4 If the Contractor is an individual or a Proprietor concern and the individuals or the
proprietor dies and if the Contractor is a partnership concern and one of the
partners dies, then unless the Purchaser is satisfied that the legal representatives of
the individual Contractor or the Proprietor of the proprietary concern and in the
case of partnership, surviving partners, are capable of carrying out and
completing the Contract the purchaser shall be entitled to cancel the Contract as to
its incomplete part without being in any way liable to payment of any
compensation to the estate of deceased Contractor and/ or to the surviving
partners of the Contractor's firm on account of the cancellation of the Contract.
The decision of the Purchaser that the legal representatives of the deceased
Contractor or surviving partners of the Contractor's firm cannot carry out and
complete the Contract shall be final and binding on the parties. In the event of
such cancellation the purchaser shall not hold the estate of the deceased
Contractor and/ or the surviving partners of the estate of the deceased Contractor
and/ or the surviving partners of the Contractor's firm liable to damages for not
completing the Contract.
10.38.1 In the event any of the Contractor or his Sub- Contractors, personnel, agents, sub-
agents, assistants, or other employees shall be guilty of any misconduct or be
incompetent or insufficiently qualified or negligent in the performance of their duties
or it is undesirable for any administrative reasons for such person to be employed,
the Contractor, if so directed, shall immediately remove such person or persons from
employment thereon. Any person or persons so removed shall not again be
employed in connection with this Contract without the written permission of the
Purchaser. Any person so removed shall immediately be replaced by a qualified and
competent substitute at the Contractor's cost and expenses. Should the Contractor be
requested to repatriate any person he shall do so and shall bear all costs and charges
in connection there with.
10.39 AMENDMENT
10.39.1 Any amendment to the terms of this Contract (including Schedules & Annexures)
shall be made in writing by both parties hereto and shall specifically state that it is an
amendment to this Contract.
10.39.2 No amendment as per above Clause shall have any effect until the Purchaser has
received such consent in writing (including that of the Contractor) as may be
necessary under and in terms of the loan/financial Agreements.
146
10.40.2 If any such notice is delivered by hand, it shall be duly acknowledged and if given
by telegram, telex, fax it shall be confirmed by Registered Letter within seven days
of the date of such notice. Either party shall by notice in writing inform the other
party of any change of its address as stated under Clause 10.40.1 for receiving such
notices.
10.40.3 Date of notices under Clause 10.40.1 shall be the date of receipt of such notice by
the receiving party.
The parties agree to use reasonable efforts to resolve all disputes equitably and in
good faith.
10.43.1.1 If any dispute between the Contractor and the Purchaser arises it shall in the
first instance be referred in writing to the Purchaser, who shall endeavour to
resolve the dispute amicably and render a decision within 30 days. The period of
30 days shall be reckoned from the date of intimation of the dispute is received by
the Purchaser.
10.43.1.2 Save as hereinafter provided, in respect of a dispute so referred, the decision of the
Purchaser shall be final and binding upon the Parties until the completion of the
147
10.43.2 Conciliation
10.43.2.1 If the party is dissatisfied with the decision rendered by the Purchaser, or if the
Purchaser omits or declines to render a decision within the said period of 30 days,
then within a further period of 30 days, the dissatisfied Party shall require by a
notification that the dispute be referred to Conciliation in the manner as per
the ‘NLCIL Conciliation Rules’, copy of which is available with the NLCIL
offices and the Bidders/ Contractors shall abide by the NLCIL Conciliation Rules’
for resolving any dispute arising out of this contract. Such a notification shall be in
writing and it shall be duly served on the other party. Failure to invoke the
Conciliation within the time stipulated shall debar the party from seeking
reference to Conciliation.
10.43.2.2 Except as otherwise provided in this clause, any dispute arising out of or
relating to this agreement, or the breach, termination or validity thereof, shall
be settled by Conciliation in accordance with ‘NLCIL Conciliation Rules’. The
Conciliation shall be held at Neyveli or Chennai or in a place with in India
mutually agreed by the parties. The Conciliation proceedings shall be conducted,
and the award shall be rendered in English. The award shall state the reasons
upon which it is based.
Number of Conciliators
For thesum of Provisional Claim & Provisional Counter Claim
The Provisional Claim / Counter claim amount shall be indicated by the respective
parties while initiating / concurring for conciliation. However, number of
conciliators in the Settlement Advisory Committee will not be modified, even if
the Sum of Actual Claim and Actual Counter Claim amount vary from the sum of
Provisional Claim and Counter Claim amounts. Appointment of Conciliators:
Conciliator(s) will be appointed by CMD of NLC India Limited.
10.43.2.4 The Contract agreement / Purchase order conditions and the rights and obligations
of the Parties, shall remain in full force and effect during the Conciliation
proceedings. Supplies and / or services under the Contract shall, if reasonably
possible, continue during the Conciliation proceedings.
10.43.2.5 For the purpose of this clause, the term ‘dispute’ shall include a demand or
difference of any kind whatsoever, arising out of the Contract and respecting the
performance of the Contract, whether during the Contract period including
extensions if any, and whether before or after termination, abandonment or breach
of the Contract. (except as to any matter, the decision of which is specifically
otherwise provided for in any of these conditions).
10.43.2.6 Only in case of failure to resolve the dispute through Conciliation, Arbitration can
be resorted to or Judicial remedy can be sought for.
148
10.43.2.8 Anything not found included in the ‘NLCIL Conciliation Rules’, but necessary to
conduct the conciliation proceedings will be dealt with as per the provisions of the
‘Arbitration and Conciliation Act 1996 -Part-III’ or as per the statutory provisions
modified from time to time.
10.44.2 Between NLCIL & Contractor other than a Public Sector enterprise
10.44.2.1 If either party is dissatisfied with the decision rendered by the Purchaser, or if
the Purchaser omits or declines to render a decision within the said period of 30
days, then within a further period of 30 days, the dissatisfied Party may require
by a notification that the dispute be referred to arbitration in the manner
hereinafter provided. Such a notification shall be in writing and it shall be duly
served on the other party. Failure to invoke the arbitration within the time schedule
shall debar the party from seeking reference to arbitration.
10.44.2.2 Except as otherwise provided in this clause, any dispute arising out of or
relating to this agreement, or the breach, termination or validity thereof, shall be
finally settled by arbitration in accordance with the Arbitration and Conciliation
Act 1996 (the ``Act''). The arbitration shall be held at Neyveli or Chennai, Tamil
Nadu. The arbitration proceedings shall be conducted, and the award shall be
rendered in English. The award shall state the reasons upon which it is based.
10.44.2.3 There shall be three arbitrators of whom each Party shall appoint one. The Party
requesting that the dispute be referred to arbitration shall, within 30 days of the
notification in terms of Clause 10.44.2.1, appoint an arbitrator as also call upon
the other Party to appoint an arbitrator within 30 days. The two arbitrators so
appointed shall, within 30 days of the date on which the second of them is
149
10.44.2.4 The agreement and the rights and obligations of the Parties, shall remain in full
force and effect pending the award in any arbitration proceedings. Supplies and/ or
services under the Contract shall, if reasonably possible, continue during arbitration
proceedings.
10.44.2.5 For the purposes of this clause, the term `dispute' shall include a demand or
difference of any kind whatsoever, arising out of the Contract and respecting the
performance of the Contract, whether during the Contract period including
extensions if any, or after completion, and whether before or after termination,
abandonment or breach of the Contract (except as to any matter, the decision of
which is specifically provided for in any of these conditions).
10.44.2.6 The Arbitrators shall publish a speaking award which shall be binding on both the
parties. The party in whose favour the award is passed shall be entitled to recover
the entire cost of arbitration from the other party. The Arbitrators shall indicate the
above in their award clearly.
10.45.1 The Contractor shall expressly undertake full responsibility for the quality
of supplies, timely deliveries as per the stipulated schedule of deliveries the
faultless operation of the equipment, the warranty for the design of the
equipment and manufacture of the complete equipment, including the Indian
portion of supplies free of any defects and faults.
10.45.2 In the event of replacements becoming necessary on account of short deliveries and
wrong supplies on account of short landing, loss/ damages during transit, storage,
erection and commissioning the Contractor shall take special steps to make such
replacements free of cost for timely commissioning of the equipment. The charges
towards, freight, insurance, port handling clearance customs duty and all other
incidentals including transport to site in respect of such replacements will be to the
account of the Contractor. The Contractor shall take special steps to arrange for
most expeditious manufacture and supply of these items to enable timely
commissioning of the equipment.
10.45.3 Equipment furnished shall be complete in every respect with all mountings,
fittings, fixtures and standard accessories normally provided with such
equipment, and/or needed for erection, completion and safe operation of the
equipment. They may not have been specifically detailed in the respective
specifications, unless included in the list of exclusions. All similar standard
components/parts of similar standard equipment provided, shall be
interchangeable with one another. The Contractor shall not be eligible for any extra
payment in respect of such mounting, fixtures and accessories.
150
No interim payment certificate of the Purchaser or the Consultant nor any sum
paid on account by the Purchaser nor any extension of time for execution of
the `works' granted by the Purchaser or the Consultant shall affect or prejudice the
rights of the Purchaser against the Contractor or relieve the Contractor of his
obligations for the due performance of the Contract or be interpreted as
approval of the `Works' done or of the equipment furnished and no certificate
shall create liability in the Purchaser to pay for alterations amendments,
variations or additional `Works' not ordered in writing, by the Purchaser or
discharge the liability of the Contractor for the payment of damages whether
due, ascertained, or certified or not or any sum against the payment of which
he is bound to indemnify the Purchaser nor shall any such certificate nor the
acceptance by him of any sum paid on account or otherwise affect or prejudice
the rights of the Contractor against the Purchaser.
ii) to give such Receiver, Liquidator or other person the option of carrying out the
Contract subject to his providing a guarantee up to an amount to be agreed for
the due and faithful performance of the Contract.Not withstanding the provision
of Cl.10.48 (i) in the event of Indian contractor undergoing liquidation or being
dissolved, become bankrupt as described above the principle contractor shall
directly assume the responsibilities of Indian contractor to the extent not
performed.
10.49.1 After acceptance of the Letter of Award, the Purchaser shall draft the Contract and
shall provide one copy to the Contractor for checking. The Contract, in two
originals, prepared on a non judicial stamp paper shall be signed by the holders of
power of attorney on a suitable date and time but within 60 (Sixty) days of the
acceptance of the Letter of Award.
151
10.49.3 Thereafter, within another 30 (Thirty) days, the Contractor shall supply 25
(Twenty five) copies of the Contract Agreement, to the Purchaser free of cost.
10.50.1 The term `Contract' or `Contract Documents' shall mean and include the following
which shall be deemed to form an integral part of the Contract.
10.50.1.1 ‘Notice Inviting Tender’ and `Invitation to Bid’ issued by the Purchaser.
10.50.1.2 The Bid proposal offered by the bidder, including all correspondences relation to
the decision on the deviations, and on the clarifications sought for, exchange
between the bidder and their purchaser prior to the award of the Contract.
10.50.1.3 All the materials, literature, data and information given by the Contractor along
with his bid or later.
10.50.1.4 Minutes of all discussion between the Bidder and the Purchaser.
10.50.1.5 `Letter of Award’ issued by the Purchaser and its acceptance by the Contractor.
10.50.1.6 Contract agreement, general and technical terms and conditions and all other
documents exchanged.
10.50.1.8 Any agreed variation to the conditions of the documents and specifications and
special terms and conditions of Contract, if any.
10.50.2 In the event of any ambiguities and discrepancies between the above mentioned
documents, the decision of the Purchaser shall be final and binding.
10.51 JURISDICTION
The Civil Courts having ordinary original civil jurisdiction over Andaman &
Nicobar Islands shall have exclusive jurisdiction in regard to all questions of
disputes of whatever nature including the arbitration proceedings, if any arising
under the Contract with the Purchaser.
This Contract shall be governed and construed according to the Indian Laws and
Regulations.
10.53 SAFETY
The Contractor shall abide by the safety Code for Contractors which is enclosed.
152
The Contractor shall abide by the General Conditions for Erection & Civil Works,
which is enclosed.
10.55 GENERAL
10.56 CORRESPONDENCE
All further correspondence in connection with this offer shall be addressed to:
The General Manager/Contracts
Corporate Office
NLC India Limited,
Block-1, Neyveli – 607 801.
Fax: 04241-252026/252645/252646
Cuddalore District, Phone: 04142 – 252215/252210
Tamil Nadu, INDIA
153
154
155
1.0 General
1.1 The following shall supplement the conditions already contained in the other parts of
these specifications and documents and shall govern that portion of the work of this
‘Contract’ to be performed at ‘site’.
1.2 The Contactor upon issue of LOA shall, in addition to a Project Coordinator, nominate
another responsible officer as his representative at site suitably designated for the
purposes of overall responsibility and co-ordination of the Works to be performed at
site. Such person shall function from the site office of the Contractor during the
execution of ‘Contract’. This representative shall have full technical capability and
complete administrative and financial powers to expeditiously and efficiently execute
the work under this ‘Contract’.
1.3 The Contractor shall proceed with the work to be performed under this ‘Contract’ and
each and every part and detail thereof, in the best and most workman like manner by
engaging qualified, careful and efficient workers, and do the several parts thereof, at
such time and in such order as the Purchaser/Consultant may direct, and finish such
work in strict conformity with the plans, drawings and/or specifications, and any
changes, modifications or amplifications thereof made by the Purchaser/Consultant.
1.4 The Contractor shall not sell, assign, mortgage hypothecate or remove equipment or
materials or materials which have been installed or which may be necessary for the
completion of the ‘Contract’ without the written consent of the Purchaser.
2.1 The Contractor shall ensure compliance with all statutes, laws, rules and regulations of
the Central or State Government or any other authority such as the Workmen’s
Compensation Act 1923, Payment of Wages Act, Minimum Wages Act 1948,
Employees State Insurance Act, Employees Provident Fund Act, etc. and any and all
statutory modifications thereof in connection with employees engaged by him or his
Sub-Contractors in the work.
2.2 The Contractor shall conform to the provisions of MNRE, DISCOMS, Andaman &
Nicobar Islands Electricity authorities, Factory Laws, Indian Electricity Act and rules
made there under, and any other acts of legislature relating to the work and to the
regulations and bye-laws of any authority and of any water, lighting and other
companies and/or authorities with whose systems the plant/structure is proposed to be
connected and shall before making any variations from the drawings or specifications
that may be necessitated by so conforming, giving to the Purchaser/Consultant written
notice, specifying the variations proposed to be made and the reason for making it and
apply for instructions thereof.
2.3 The Contractor shall arrange to give all notice required by the said Acts, Regulations or
Bye-laws to be given to any Authority or to any Public Officer and pay all fees that
may be properly chargeable in respect of the ‘Works’ and lodge the receipts with the
156
2.4 All registration and statutory inspection fees, if any, in respect of his work pursuant to
this ‘Contract’ shall be to the account of the Contractor. However, any registration,
statutory inspection fees and any other statutory laws and its amendments from time to
time during erection in respect of the plant and equipment ultimately to be owned by
the Purchaser shall be to the account of the Purchaser. Should any such inspection or
registration need to be re-arranged due to the fault of the Contractor or his Sub-
Contractor, the additional fees for such inspection and/or registration shall be borne by
the Contractor.
The Purchaser shall have lien on all equipment including those of the Contractor
brought to the site for the purpose of erection, testing and commissioning of the plant.
The Purchaser shall continue to hold the lien on all such equipment throughout the
period of ‘Contract’. No material brought to the site shall be removed from the site by
the Contractor and/or his Sub-Contractor’s without the prior written approval of the
Purchaser/Consultant.
5.1 The provisions of the clause entitled Inspection, Testing and Inspection Certificates
shall also be applicable to the erection portion of the ‘Works’. The Purchaser /
Consultant shall have the right to re-inspect any equipment (though previously
inspected and approved by him, at the Contractor’s works) before and after the same
are erected at Site. If by the above inspection, the Purchaser / Consultant rejects any
equipment, the Contractor shall make good for such rejections either by replacement or
modifications / repairs as may be necessary, to the satisfaction of the Purchaser /
Consultant. Such replacements will also include the replacements or re-execution of
such of those works of other Contractor’s and/or agencies, which might have got
damaged or affected by the replacements or re-work done to the Contractor’s work.
5.2 Any work, which proves faulty, shall be corrected by the Contractor without delay. The
fact that the Purchaser / Consultant or their representatives have not pointed out faulty
work or work which is not in accordance with plans and specifications shall not relieve
the Contractor from correcting such work as directed by the Purchaser / Consultant
without additional compensation.
5.3 When finished work is taken down for the purpose of re-inspection, the Contractor shall
bear the entire expenses incident thereto in the event that said work is found to be
defective. The Purchaser shall pay the cost incident thereto in the event that the work
inspected is found to be in accordance with the ‘Specification’. In the latter case, the
replacing of the covering or the making good of any of the parts removed shall be paid
for by the Purchaser at the Contract price for the class of work done and the uncovering
157
5.4 The Purchaser / Consultant, their representatives and employees shall, at all reasonable
times, have free access to the works and/or to the workshops, factories or other places
where materials are being prepared or constructed for the ‘Contract’ and also to any
place where the materials are lying or from where they are being obtained, and the
Contractor shall give every facility to the Purchaser / Consultant and his representatives
for inspection and examination and test of the materials and workmanship even to the
extent of discontinuing portions of the work temporarily, or of uncovering or taking
down portions of finished work.
6.1 Suitable access to and possession of the site shall be afforded to the Contractor by the
Purchaser in reasonable time.
6.2 The Purchaser shall have the necessary foundations to be provided by him ready, as per
the agreed schedule for the execution of the individual phases of ‘Works’.
6.3 In the execution of the ‘Works’, no persons other than the Contractor or his duly
appointed representative, Sub-Contractor and workmen shall be allowed to do work on
the site, except by the special permission, in writing of the Purchaser / Consultant or his
representative.
6.4 Access to the site at all times shall be accorded to the Purchaser / Consultant and other
authorized officials and statutory Public Authorities. Nevertheless, the Contractor shall
not object to the execution of the work by other Contractors or tradesmen whose names
shall have been previously communicated in writing to the Contractor by the Purchaser
/ Consultant and afford them every facility for the execution of their several functions
simultaneously with his own.
7.1 The Contractor shall establish a Site Office at the site and keep posted an authorized
representative for the purposes of the ‘Contract’. Any written order or instruction of the
Purchaser / Consultant or his duly authorized representative, shall be communicated to
the authorized representative of the Contractor at the Site Office and the same shall be
deemed to have been communicated to the Contractor at his legal address.
158
8.1 The Contractor shall cooperate with all other Contractors or tradesmen of the
Purchaser, who may be performing other works on behalf of the Purchaser and the
workmen who may be employed by the Purchaser and doing work in the vicinity of the
‘Works’ under the ‘Contract’. The Contractor shall also so arrange to perform his work
as to minimize, to the maximum extent possible, interference with the work of other
Contractors and his workmen. Any injury or damage that may be sustained by the
employees of the other Contractors and the Purchaser due to the Contractor’s work
shall promptly be made good at his one expense. The Purchaser/Consultant shall
determine the resolution of any difference or conflict that may arise between the
Contractor and other Contractors or between the Contractor and the Workmen of the
Purchaser in regard to their Work. If the ‘Works’ of the Contractor is delayed because
of any acts or omissions of another Contractor, the Contractor shall have no claim
against the Purchaser on that account.
8.2 The Purchaser/Consultant shall be notified promptly by the Contractor of any defects in
the other Contractor’s works that could affect the Contractor’s ‘Works’. The
Purchaser/Consultant shall determine the corrective measures, if any, required to rectify
this situation after inspection of the ‘Works’ and such decisions by the
Purchaser/Consultant shall be binding on the Contractor. If a part of the Contractor’s
work depends, for proper execution, upon the work of any other Contractor, the
Contractor shall inspect and promptly report in writing to the Purchaser/Consultant any
defect in such work of other Contractors that render it unsuitable for proper execution
of the work under this ‘Contract’. His failure to so inspect and report shall constitute an
acceptance of ‘Others’ work as fit and proper for the reception of his work, except as to
defects which may develop in the work of ‘Others’ after the proper execution of the
work. To ensure proper execution of his sub-sequent work, the contractor shall inspect
work already in place and shall at once report to the Purchaser/Consultant any
discrepancy between the executed work and the drawings.
159
10.1 The Contractor shall keep the Purchaser/Consultant informed in advance regarding his
field activity plans and schedules for carrying out each part of the ‘Works’. Any review
of such plan or schedule or method of work by the Purchaser/Consultant shall not
relieve the Contractor of any of his responsibility towards the field activities. Such
reviews shall also not be considered as an assumption of any risk or liability by the
Purchaser/Consultant or any of his representatives and no claim of the Contractor will
be entertained because of the failure or inefficiency of any such plan or schedule or
method of work reviewed. The Contractor shall be solely responsible for the safety,
adequacy and efficiency of plant and equipment and his erection methods.
10.2 The Contractor shall have the complete responsibility for the conditions of the work site
including the safety of all persons employed by him or his Sub-Contractor and all the
properties under his custody during the performance of the work. This requirement
shall apply continuously till the completion of his ‘Contract’ and shall not be limited to
normal working hours. The construction review by the Purchaser/Consultant is not
intended to include review of Contractor’s safety measures in, on or near the work-site,
and their adequacy or otherwise.
10.3 The work so far as it is carried out on the Purchaser’s premises shall be carried out at
such time as the Purchaser may approve consistent with the construction schedule and
so as not to interfere unnecessarily with the conduct of the Purchaser’s business and the
Purchaser will give the Contractor all reasonable facilities for carrying out the work.
12.1 The Contractor shall submit to Purchaser/Consultant on the first day of every week, a
man-power schedule for the next week, detailing the man-power scheduled skill-wise
and area-wise.
12.2 The Contractor shall also submit to the Purchaser/Consultant on the first day of every
month, a manpower report of the previous month detailing the number of persons
scheduled to have been employed and actually employed, skill-wise and the areas of
employment of such labour.
13.1 The Contractor shall have total responsibility for protecting his ‘Works’ till it is finally
accepted by the Purchaser/Consultant. No claim will be entertained by the
Purchaser/Consultant for any damage or loss to the Contractor’s ‘Works’ and the
Contractor shall be responsible for the complete restoration of the damaged ‘Works’ to
its original condition to comply with the specifications and drawings. Should any such
damage to the Contractor’s ‘Works’ occur because of other party not under his
supervision or control, the Contractor shall make his claim directly with the party
concerned. If disagreement or conflict or dispute develops between the Contractor and
the other party or parties concerned regarding the responsibility for damage to the
160
13.2 The Contractor and his Sub-Contractors shall be responsible during work for protection
of the work, which has been completed by Others. Necessary care shall be taken to see
that no damage to the same is caused by his own men during the course of execution of
their work.
13.3 All other work completed or in progress as well as machinery and equipment that are
liable to be damaged by the Contractor’s work shall be protected by the Contractor and
such protection shall remain and be maintained until its removal is directed by the
Purchaser.
13.4 The Contractor shall effectively protect all the works from action of weather and from
damages or defacement and shall cover finished parts where required for their thorough
protection. Face work shall be perfectly clean and free from defects.
13.5 The work shall be carried out onto completion without damage to any work and
property adjacent to the area of his work, to whomsoever it may belong, without
interference with the operation of their existing machines or equipment.
13.6 The Contractor shall provide the necessary temporary roadways, footways, guards as
may be rendered necessary by reason of his work, for the protection and
accommodation of foot passengers of other traffic of the Purchaser or occupier of
adjacent property and of public. The Contractor shall at the times provide sufficient
temporary barriers, notice boards and lights to protect and warn the public and post
necessary watchman to guard the site and equipment. He shall take all precautions
necessary and shall be responsible for the safety of the work to be performed by him.
The Contractor shall also observe and display Safety First signs and shall have proper
safety and fire protection equipment.
13.7 Adequate lighting at and near all the storage, handling, fabrication, pre-assembly and
erection sites for properly carrying out the work and for safety and security shall be
provided by the Contractor. The Contractor’s work area would be adequately lighted
during nighttime also. The Contractor should also engage adequate
electricians/wiremen, helpers, etc., to carry out and maintain these lighting facilities. If
the Contractor fails to provide all the above listed facilities, the Purchaser may provide
such facilities as he may deem necessary and charge the cost thereof to the Contractor.
In any case the Contractor shall be liable for all damages and consequences arising out
of his neglect in this regard.
161
14.3 All traveling expenses including provisions of all necessary transport to and from site,
loading allowances and other payments to the Contractor’s employees shall be the sole
responsibility of the Contractor.
14.4 The hours of work on the site shall be decided by the Purchaser and the Contractor shall
adhere to it. Working hours for each employee will normally be eight (8) hours per day.
14.5 The Contractor’s employees shall wear identification badges while on work at site.
14.6 The Contractor shall ensure that he pays his men regularly their wages, overtime and
other compensations. The attendance register and the wage register shall be submitted
to the Purchaser for verification at regular intervals. The Contractor shall also furnish
the Purchaser at fortnightly intervals a certificate that he has paid all the dues to his
workmen. In case such payment is not made regularly by the Contractor, the Purchaser
will be in his right to make such payments and deduct the same from the Contractor’s
progress payments.
14.7 In case the Purchaser becomes liable to pay any wages or dues to the labour or to any
Government agency under any of the provisions of the Minimum Wages Act,
Workmen’s Compensation Act or any other law due to act of omission of the
Contractor, the Purchaser may make such payments and shall recover the same from
the Contractor’s bills.
14.9 In connection with the performance of work under this ‘Contract’, the Contractor shall
agree not to discriminate because of race, religion, colour or national origin. It is also
expected that the Contractor in his selection of personnel will give due regard to their
ability to co-operate with the Purchaser/Consultant. Suggestions and recommendations
made by the Purchaser/Consultant relating to the work and coordination thereof are to
be carefully and courteously considered.
16.1.1 The Contractor shall provide at his own expense, all the construction equipment, false
work, erection tools, machine tools, power tools, tackles, hoists, cranes, derricks,
162
16.1.2 The Contractor shall also furnish all necessary expandable devices like anchors,
grinding and abrasive wheels, raw plugs, hacksaw blades, taps, dies, drills, reamers,
chisels, files, carborandum stones, oil stones, wire brushes, necessary scaffolding,
ladders, wooden planks, timbers, sleepers and consumable material like welding
electrodes, oxygen, acetylene, argon, lubricating oils, greases, cleaning fluids, cylinder
oil, graphite powder and flakes, fasteners, gaskets, temporary supports, stainless steel
shims of various thickness as required, cotton waste, cheese cloth and all other
miscellaneous supplies of every kind required for carrying out the work under the
‘Contract’.
16.1.3 The Contractor shall provide all reasonable facilities including tools, personnel, etc. and
ensure coordination with the Purchaser / Consultant and the Sub-Contractor’s erection
supervisors to enable them to carry out all supervision, measurements, checks, etc. in a
satisfactory manner.
16.1.4 The Contractor shall not dispose of, transport or withdraw any tools, tackles, equipment
and material provided by him for the ‘Contract’ without taking prior written approval
from the Purchaser/Consultant, and the Purchaser/Consultant at all times shall have
right to refuse permission for disposal, transport or withdrawal of tools, tackles,
equipment and material if, in his opinion, the same will adversely affect the efficient
and expeditious completion of the ‘Project’.
16.2 Communication
The Contractor will make his own arrangement for all his communication needs such as
telephone, email etc. at his Site Office. The Purchaser will assist the Contractor in
getting the above facilities, in case he finds difficulty.
16.3 First-aid
16.3.1 The Contractor shall provide necessary first-aid facilities for all his employees,
representatives and workmen at the site.
16.4 Cleanliness
16.4.1 The Contractor shall be responsible for keeping the entire area allotted to him clean and
free from rubbish, debris etc. during the period of ‘Contract’. The Contractor shall
employ enough number of special personnel to thoroughly clean his work area at least
once in a day. All such rubbish and scrap material shall be stacked or disposed in a
place to be identified by the Purchaser / Consultant. Materials and stores shall be so
163
16.4.2 Similarly, the offices of the Contractor shall be kept clean and neat to the entire
satisfaction of the Purchaser/Consultant. Proper sanitary arrangements shall be
provided by the Contractor in the work areas and office of the Contractor.
17.1 All the ‘Works’ shall be performed to the lines, grades and elevations indicated on the
drawings. The Contractor shall be responsible to locate and layout the ‘Woks’. Basic
horizontal and vertical control points will be established and marked by the Purchaser /
Consultant at site at suitable points. These points shall be used as datum for the
‘Works’ under the Contract. The Contractor shall inform the Purchaser / Consultant
well in advance of the times and places at which he wishes to do work in the area
allotted to him, so that suitable datum points may be established and checked by the
Purchaser / Consultant to enable the Contractor to proceed with his ‘Works’. Any work
done without being properly located may be removed and/or dismantled by the
purchaser/Consultant at Contractor’s expense.
17.2 Where the Purchaser/Consultant had already established the base lines and bench marks
adjacent to the various sections of work, the same must be carefully preserved by the
contractor, and in case of their unnecessary destruction by him or any of his employees,
these will be re-established by the Purchaser/Consultant at the Contractor’s expense.
17.3 The Contractor shall be responsible for the accuracy of all dimensions within the
various sections of the work according to the figures of dimensions in the drawings.
19.0 SECURITY
Watch towers shall be provided by the Contractor around the periphery of Solar PV
Power Plant and shall be designed and constructed considering the safety and security
requirements of the Solar PV Power Plant as per the Technical Specification.
The Purchaser/Consultant will mark-out the boundary limits of access roads, parking,
spaces, storage and construction areas for the Contractor and the Contractor shall not
tress-pass areas not so marked out for him. The Contractor shall be responsible to
ensure that none of his personnel move out of the areas marked out for his operations.
In case of such a need for the Contractor’s personnel to work out of the areas marked
out for him, the same shall be done only with the written permission of the
Purchaser/Consultant.
164
21.1 In cases where the performance of the erection work by the Contractor affects the
operation of the system facilities of the Purchaser/Consultant or other agencies such
erection work of the Contractor shall be scheduled to be performed only in the manner
stipulated by the Purchaser/Consultant and the same shall be acceptable at all times to
the Purchaser/Consultant. The Purchaser/Consultant may impose such restrictions on
the facilities provided to the Contractor such as electricity, water etc. as he may think fit
in the interest of the Purchaser and the Contractor shall strictly adhere to such
restrictions and co-operate with the Purchaser/Consultant. It will be the responsibility
of the Contractor to provide all necessary temporary instrumentation and other
measuring devices required during start-up and operation of the equipment systems,
which are erected by him. The Contractor shall also be responsible for consumables
required for the equipment furnished and erected by him, so as to make such equipment
ready for operation. The Contractor shall be responsible for supplying such
consumables.
21.2 The Contractor at all times shall work in coordination with the Purchaser’s Consultants
and offer them all reasonable facilities to become familiar with the erection, operation
and maintenance of the equipment.
21.3 In respect of observations of local rules, administrative orders, working hours and the
like, the Contractor and his personnel shall cooperate with the Purchaser.
22.0 COMMISSIONING
The ‘Commissioning’ of the equipment supplied and erected by the Contractor shall be
the responsibility of the Contractor as detailed in Tender specification. The Contractor
shall provide in addition, test instruments, calibrating devices etc. and the labour
required for the successful performance of these tests. If it is anticipated that the above
tests may prolong for a long time, the Contractor’s workmen required for the above
tests shall always be present at site during such tests.
23.1 All the equipment furnished under the Contract and arriving at site shall be promptly
received, unloaded and transported and stored in the storage spaces by the Contractor.
23.2 The Contractor shall be responsible for examining all the shipment and notify the
Purchaser/Consultant immediately of any damage, shortage, discrepancy etc. for the
purpose of Purchaser’s / Consultant’s information only. The Contractor shall submit to
the Purchaser / Consultant every week a report detailing all the receipts during the
week. However, the Contractor shall be solely responsible for any shortages or damage
in transit, handling and/or in storage and erection of the equipment at the site (Any
demurrage, wharfage and other such charges claimed by the transporters, railways etc.
shall be to the account of the Contractor).
23.3 The Contractor shall maintain an accurate and exhaustive record detailing out the list of
all equipment received by him for the purpose of erection and keep such record open
for the inspection of the Purchaser/Consultant at any time.
165
23.5 All electrical panels, control gears, motors and such other devices, shall be properly
dried by heating before they are installed and energized. These equipments shall be
protected against moisture ingress and corrosion during storage and periodically
inspected. Heavy rotating parts in assembled condition shall be periodically rotated to
prevent corrosion due to prolonged storage and shall also be periodically inspected.
23.6 All critical electrical equipments shall be tested for insulation resistance at least once in
three months from the date of receipt till the date of commissioning and a record of
such measured insulation values shall be maintained by the Contractor. Such records
shall be open for inspection by the Purchaser/Consultant.
23.7 The Contractor shall ensure that all the packing materials, and protection devices used
for the various equipments during transit and storage are removed before the
equipments are installed.
23.8 The consumables and other supplies likely to deteriorate due to storage must be
thoroughly protected and stored in a suitable manner to prevent damage or deterioration
in quality by storage.
23.9 All the materials stored in the open or dusty locations must be covered with suitable
weatherproof and flameproof and flame proof covering material wherever applicable.
23.10 If the materials belonging to the Contractor are stored in areas other than those
earmarked for him, the Purchaser/Consultant will have the right to get it moved to the
area earmarked for the Contractor at Contractor’s cost.
23.11 The Contractor shall be responsible for making suitable indoor storage facilities to store
all equipment which require indoor storage. Normally all the electrical equipments shall
be stored in the closed storage space. The Purchaser/Consultant in addition, may direct
the Contractor to move certain other materials which in his opinion will require indoor
storage, to indoor storage areas which the Contractor shall strictly comply with.
23.12 The Contractor shall arrange for periodic inspection of material/equipment in his
custody until taken over by the Purchaser and shall carry out all protective and
preservative measures required thereupon.
23.13 The Contractor shall also keep a check on the deliveries of the equipment/material
covered in his scope of erection and shall advise the Purchaser well in advance
regarding possible hold-ups in his work due to expected delays in delivery of
equipment, to enable the Purchaser to expedite the deliveries if supplier is different
from the Contractor.
166
23.15 All the I& C electronic equipment shall be stored in Air-Conditioned storage.
24.1 The field activities of the Contractor working at site will be coordinated by the
Purchaser/Consultant and the Purchaser’s/ Consultant’s decision shall be final in
resolving any disputes or conflicts regarding scheduling and co-ordination of work.
Such decision by the Purchaser/Consultant shall not be a cause for extra compensation
or extension of time for the Contractor.
24.2 The Purchaser/Consultant shall hold weekly meetings at site with Contractor. The
Contractor shall attend such meetings and take notes of discussions during the meeting
and the decisions of the Purchaser / Consultant and shall strictly adhere to those
decisions in performing his ‘Works’. In addition to the above weekly meetings, the
Purchaser / Consultant may call for other meetings and in such a case the Contractor, if
called, will also attend such meetings.
24.3 Time is the essence of the ‘Contract’ and the Contractor shall be responsible for
performance of his Works in accordance with the specified construction schedule. If at
any time, the Contractor is falling behind the schedule, he shall take necessary action to
make good for such delays by increasing his work force or by working overtime or
otherwise accelerate the progress of the work to comply with the schedule and shall
communicate such action in writing to the Purchaser / Consultant satisfying that his
action will compensate for the delay. The Contractor shall not be allowed any extra
compensation for such action.
24.4 The Purchaser / Consultant shall however not be responsible for provision of additional
labour and/or materials or supply or any other services to the Contractor except for the
co-ordination work between various Contractors as set out earlier.
25.0 FIELD OFFICE RECORDS
25.1 The Contractor shall maintain at his site Office up-to-date copies of all drawings,
specifications and other Contract Documents and any other supplementary data
complete with all the latest revisions thereto. The Contractor shall also maintain in
addition the continuous record of all changes to the above Contract Documents,
drawings, specifications, supplementary data, etc. effected at the field and on
completion of his total assignment under the ‘Contract’ shall incorporate all such
changes on the drawings and other Consultant data to indicate as installed conditions of
the equipment furnished and erected under the ‘Contract’. Such drawings and
Engineering, data shall be submitted to the Purchaser / Consultant in required number
of copies. A record of all readings taken during the testing and inspection shall be
maintained by the Contractor. This shall be signed by the erection supervisor and the
Purchaser/Consultant as a token of their acceptance of the same. All such records shall
be handed over to the Purchaser on completion of the ‘Works’.
167
26.1 The Contractor shall bring to site all equipment, components, parts, materials including
construction equipment, tools and tackles for the purpose of the ‘Works under
intimation to the Purchaser/Consultant. All such goods shall, from the time of their
being brought vest in Purchaser, but may be used for the purpose of the ‘Works’ only
and shall not on any account be removed or taken away by the Contractor without the
written permission of the Purchaser/Consultant. But the Contractor shall nevertheless
be solely liable and responsible for any loss or destruction thereof and damage thereto.
26.2 The Purchaser shall have a lien on such goods for any sum or sums, which may at any
time, be due or owing to him by the Contractor, under, in respect of or by reasons of the
‘Contract’. After giving a fifteen (15) days notice in writing of his intention to do so,
the Purchaser shall be at liberty to sell and dispose of any such goods, in such manner
as he shall think fit including public auction or private treaty and to apply the proceeds
in or towards the satisfaction of such sum or sums due as aforesaid.
26.3 After the completion of the ‘Works’, the Contractor shall remove from the site under
the direction of the Purchaser/Consultant the materials such as construction equipment,
erection tools and tackles, scaffolding, etc. with the written permission of the Purchaser
/ Consultant. If the Contractor fails to remove such materials, within fifteen (15) days
of issue of a notice by the Purchaser/Consultant to do so, then the Purchaser/Consultant
shall have the liberty to dispose of such materials as detailed under Clause 26.2 above
and credit the proceeds to the account of the Contractor.
26.4 On completion of the work, all rubbish materials and temporary structures of any sort
or kind used for the purpose or connected with the construction/erection work and
heaps are to be removed by the Contractor and all pits and excavations filled up and the
site handed over in a tidy and workmanlike condition and no final payment or
settlement of the account for the said work shall held or due shall be made to the
Contractor till such site clearance shall have been effected by him and such clearance
shall be made by the Purchaser at the expense of the Contractor in the event of his
failure to comply with this provision within 7 (seven) days after receiving notice in
writing from the Purchaser to that effect. If it becomes necessary for the Purchaser to
have the site cleared as indicated above at the expense of the Contractor, the Purchaser
shall under no circumstances be held liable for any losses of damages to such of
Contractors property as may be on such site due to such removal there from, which
removal may be effected by means of public sale of such materials and property in such
a way as deemed fit and convenient to the Purchaser.
26.5 The Contractor must take sufficient care in moving his construction/erection plant and
equipment from one place to another so that they may not cause any damage to the
property of the Purchaser, particularly of the existing structures and overhead and
underground services and in the event of the Contractors failure to do so, the cost of
such damages shall be borne by the Contractor.
27.0 PROTECTION OF PROPERTY AND CONTRACTOR’S LIABILITY
27.1 The Contractor shall be responsible for any damage resulting from his operations. He
shall also be responsible for protection of all persons including members of public and
employees of the Purchaser/Consultant and the employees of other Contractors and
Sub-Contractors and all public and private property including structures, buildings,
other plants and equipment and utilities either above or below the ground.
27.2 The Contractor will ensure provision of necessary safety equipment such as barriers,
signboards, warning lights and alarms, etc. to provide adequate protection to persons
168
169
34.1 The Purchaser/Consultant may, in his absolute discretion, from time to time, issue
further drawings and/or written instructions, details, directions and explanations, which
are collectively referred to as “Purchaser’s Instructions”, in regard to :
34.1.1 Any additional drawings and explanations to exhibit or illustrate details.
34.1.2 The variation or modification of the design, quality or quantity of work or the additions
or omission or substitution of any work.
34.1.3 Any discrepancy in the drawings or between the Schedule of Quantities and/or
specification.
34.1.4 The removal from the site of any materials brought thereon by the Contractor and the
substitution of other materials thereof.
34.1.5 The removal and/or re-execution of any work executed by the Contractor.
34.1.6 The dismissal from the work of any persons employed thereupon.
34.1.7 The opening up for inspection of any work covered up.
34.1.8 The amending and making good of any defects.
34.2 The Contractor shall comply with and duly execute any work covered in such
‘Purchaser’s Instructions’ provided always that verbal instructions, directions, and
explanations given to the Contractor or his foreman upon the work by the
Purchaser/Consultant shall, if involving a variation, be confirmed in writing by the
Purchaser/Consultant within seven (7) days.
34.3 If compliance with the ‘Purchaser’s Instructions as aforesaid involves work and scope
beyond that contemplated by the ‘Contract’, unless the same were issued owing to
some breach of this ‘Contract’ by the Contractor, the Purchaser shall pay to the
Contractor the price of the said work as hereinafter provided.
34.4 If the Contractor after receipt of written notice from the Purchaser/Consultant requiring
compliance, with such further drawings and/or ’Purchaser’s Instructions’ fails to
comply with the same within seven (7) days the Purchaser may employ and pay other
agencies to execute any such work whatsoever, as may be necessary to give effect
thereto, and all costs incurred in connection therewith shall be recoverable from the
Contractor by the Purchaser on a certificate by the Consultant as a debt or may be
deducted by the Purchaser from any money that may become due to the Contractor.
35.0 RIGHTS OF THE PURCHASER/CONSULTANT
35.1.1 The various parts of the ‘Contract’ are intended to be complementary to each other but
should any discrepancy appear or any misunderstanding arise as to the import of
anything contained therein, the explanation of the Purchaser/Consultant shall be final
and binding.
35.1.2 The correction of any errors or omissions of the Drawings and Specifications may be
made by the Purchaser/Consultant, when such correction is necessary to bring out
clearly the intention which is indicated by the reasonable interpretation of the Drawings
and Specifications as a whole.
170
172
173
174
1.0 The Contractor shall make his own arrangement for all labour, construction
equipment, tools and tackles and construction materials. All temporary approach
roads to the site for carrying out construction work shall be constructed and
maintained by the Contractor at his own cost.
2.0 The Contractor shall take all necessary precautions to avoid damage to any
property of the Purchaser or any third party. The Contractor shall also ensure that
the progress of work of other Contractors in the adjoining areas is not hindered.
Any damage occurring should then be made good by the Contractor at his own
expense.
3.0 The Contractor shall take all precautions during execution, especially while
excavating to avoid interference with or, damage to underground works, such as
cables, pipe lines, drains etc. and provide all possible protection to these works
and in case they are damaged, rebuild/divert them at his own cost.
4.0 The Contractor shall carry out necessary precision survey to set out and check
the setting of all works including foundation & anchor bolts etc. to required
tolerances using the grid reference points available in the plant site. The
Contractor shall make and maintain proper bench mark and reference points and
check lines and levels periodically.
5.0 Materials brought to the site shall not be removed from the site without the
written consent of the Purchaser. The Contractor shall submit well in advance for
approval, all samples and specimens as the Purchaser may demand from time to
time. Any material brought to site and rejected by the Purchaser shall be
removed by the Contractor from the site of work immediately within the time
limit specified by the Purchaser. In case, the Contractor is not removing the
rejected materials, the same will be removed by the Purchaser and cost thereof
shall be recovered from the bills of the Contractor.
6.0 The Purchaser may during the progress of work, order the removal of part or
whole of the work executed, found not in accordance with the approved
drawings/ specifications/ written instructions. No extra claims shall be
entertained for removal & re-execution of such work.
7.0 No work shall be covered up or put out of view without the approval of the
Purchaser. In the event of failing to do so, the Contractor shall uncover any part
of the work or make openings in or through the works as the Purchaser may
direct and they shall be made good with materials approved by the Purchaser and
should match with workmanship of the surrounding work.
8.0 The Contractor shall dismantle and remove the stagings and other temporary
facilities like stores, offices, etc. on completion of work, clear and clean the site
where such temporary facilities were built and restore the same to original
condition at his own cost.
9.0 The Contractor shall provide all necessary storage at the site in specified areas
for all materials such as timber, cement, lime and such other materials which are
likely to deteriorate by the action of sun, winds, rain, coastal conditions or other
natural cause due to exposure in the open in such manner that all such materials
shall be duly -protected from damage by weather or any other cause. All such
stores shall be cleared away and the whole site left in good order on completion
175
176
GENERAL
1.01 The Contractor shall submit Safety Code and handed over a copy to all sub- Contractors
working under his control and he should in turn display all rules on the office notice
board for the benefit of all the men working under him.
1.02 The Contractor shall provide adequate guards, illumination, fencing and watching
wherever necessary at the construction site & working area, for the safety & convenience
of public or others.
1.03 Fire extinguishers adequate in number shall be kept by the Contractor at the site of works
where there is risk of fire hazard, especially near the site stores.
1.04 Adequate washing facilities with proper drainage shall be provided properly maintained
near the place of work but at a safe distance from approach roads, Electrical HT Lines
etc.
1.05 When work is to be done near any place, where there is risks of drowning, arrangements
to be made for safe barricading of such areas. All necessary equipment shall be provided
and kept ready for use and necessary steps taken for prompt rescue of any person in
danger and adequate provision shall be made for prompt first-aid treatment of all injuries
likely to be sustained during the course of the work in case of mishap.
1.06 To ensure effective enforcement of the rules and regulations relating to safety
precautions, the arrangements made by the Contractor shall be open to inspection by the
Safety Engineer, the Labour Officer, Engineer-in-charge of the department or their
representatives.
1.07 Notwithstanding the above clauses, there is nothing in those to exempt the Contractor
from the operation of any other Act or Rule in Republic of India for the safety of men and
materials.
1.08 An injury sustained in the plant, must be reported to the First-Aid Station no matter
how slight it is, the injured person will inform Supervisor/Officer in-charge.
1.09 In case of a fatal accident, the Contractor must inform the Engineer in-charge of the
department for which he is working and report in writing should be made in the form.
1.10 Smoking or keeping of naked light is strictly prohibited near gas lines, valves and any
other equipment connected with the gas distribution.
1.11 Smoking and carrying of matches, lighters and other spark producing devices is strictly
prohibited within the area where inflammable liquids are stored, handled or used or
where loading or unloading operations are performed. Any tank or container containing
flammable liquid should be properly grounded for preventing ignition due to static
177
1.12 Contractors should ensure that employees do not come to work while still under the
influence of intoxicants. Any employee found on duty under the influence of liquor or of
intoxicating drugs, will be liable to severe disciplinary action.
1.13 Work surrounds should be kept clean, free from oil, grease and other obstructions or
fallen objects like nuts bolts etc.
1.14 After a job or work is completed, all left-over junk and other scrap materials should be
cleared from the area immediately.
1.15 Drums or other make-shift arrangement must not be used in place of ladders or as work
benches or supports for any job.
1.16 Employees must not walk through or across any systems that is brought into operation
unless their duties require them to do so or they are authorised to do so.
1.17 Compressed air should not be used for removing dust from one's clothes. Compressed air
should not be blown against anyone as it may injure or even kill him.
1.18 If an employee, in the course of his work, encounters condition of unusual hazard with
which he is not familiar, he should contact the supervisor for advice before proceeding
further. He should also inform the Contractor as well as the Engineer in-charge.
1.19 Contractors should particularly ensure that they or their employees do not meddle with
any equipment and see that they keep away from such equipment.
1.20 It should be ensured that no one takes rest/shelter below any under cut pit/excavation or
near any stock of materials or under Solar PV arrays.
1.21 i. For any work involving repair & maintenance underground work the Contractor shall
follow the safety procedural orders/instruction issued by the Purchaser.
ii The Contractor shall exercise supervision of such jobs by competent persons within
the meaning of factories act & rules.
iii All persons engage on such jobs shall have to have before hand proper training
instructions as required under Factories Act & Rules.
1.22 The site is in the vicinity of desert area with sand dunes. Contractor has to caution his
employees at site against the associated hazards. If considered necessary, he shall arrange
for a properly equipped team for taking care of contingencies.
178
2.2 Any special safety precautions, if required to be followed by the Contractor, such clauses
shall be added.
2.3 The executing department would take necessary shut-downs wherever there are hazards of
gases, electricity, moving machinery etc. The Contractor shall ensure that the
shut-down/clearance are taken before sending workers to such locations.
2.4 The Contractor shall supply safety appliance like shoes, safety belts, ladies chappals,
helmets, gloves etc. to his workers depending on working conditions and Life saving
jackets shall be kept in readiness always at the site. The Contractor shall not deploy any
workmen without safety boot and safety helmet and the safety applicable to the specific
work conditions.
2.5 Before starting the day's job, the Purchaser's Supervisor/representatives will ensure that
safety briefing has been done to the Contractor's supervisor who has been imparted safety
induction earlier.
2.6 HOD/Zonal in-charge will nominate Engineer in-charge of the contractual work under
reference who will be fully responsible for the safe execution of the work at site.
2.7 In case of injury to persons, the Contractors shall first take the injured person to the NLC
Dispensary hospital with the necessary forms. In no case the Contractors are allowed to
take injured persons directly to their own Doctors.
2.8 The Contractor shall abide by the provisions of Factories Act, State Factory Rules,
Workmen’s Compensation Act, Payment of Wages Act, Contract Labour (Regulation)
Act etc. and keep the Purchaser indemnified of provisions of the above Acts and Rules.
2.9 The Head of Deptt. Executing the contract upon the satisfaction that the Contractor is not
conforming to the Safety requirements may direct stoppage of work and require the
Contractor to remedy the defects. The Contractor shall not proceed with the work until he
has complied with each direction to the satisfaction of such Head of the Department.
2.10 The Contractor shall be fully responsible for accidents caused due to him or his agents or
workmen’s negligence or carelessness in regard to the observance of the safety
requirements and shall be liable to pay compensation for injuries.
2.11 Without prejudice to the right conferred by the clause 2.09 above for stoppage of work for
violations of safety requirements the Contractor shall be liable for penalty as deemed fit
for violation of safety rules & regulations upto first two instances. For the third violation
he shall be liable to be debarred from further contracts upto a period of one year from the
date of issue of debarring notice.
179
2.13 Whenever work, at height is involved, Contractor must obtain height passes from Safety
Engg. Deptt. For those persons required to do work at height.
2.14 Contractor must insure all the workmen against “Workmen Compensation Act.”
*******
180
1.1 Codes and Standards shall mean all the applicable codes & standards as indicated in
the system specification.
1.2 `CONTRACTOR' shall mean the successful BIDDER whose bid has been accepted
by the PURCHASER and on whom the `Contract' or `Purchase order' is placed
by the Purchaser and shall include his heirs, legal representatives, successors and
permitted assignees.
1.3 Contract shall mean and include this contract between the owner and Contractor for the
execution of the works as per agreed terms, conditions, specifications prices and
enforceable as per law.
1.4 Contract period shall mean the period / time schedule agreed in the contract during
which period the Contracted work shall be performed / executed, inclusive of any
period covered by extension(s), duly issued.
1.5 ‘Contract Price’ in relation to particular contract shall mean the total consideration to be
paid by NLC to the Contractor.
1.6 `Date of Contract' shall mean the calendar date on which NLCIL and the
CONTRACTOR have signed the `CONTRACT'.
1.7 "Effective date of Contract for O&M” shall mean the date of final acceptance of installed
PV Solar Power Plant.
1.8 `Notice in Writing', `Written Notice' shall mean any notice in written, typed or printed
characters sent (unless delivered personally or otherwise proved to have been
received) by registered post to the last known private or business address or registered
office of the addressee and shall be deemed to have been received when in the ordinary
course of post it would have been delivered.
1.9 Purchaser/Owner shall mean and include NLC India Limited (NLCIL) and its different
functionaries entrusted with the responsibilities in relation to this contract in respect of
the area of responsibilities of such functionaries.
1.10 ‘Site ’ shall mean the place or places envisaged by NLCIL at which the services are to be
performed, as also such other places as may be specifically provided by NLCIL for the
stated purposes.
1.11 `Work' shall mean the services to be provided by the CONTRACTOR under the scope
of the ‘Contract'.
1.12 Writing' shall include any manuscript, typewritten or printed statement, under or over
signature and/or seal as the case may be.
181
3.1 The Bidder shall quote “FIRM’ price in Indian rupee for the entire contract period of
ten (10) years after completion of warranty period.
3.2 Price quoted shall include cost of all spares and consumable, to meet NLCIL’s
requirement as specified in the tender specification.
3.3 Bidder are requested to quote their operation and maintenance charges as per the price
schedule (Schedule-7.)
4.1 The time schedule for operation and maintenance shall be for a period of ten (10) years
after one year warranty period.
5.1 As a contract security for faithful performance of the Contract in accordance with the
terms and conditions specified in the Operation and Maintenance Contract the
CONTRACTOR shall furnish a Contract Performance Bank Guarantee in the form
of irrevocable bank guarantee from any Nationalized Bank or Scheduled Bank
approved by RBI except banks from China in a non-judicial stamp paper for the value
of Rs.80/- 30 days before commencement of operation and maintenance for an amount
equal to 10% of the total Contract price of operation and maintenance contract. The
Contract Performance Bank Guarantee shall be valid for 10 years and shall be valid till
the expiry of 90 days beyond the actual date of successful completion of
operation and maintenance contract period.
5.2 NLC shall have the right to encash the Contract Performance Guarantee for non-
compliance of any or all the terms and conditions of the contract and non
performance with respect to availability, discontinues to do the work before the
completion of period mentioned in Cl. 4.0 above and for failure to comply with any of
the obligations as enumerated in the Contract.
182
6.1 The O & M charges quoted in Price Schedule-7 (Vol.1 of 3) shall be paid on pro-rata
quarterly basis on certification of work by the Project Manager at the end of every
quarter.
a. The O&M charges shall be inclusive of taxes and duties as applicable except
service tax. But any taxes, levies/fees newly imposed would be reimbursed
extra (with submission of documentary proof from concerned authority).
Similarly, due credit would be given to NLCIL in case of withdrawal or reduction
in applicable taxes/fees/duties. The O&M charges should be quoted for a period
of 10 years.
b. Payment will be made after all statutory deductions as applicable to such type of
contracts. The rate quoted shall deem to be inclusive of all salaries and other
cost, expenses of employees, cost of spares, cost of repair/replacement/
modification of any equipment or system for the entire quoted period of 4 years so
as to give maximum machine availability. The rates are also inclusive of tools &
tackles, etc. and liabilities of every description and all risk of every kind to be
taken in operation, maintenance and handing over the plant to NLCIL by the
contractor.
8.1 All Payments in Indian Rupees shall be made direct to the Contractor through E-
payment. For effecting E-Payment, Contractor shall furnish necessary details to the
Purchaser. All bank charges shall be to the account of the Contractor.
9.0 GST
9.1 The Contractor shall register with statutory / tax authorities wherever required.
i. The Supplier / Contractor has to provide a copy of the GST Registration Certificate
and also mention their GST Registration No. and Date in each of their invoices /
bills without fail. No invoice or bill will be paid unless the GST Registration No. is
mentioned therein.
9.1.1 i. The GST lumpsum indicated in the price schedule is as per the rates prevailing one
month prior to original schedule date of Tender Opening . Any statutory variation in
respect of GST within the agreed time schedule will be to the account of the
purchaser, at actuals based on the documentary evidence, independent of the ceiling
quoted. Statutory variation arising beyond agreed time schedule shall not be payable
ii. While claiming the GST payment, the contractor should furnish the requisite details
in the invoice as per statutory requirements.
183
11.4.1 Income Tax and Cess, if any payable by the Contractors/ sub-Contractor's employees
shall be paid by the said employees directly, and the Purchaser shall not be liable to pay
the income tax & Cess payable by the employee of the Contractor/sub Contractor and
the purchaser is not responsible for filing the tax returns of contracts
employees/experts.
11.5 Deduction of Tax at source at prevailing rate shall be effected by the Purchaser before
payment as a statutory obligation wherever applicable
12.1 The Contractor shall engage required qualified & trained persons for the above O&M
works for achieving the guaranteed output. The entire work shall be supervised by a
B.E Degree Holder with experience in similar nature of works.
12.2 The Contractor shall see that one of the technically qualified persons is always
available at the site of work, during working hours, to check all items of work.
13.1 NLCIL give directions from time to time in writing for any valid reasons, without in
any way violating this contract, to the Contractor to suspend the work or any part
thereof. The Contractor shall suspend the work till such time as indicated by NLC. The
Contractor shall not, after receiving such written notice proceed with the works therein
ordered to be suspended until he shall have received written notice or authority to the
effect from the NLC.
14.1 The Purchaser or his duly authorized person shall have at all times, full power to
inspect the Solar PV Power Plant where the Contractor is carrying out the Operation
and Maintenance. The Contractor shall properly carry out the written instruction issued
by the NLCIL.
15.1 The Contractor shall arrange tools and tackles, spares, and consumables required for the
Operation & Maintenance of the Solar PV Plant. .
16.1 The Contractor shall not sublet, transfer or assign the contract or any part there of
without the written permission of NLC. In the event of the Contractor contravening
this condition Owner shall be entitled to entrust the work to other agencies at the
Contractor’s account and risk. The Contractor shall be liable for any loss or damage
which the Corporation may sustain in consequence of or arising out of such replacing
the contract notwithstanding any such permission to sublet, the Contractor shall always
be held responsible for the due fulfillment of the terms and conditions of contract.
184
17.1 The Contractor shall ensure compliance with all statutes, laws, rules and regulations of
the Central or State Governments or any other authority such as the Workmen's
Compensation Act 1923, Payment of Wages Act, Minimum Wages Act - 1948
Employees State Insurance Act, Employees Provident Fund Act, Mines Act Indian
Electricity Rules 1956, the Contract Labour and Regulation Act etc. and the general
rules there-under any and all statutory modifications thereof in connection with
employees engaged by him or his Sub- Contractors in the work.
17.2 The Contractor shall arrange to give all notices required by the said Acts, Regulations
or Bye-laws to be given to any authority or to any Public Officer and pay all fees that
may be properly chargeable in respect of the `works’ and lodge the receipts with NLC,
Obtaining all permits and licenses required thereupon is the responsibility of the
Contractor.
17.3 All registration and statutory inspection fees, if any, in respect of his work pursuant to
this `Contract' shall be to the account of the Contractor.
18.1 No material brought to the “site” shall be removed from the “site” by the Contractor
and/or his SUB- Contractor without the prior written approval of NLC.
19.1 The Contractor shall co-operate with all other Contractor’s or tradesmen of NLC who
may be performing other works on behalf of the NLC and the workmen who may be
employed by NLCIL and doing work in the vicinity of the works under their respective
contracts. The Contractor shall also so arrange to perform his work as to minimize, to
the maximum extent possible interference with the work of other Contractor’s and his
workmen. NLCIL shall determine the resolution of any difference of conflict that may
arise between the Contractor and other Contractor or between the Contractor and the
workmen of NLCIL in regard of their work. If the works of this Contractor is delayed
because of any acts or omissions of another Contractor, the Contractor shall have no
claim against NLCIL on that account other than an extension of time for a completing
his works.
20.1 The Contractor shall adhere to the disciplinary procedure set by NLCIL in respect of his
employees and workmen at 'Site'. NLCIL shall be at liberty to object to the presence of
any representative or employee of the Contractor at the `Site' if in the opinion of
NLCIL such employee has misconducted himself or be incompetent or negligent or
otherwise undesirable and then the Contractor shall promptly remove such a person
objected to, and provide in his place a competent replacement at his own expenses.
21.1 The Contractor shall submit to NLCIL on the last week of every month, a man-hour
schedule for the next month, detailing the man hours scheduled for the month, skill
wise and area wise.
185
21.3 The Contractor shall also submit periodically such of the reports as NLCIL may call for
from time to time.
22.1 The work procedures that are to be used during the maintenance shall be those, which
minimize fire hazards to the extent practicable. Combustible materials, combustible
waste and rubbish shall be collected and removed from the `Site' at least once a day.
22.2 The Contractor shall provide enough fire protection equipment of the types and number
for the warehouses, office, temporary structures etc. Access to such fire protection
equipment shall be easy and kept open at all times.
23.0 SECURITY:-
23.1 The Contractor shall have total responsibility for all equipment and materials in his
custody. The Contractor shall make suitable Security arrangements including
employment of Security personnel to ensure the protection of all materials, equipment
and `Works' from theft, fire, pilferage and any other damages and loss. All materials of
the Contractor shall enter and leave the Project `Site' only with the written permission
of NLC in the prescribed manner.
24.1 The Contractor shall bring to `Site' all the equipment, components, parts, materials,
including equipment, tools and tackles for the purpose of the `Works' under
intimation to NLCIL. All such goods shall from the time of their being brought may
be used for the purpose of the `Works' only and shall not on any account be removed
or taken away by the Contractor without the written permission of NLC. But, the
Contractor shall nevertheless be solely liable and responsible for any loss or destruction
thereof and damage thereto.
24.2 NLC shall have lien on such goods for any sum or sums which may at any time be
due or owing to him by the Contractor , under in respect of or by reasons of the
`Contract'. After giving a fifteen (15) days' notice in writing of his intention to do
so, NLCIL shall be at liberty to sell and dispose of any such goods, in such manner as
he shall think fit including public auction or private treaty and to apply the
proceeds in or towards the satisfaction of such sum or sums due as aforesaid.
24.3 After the completion of the `works' the Contractor shall remove from the `Site' under
the direction of NLCIL his own materials such as equipment, tools and tackles,
scaffolding, etc. which were brought by him with the written permission of NLC. If
the Contractor fails to remove such materials, within 15 (fifteen) days of issue
of a notice by NLCIL to do so, then NLCIL shall have the liberty to dispose off such
materials and credit the proceeds thereto the account of the Contractor .
24.4 On completion of the work, all rubbish, kilns, vats, tanks, materials and temporary
structure of any sort or kind used for the purpose or connected with the work are to be
186
24.5 The Contractor must take sufficient care in moving his equipment from one place to
another so that they may not cause any damage to the property of NLCIL, particularly
to the existing structures and overhead and underground services and in the event of
Contractor's failure to do so, the cost of such damages shall be borne by the Contractor.
25.1 The Contractor shall advise NLC of any modifications or upgrades of the Solar PV
Power Plant for increasing safety and reliability, improved production performance.
25.2 If Contractor on his own initiative wishes to upgrade or modify the Solar PV Power
Plant then, the Contractor may carry out the upgrade at his own cost with the prior
written consent of NLCIL.
25.3 If any alteration or modification is required to be made in the Solar PV Power Plant to
comply with all provision of law for the time being in force on the Commencement
Date of this agreements the Contractor shall take necessary step to make Solar PV
Power Plant comply with the provisions of such law.
25.4 If modification is required in the Solar PV Power Plant to comply with the provisions
of any Law, which came into force after the commencement date of this agreement,
then such modification shall be taken up by NLCIL. The Contractor at the cost of
NLCIL on the terms & conditions as may be agreed by the parties and in such case the
time spent shall not be classified as down time hours.
25.5 Upgrading of Solar PV Power Plant will be done in consultation with O.E.M. (Original
Equipment manufacturer) & through the Contractor on mutually agreed terms &
conditions.
26.1 If there is any damage to Solar PV Power Plant due to accident or otherwise and it is
established that the said accident and/or damage has been occurred due to the operators
faults or negligence, Contractor shall be responsible for payment towards rectification
of such damage of Solar PV Power Plant.
26.2 If any damage is caused to Solar PV Power Plant and / or accident occurred at the site
of the said Solar PV Power Plant, due to improper maintenance of the Solar PV Power
Plant by the Contractor, the Contractor shall be responsible and liable against all such
damage and compensation and indemnify Purchaser against such loss or damage
incurred or be incurred by NLCIL.
187
28.0 GENERAL:
28.1 Contractor shall meet the NLCIL authorised representative and receive instructions
regarding the works to be carried out. The Contractor or his representative shall be
available at all times in the site in order to execute any urgent work.
28.2 Decision of the NLCIL shall be final and binding in all matters regarding contract.
29.0 SAFETY:
29.1 The Contractor shall ensure the safety of his workmen against accidents and injuries
while at work as required by the relevant rules. It shall be the obligations of the
Contractor to pay compensation as per workmen compensation Act and to extend co-
operation to the officers in any enquiry conducted there on. No responsibility shall rest
with the corporation in this regard. The Contractor shall work in co-ordination and
close co-operation with the staff working in the area.
29.2 While doing works, all the safety precautions and safety rules should be followed and
failure to adhere to the same shall be viewed seriously and the contract shall be
terminated if required."
29.3 The Contractor shall arrange all safety gadgets for workmen engaged by him.
29.4 Before the Contractor connects any electrical appliances to any plug or socket
belonging to the other Contractor or NLCIL, he shall.
(a) Satisfy NLCIL that the appliance is in good working condition.
(b) Inform NLCIL of the maximum current rating, voltage and phases of the
appliances.
(c) Obtain permission of NLCIL detailing the sockets to which the appliances may be
connected
188
29.6 No electric cable in use by NLCIL will be disturbed without prior permission. No
weight of any description will be imposed on any such cable and no ladder or similar
equipment will rest against or be attached to it.
29.7 No work shall be carried out on any live equipment. The Equipment must be made safe
and a permit to work issued before any work is carried out.
30.0 WORKS:
30.1 The site of work shall be kept clean, free from rubbish and dismantled materials. All
rejected and unwanted materials, debris etc., shall be removed from the site then and
there. If the Contractor fails to do such clearance work, the work shall be got done
departmentally, two days after the issue of a single written notice to the Contractor and
the expenditure incurred there for shall be recovered from the Contractor 's bills.
30.2 Any faulty work noticed and pointed out by NLCIL shall be rectified by the Contractor
30.3 The Contractor shall Work in co-ordination and close co-operation with other
Contractor’s staff working in the area.
31.0 MATERIALS:-
31.1 The material used shall comply with the relevant standard specification and shall be
approved by NLCIL.
32.0 LABOUR:-
32.1 Under the provisions of the Contract Labour (Regulation and Abolition) Act 1970 the
Contract Labour (Regulation and abolition) Rules 1971 any Contractor who employs or
employed 20 or more men on any day of the preceding 12 months shall obtain a
licence. The licence so obtained shall be renewed every year.
32.3 The Contractor shall issue an employment card in Form XIV as per rule 76 of the
contract labour (Regulation and Abolition) Rules 1971.
189
32.5 Failure to comply with the statutory provisions will entail prosecution by the statutory
authorities beside black listing the Contractor .
"The Contractor should produce the following declaration along with their application
for issue of identity cards to the workmen. "Certified that the following contract
workers engaged by me bear good conduct, that their antecedents have been verified
and found satisfactory".
Sl. Name of the Contract Address Identification
No. Worker Marks
33.0 INSURANCE:-
33.1. The Contractor shall arrange for Workmen's Compensation Insurance, Comprehensive
Automobile Insurance and Comprehensive General Liability Insurance and till
completion of Operation & Maintenance period which shall also be the responsibility of
the Contractor.
33.2 The Contractor should take group insurance scheme for the workers under his contract,
which may or may not result in partial or permanent disablement. The first bill will be
passed after producing group insurance policy.
33.3 The above are only illustrative list of insurance covers normally required and it will
be the responsibility of the Contractor to maintain at his cost all necessary insurance
coverage to the extent both in time and amount to take care of all his liabilities either
direct or indirect in pursuance of the `Contract'.
33.4 Third Party Liability Insurance:
The policy shall cover third party liability. The third party liability shall cover the loss /
disablement of human life (persons not belonging to the Contractor) and also cover the
risk of damages to others' materials/equipment/ properties during O&M .The value of
third party liability for compensation for loss .of human life or partial / full disablement
shall be of required statutory value but not less than Rs.2 lakh per death, Rs.1.5 lakh per
full disablement and Rs.1 lakh per partial disablement and shall nevertheless cover such
compensation as may be awarded by a Court of Law in India or abroad and cover for
damage to others' equipment /surrounding property as approved by NLCIL.
34.0 RESOLUTION OF DISPUTES AND ARBITRATION:-
34.1 Informal dispute resolution:
34.1.1 The parties agree to use reasonable efforts to resolve all disputes equitably and in good
faith.
34.1.2 If any dispute between the Contractor and NLC arises it shall in the first
instance be referred in writing to NLC, who shall endeavor to resolve the dispute
amicably and render a decision within 30 days. The period of 30 days shall be
reckoned from the date of intimation of the dispute is received by NLC.
34.1.3 The agreement and the rights and obligations of the Parties, shall remain in full force
and effect pending the award in any arbitration proceedings. Supplies and/ or services
under the Contract shall, if reasonably possible, continue during arbitration
proceedings.
190
35.2.4 The Contract agreement / Purchase order conditions and the rights and obligations of
the Parties, shall remain in full force and effect during the Conciliation proceedings.
Supplies and / or services under the Contract shall, if reasonably possible, continue
during the Conciliation proceedings.
35.2.5 For the purpose of this clause, the term ‘dispute’ shall include a demand or difference
of any kind whatsoever, arising out of the Contract and respecting the performance of
the Contract, whether during the Contract period including extensions if any, or after
completion, and whether before or after termination, abandonment or breach of the
Contract. (except as to any matter, the decision of which is specifically otherwise
provided for in any of these conditions).
35.2.6 Only in case of failure to resolve the dispute through Conciliation, Arbitration can be
resorted to or Judicial remedy can be sought for.
35.2.7 Once the settlement agreement is signed with respect to a dispute, the same dispute is
not subject to further appeal through Arbitration or Judicial Proceedings.
35.2..8 Anything not found included in the ‘NLC Conciliation Rules’, but necessary to conduct
the conciliation proceedings will be dealt with as per the provisions of the ‘Arbitration
and Conciliation Act 1996 -Part-III’ or as per the statutory provisions modified from
time to time.
35.3.2 Except as otherwise provided in this clause, any dispute arising out of or relating to this
agreement, or the breach, termination or validity thereof, shall be finally settled by
arbitration in accordance with the Arbitration and Conciliation Act 1996 (the ``Act'').
The arbitration shall be held at Chennai, Tamil Nadu. The arbitration proceedings shall
be conducted, and the award shall be rendered in English. The award shall state the
reasons upon which it is based. Interest, if awarded by the arbitrators, shall be at a rate
not exceeding the Cash Credit rate prevailing on the date of the award. All interest
payments so awarded are subject to deduction of TDS at sources as applicable at
prevailing rates of Income Tax.
35.3.3 There shall be three arbitrators of whom each Party shall appoint one. The Party
requesting that the dispute be referred to arbitration shall, within 30 days of the
notification in terms of Clause 31.3.1, appoint an arbitrator as also call upon the other
Party to appoint an arbitrator within 30 days. The two arbitrators so appointed shall,
within 30 days of the date on which the second of them is appointed, agree on the third
arbitrator who shall act as the presiding arbitrator of the tribunal.
35.3.4 The agreement and the rights and obligations of the Parties, shall remain in full force
and effect pending the award in any arbitration proceedings. Supplies and/ or services
under the Contract shall, if reasonably possible, continue during arbitration
proceedings.
35.3.5 For the purposes of this clause, the term `dispute' shall include a demand or
difference of any kind whatsoever, arising out of the Contract and respecting the
performance of the Contract, whether during the Contract period including extensions if
any, or after completion, and whether before or after termination, abandonment or
breach of the Contract (except as to any matter, the decision of which is specifically
provided for in any of these conditions).
35.4 The party, in whose favour the Award is passed shall be entitled to reach the entire costs
of Arbitration from the other party. The Arbitration shall indicate the above in their
award clearly.
In the event of any dispute or difference, relating to the interpretation and application of
the provisions of the Contracts, such dispute or difference shall be referred by either
party to the arbitration of one of the Arbitrators in the Department of Public
Enterprises. The Arbitration and Conciliation Act, 1996 shall not be applicable to the
arbitration under this clause. The award of the Arbitrator shall be binding upon the
parties to the dispute, provided, however, any party aggrieved by such award may
make a further reference for setting aside or revision of the award to the Law
Secretary, Department of Legal Affairs, Ministry of Law & Justice, Government of
India. Upon such reference the dispute shall be decided by the Law Secretary or the
Special Secretary/Additional Secretary when so authorized by the Law Secretary,
whose decision shall bind the parties finally and conclusively. The parties in the
192
36.1 Force majeure herein defined is a cause which is beyond the control of the Contractor or
the Purchaser, which they could not foresee and which substantially affect the
performance of the “contract” such as
36.1.1 Natural phenomena, including but not limited to floods, droughts, Earthquakes and
epidemics
36.1.2 Acts of any government, domestic or foreign, including but not limited to war, declared
or undeclared priorities, quarantines, embargoes,
36.1.4 Piracy
36.1.5 Riots and civil commotions Provided either party shall within fifteen (15) days from the
occurrence of such a cause notify the other in writing of such cause.
36.1.6 However Power cut and failure in water supply shall not be considered under “Force
Majeure” condition.
36.2 The Contractor or the owner shall not be liable for delays in performing the
respective obligations resulting from any force majeure condition occurred. The date of
completion shall be extended by a reasonable time
36.3 If the performance as a whole or part by the Contractor or any obligations under the
Contract is prevented or delayed by “Force majeure” condition for a period exceeding
120 days, the Purchaser may at his option terminate the contract by notice in writing.
36.4 Force Majeure conditions prevailing at the works of the Sub-Suppliers / Sub-
Contractors other than 4 major sub-suppliers (the names of which to be indicated by the
contractor) shall not be recognized by the Purchaser on any account and it shall be upto
the Contractor to make necessary alternative arrangement to execute the Contract
within the agreed time schedule.
36.5 No increase or decrease in price shall be payable due to Force Majeure condition.
37.1 If the Contractor discontinuous to do the work before the completion of time indicated
in Cl.4.0 then in such case NLCIL may give notice in writing and shall be at liberty to
employ other person / persons and forthwith execute such part of the `works' as the
Contractor may have neglected to do or if NLCIL shall think fit it shall be lawful for
him without prejudice to any other right he may have under the `Contract' to take the
`Works' wholly or in part out of the Contractor’s hands and re-contract with any
other person or persons, complete the `works' or any part thereof and in that event
NLCIL shall be free to use without hire charges, of all Contractor’s equipment that
may have been at the time on the `Site' in connection with the `Works' without being
193
37.2 In such a event NLCIL shall also have the right to encash the Contract Performance
Bank Guarantee for non-performance of Contract.
38.1 NLC reserves the right to terminate the CONTRACT either in part or in full due to
reason other than those mentioned under clause entitled Contractor’s Default. NLC
shall, in such an event, give 30 (thirty) days notice in writing to the Contractor of his
decision to do so.
38.2 The Contractor upon receipt of such notice shall discontinue the work on the date and
to the extent specified in the notice, make all reasonable efforts to obtain cancellation of
all order and Contracts to the extent they are related to the work terminated and upon
terms satisfactory to NLCIL, stop all further sub-Contracting or purchasing activity
related to the work terminated and assist NLCIL in maintenance, protection and
disposition of the works acquired under the Contract by NLCIL.
38.3 In the event of such a termination, the Contractor shall be paid compensation, equitable
and reasonable dictated by the circumstances prevalent at the time of termination. No
consequential damages shall be payable by the NLCIL to the Contractor in the event of
termination.
38.4 If the Contractor is an individual or a Proprietor concern and the individuals or the
proprietor dies and if the Contractor is a partnership concern and one of the partners
dies, then unless the NLCIL is satisfied that the legal representatives of the individual
Contractor or the Proprietor of the proprietary concern and in the case of partnership,
surviving partners, are capable of carrying out and completing the Contract NLCIL
shall be entitled to cancel the Contract as to its incomplete part without being in any
way liable to payment of any compensation to the estate of deceased Contractor
and/ or to the surviving partners of the Contractor 's firm on account of the
cancellation of the Contract. The decision of NLCIL that the legal representatives of
the deceased Contractor or surviving partners of the Contractor’s firm cannot carry out
and complete the Contract shall be final and binding on the parties. In the event of
such cancellation NLCIL shall not hold the estate of the deceased Contractor and/ or
the surviving partners of the estate of the deceased Contractor and/ or the surviving
partners of the Contractor's firm liable to damages for not completing the Contract.
194
40.1 The Contractor shall maintain a history register and submit to the NLCIL at the end of
each calendar year for review.
40.2 The history card shall contain all the works carried out including replacement of spares
& consumables etc.
41.1 The contract period shall automatically cease to exist after ten years from the effective
date of O&M contract and the Contractor shall have no right to ask for any extension.
However, NLCIL at its discretion can extend this contract, for further period at the
mutually agreed price and terms & conditions.
42.0 JURISDICTION:
42.1 The Civil Courts having ordinary original civil jurisdiction over Andaman & Nicobar
Islands shall have exclusive jurisdiction in regard to all questions of disputes of
whatever nature including the arbitration proceedings, if any arising under the Contract
with NLCIL.
43.1 This Contract shall be governed and construed according to the Indian Laws and
Regulations.
195
Dear Sirs,
2.0 Whereas as per Clause …………, of the Contract the CONTRACTOR should have
completed the work of……………. by ……………. and as per the Clause ………… of
the Contract, the PURCHASER is entitled to levy Liquidated Damages for delays.
3.0 Whereas the CONTRACTOR failed to adhere to the Time Schedule or, stipulated in
the Contract for which, the PURCHASER has recovered a sum of Rs/FC……………..
(Rupees/FC………………………….only) towards Liquidated Damages for the delays
in the execution of works in accordance with the Clause………..of the Contract.
4.0 Whereas the CONTRACTOR has requested the PURCHASER for the release of the
said amount withheld towards Liquidated Damages for the delay in execution of work
to enable him to overcome the Liquidity problems. In consideration of the above
request, the PURCHASER has agreed to withheld 10% of the amount recoverable and
to release 90% of amount recovered towards Liquidated Damages subject to the
196
6.0 This guarantee will not be discharged due to the change in the constitution of the Bank
or the CONTRACTOR(S).
7.0 The PURCHASER shall have the fullest liberty without affecting in any way the
liability of the Bank under this guarantee from time to time to extend the time of
performance by the CONTRACTOR. The Bank shall not be released from its liabilities
under these presents by any exercise of the PURCHASER of the liberty with reference
to the matter aforesaid.
8.0 We, the Bank also agree that the PURCHASER shall be entitled at his option to enforce
this Bank Guarantee against the Bank as a Principal debtor in the first instance
notwithstanding any other security or guarantee that it may have in relation to the
CONTRACTOR’S liabilities.
9.0 In any case our liability under this guarantee shall not exceed Rs/FC……………..
(Rupees/FC…………………………only). This guarantee will be valid upto………
(Scheduled date of completion of Contract) and shall be extended for such period as
may be desired by M/s. . . . . . . . . . . . on whose behalf this guarantee has been given.
10.0 The Bank further agrees that the decision of the PURCHASER as to the failure on the
part of the CONTRCTOR to fulfill the contractual obligations stipulated in the said
Contract and/ or to the amount payable by the Bank to the PURCHASER shall be final
conclusive and binding.
11.0 This guarantee is revocable only with the written consent of the PURCHASER.
12.0 This guarantee deed must be returned to us to upon the expiration of the guarantee or
after fulfilment of the obligations specified in the guarantee.
197
a. Our liability under this bank guarantee shall not exceed ……………. (in words)
b. This bank guarantee shall be valid upto…………………..: and
c. We are liable to pay the guaranteed amount or any part thereof under this bank
guarantee only and only if you serve upon us a written claim or demand on or
before…………..
Witness (Signature)
Name in Block Letters
1 Designation
Signature Staff Code No.
Name in Block Letters
Occupation
Address
(Banker’s seal)
2 Attorney as per Power of
Signature Attorney No……………..
Name in Block Letters Dated:……………..
Occupation
Address
198
2. This bank guarantee should be furnished on stamp paper of value not less than Rs. 80.00
3. The stamp paper should have been purchased in the name of the Bank executing the
Guarantee.
4. In the case of foreign bidder the B.G may be furnished by an international reputed bank
acceptable to the PURCHASER/ RBI.
5. The Retention bank guarantee shall be valid till the actual date of completion of Take over
Test.
To
The General Manager/Contracts
M/s. NLC India Limited,
Neyveli - 607 801.
Cuddalore District, Tamil Nadu).
Dear Sirs,
1.0 In consideration of the NLC India Limited, Neyveli (hereinafter referred to as the
`Purchaser' which expression shall unless repugnant to the context or meaning thereof,
include its successors administrators, representatives and assignees),having awarded
to M/s................ with its Registered Office/Head Office at .........(hereinafter referred
to as the "CONTRACTOR", which expression shall, unless repugnant to the context
or meaning thereof, include its successors, administrators, executors, representatives
and assignees) a Contract/ Letter of Award herein after referred to as the
Contract/Letter of Award for `scope of work' on terms and conditions set out interlia in
the Purchaser's Letter of Award/Contract
No . . . . ......... dated . . . . . . ........... as well as contract document valued at
........................ . . . . ......at and the same having been unequivocally accepted by
the Contractor, and whereas the Purchaser under the terms contract has agreed to
199
make the payment of the final 10% value of the contract price of the..... Unit to the
Contractor amounting to........................ (in words) against Retention Money Bank
Guarantee to be furnished by the Contractor.
2.0 For this payment, we, the undersigned............. (Name) ............... (address) with Head
Office at ......... (address) (hereinafter referred to as the `Bank' which expression shall
unless repugnant to the context or meaning thereof include its successors,
administrators, executors, representatives and assignees)do hereby guarantee to the
effect that we irrevocably undertake to pay immediately upon the PURCHASER's first
demand without any previous notice and without any demur, reservations recourse,
contest or protest and/ or without referring to any other sources including the
Contractor, any and all monies, but not exceeding ................ (.....in words) at any
time upto....................... Any such demand made by the Purchaser on the Bank shall be
conclusive and binding notwithstanding any difference between the PURCHASER and
the CONTRACTOR or any dispute pending before any court, Tribunal, Arbitrator or any
other authority. We hereby agree that the Guarantee herein contained shall be irrevocable
and shall continue to be enforceable till the PURCHASER discharges this guarantee.
3.0 The Purchaser shall also have the right to encash the RMBG for the recovery of penalties
in terms of the contract.
4.0 The PURCHASER shall have the fullest liberty without affecting in any way the liability
of the Bank under this guarantee from time to time extend the time performance of the
contract by the CONTRACTOR. The Purchaser shall have full liberty without affecting
this guarantee to postpone from time to time the exercise of any powers vested in them
or of any right which they might have against the Contractor and to exercise the same at
any time in any manner, and either to enforce or to forbear to enforce any covenants
contained or implied in the contract between the Purchaser and the Contractor or any
other course or remedy or security available to the Purchaser. The Bank shall not be
released of its obligations under these presents by any exercise by the Purchaser or
its liberty with reference to matters aforesaid or any of them or by reason of any other
act or forbearance or other acts of omission or commission on the part of the Purchaser
or any other indulgence shown by the Purchaser or by any other matter or thing
whatsoever which under law would but for this provision have the effect of relieving the
Bank. The Bank shall not be released from its liability under these presents by an
exercise of the PURCHASER of the liability with reference to the matter aforesaid.
5.0 The Bank also agrees that the PURCHASER at his option shall be entitled to enforce
this guarantee against the Bank as a principal Debtor, in the first instance, without
proceeding against the Contractor and notwithstanding any other security or guarantee
that the Purchaser may have in relation to the Contractor's liabilities.
200
6.0 a. This guarantee will not be discharged due to the change in the constitution of the Bank
or the Contractor.
b. Notwithstanding anything contained herein above our liability under this guarantee
does not exceed ........ ......... .......... (in words)
c. This guarantee shall remain in force upto and including ...... ......and shall be
extended retaining the same terms and conditions from time to time for such periods
as may be desired by M/s ..........on whose behalf this guarantee has been given.
7.0 The Bank further undertakes not to revoke this guarantee during its currency without the
previous consent of the Purchaser in writing.
This guarantee deed must be returned to us upon the expiration of the guarantee.
a. our liability under this bank guarantee shall not exceed ………… (in words)
c. we are liable to pay the guaranteed amount or any part thereof under this bank
guarantee only and only if you serve upon us a written claim or demand on or
before ………………
Return of this document to us by any person before the aforesaid date will,
however, extinguish our liability as on the date of return.
WITNESS
1. Signature................. Signature.............
(Name in Block Letters)...... Printed Name..........
(Designation) Designation Staff Code No..........
Bank's Seal
2. Signature...................
(Name in Block Letters)........ (Designation)
201
2.0 We,................ Bank........... ...... ....... (address) having its Head Office at .............
......... ......(hereinafter referred to as the 'Bank ' which expression shall, unless
repugnant to the context or meaning thereof, include its successors,
administrators, representatives and assignees) do hereby guarantee and undertake
to pay to NLCIL on on mere demand any and all monies to the extent of ...........
............. (currency and amount in figures) .......... ............ .......... ....... .......... as
aforesaid at any time upto ………….from the date of Letter of Award and till the
obligations under the Contract are completed without any demur, reservation, contest
202
3.0 The Bank do hereby undertake not to revoke this guarantee during its currency without
previous written consent of NLCIL and further agrees that the guarantee herein
contained shall continue to remain enforceable till NLCIL discharges this guarantee.
4.0 Any such demand made by NLCIL on the bank shall be conclusive and binding
notwithstanding any difference between NLCIL and Consortium partners /
Collaborator/Joint Venture Partner pending before any Court, Tribunal, Arbitrator or
any other Authority.
5.0 NLCIL shall have the fullest liberty without affecting in any way the liability of the
Bank under this Guarantee from time to time to extend the time for performance of
the contract of the Collaboration / Consortium Agreement/Joint Venture Agreement
by CONTRACTOR and the Consortium partners / Collaborator/Joint Venture Partner.
6.0 NLCIL shall have the fullest liberty without affecting this guarantee to postpone
from time to time the exercise of any powers vested in them or of any right which
they might have against the CONTRACTOR and the Consortium partners /
Collaborator/Joint Venture Partner and to exercise the same at any time, in any
manner, and either to enforce or to forbear to enforce any covenants, contained or
implied in the said contract or undertaking or any other course or remedy or security
available to NLCIL.
7.0 The Bank shall not be released of its obligations/liabilities under these presents by any
exercise by NLCIL of its liberty with reference to the matters aforesaid or any of
them or by reason of any other acts or omissions or commissions on the part of
NLCIL or any other indulgence shown by NLCIL or by any other matter or thing
whatsoever which under law would, but for this provision, have the effect of
relieving the bank from its obligations. The Bank also agrees that NLCIL at its
option shall be entitled to enforce this Guarantee against the Bank as a Principal
Debtor in the first instance without proceeding against the CONTRACTOR or
Consortium partners / Collaborator/Joint Venture Partner and notwithstanding any
other security or guarantee that NLCIL may have in relation to CONTRACTOR/
Consortium partner’s /Collaborator's/Joint Venture Partner’s liabilities.
8.0 Notwithstanding anything contained herein above our liability under this Guarantee
is restricted to Rs.................... (Rupees) in words and it shall remain in force
upto and including........... .............and shall be extended from time to time for such
period as may be desired by Consortium partners / Collaborator/Joint Venture Partner
on whose behalf this guarantee has been given.
203
a. our liability under this bank guarantee shall not exceed ………… (in words)
b. this bank guarantee shall be valid upto ……………..; and
c. we are liable to pay the guaranteed amount or any part thereof under this bank
guarantee only and only if you serve upon us a written claim or demand on or
before ………………
WITNESS
1. Signature................. Signature.............
(Name in Block Letters)...... Printed Name..........
(Designation) Designation Staff Code No..........
Bank's Seal
2. Signature...................
(Name in Block Letters)........
(Designation)
204
Dear Sirs,
1.0 In consideration of the NLC India Limited, Neyveli hereinafter referred to as the
PURCHASER, which expression shall, unless repugnant to the context or meaning,
thereof include its successors, administrators, representatives and assignees, having
awarded in favour of M/s. ............. ........... ........... ...... ........ having registered office
at ................ hereinafter referred to as the CONTRACTOR, which expression shall
unless repugnant to the context or meaning thereof include its successors,
administrators, representatives and assignees, a Contract, hereinafter "referred as the
CONTRACT" for the ........................ on terms and conditions set out interalia, in the
PURCHASER`s Contract /Letter of Award No......................... dated as well as
"CONTRACT" documents, valued at ........... ............ ........... (In words) and the
same having been unequivocally accepted by the CONTRACTOR and the
CONTRACTOR having agreed to provide a Contract Performance Guarantee for the
faithful performance of the entire "Contract" including the warranty obligations
/liabilities under the contract Equivalent to 10% of the said value of the Contract plus
…..% of the computed price adjustment, if any, to the PURCHASER amounting
to....................................... (In words) as Contract Security in the form of a Bank
Guarantee.
3.0 The Bank further irrevocably guarantees and undertakes to pay on mere demand,
without any demur, reservation, contest, recourse or protest any and all monies due and
payable by the CONTRACTOR by reasons of non-fulfillment of any of the following
obligations.
3.1 For the successful and satisfactory operation of the equipment furnished and erected
under the said Contract as per the specifications and documents.
3.2 That the equipment installed under the said Contract shall be new and in accordance
with Contract Documents and be free from all defects in design, material
workmanship and performance including modifications, improvements and
replacements for a period of 12 calender months, from successful completion of take
over test/commissioning of the equipment and that immediately upon intimation
/written notice from the PURCHASER, the CONTRACTOR shall remedy free of
expenses to the PURCHASER such defects as noticed and developed under the normal
use of the said equipment, within the said guarantee period.
4.0 The PURCHASER shall have the fullest liberty without affecting in any way the
liability of the Bank under this guarantee, from time to time, to extend the time of
performance by the CONTRACTOR. The Bank shall not be released from its liabilities
under these presents by any exercise of the PURCHASER of the liberty with reference
to the matter aforesaid.
5.0 The PURCHASER shall have the fullest liberty, without affecting this guarantee to
postpone from time to time the exercise of any powers vested in them or of any right
which they might have against the CONTRACTOR and to exercise the same at any
time in any manner, and either to enforce or to forbear to enforce any covenants,
contained or implied in the CONTRACT between the PURCHASER and the
CONTRACTOR or any other course or remedy or security available to the
PURCHASER and the BANK shall not be released of its obligations/ liabilities under
these presents by any exercise by the PURCHASER of his liberty with reference to
the matters aforesaid or any of them or by reasons of any other act or forbearance or
other acts of omission or commission on part of the PURCHASER or any other
indulgence shown by the PURCHASER or by any other matter or thing whatsoever
which under law would, but for this provision, have the effect of relieving the Bank
Guarantee. The Bank further undertakes not to revoke this guarantee during its currency
without the previous consent of the PURCHASER.
6.0 The Purchaser shall have the fullest liberty to lodge their claims for encasements of the
guaranteed sum in full or in part, in the manner suitable to them. However, payment
made for a sum lesser than the guaranteed amount, shall not relieve or discharge the
Bank from their obligations guaranteed hereunder, till the contractual obligation are
fully performed by the Contractor or the Bank Guarantee is discharged by the
Purchaser, as the case may be and the Bank Guarantee shall continue to be in force till
such time.
6.1 The Bank further agrees that the decision of the PURCHASER as to the failure on the
part of the CONTRACTOR to fulfill their obligations as aforesaid and/or as to the
206
7.0 The Bank also agrees that the PURCHASER shall be entitled at his option to enforce
this guarantee against the BANK as a principal debtor, in the first instance
notwithstanding any other Security or guarantee that it may have in relation to the
CONTRACTOR`s liabilities.
8.0 This guarantee will not be discharged due to the change in the constitution of the
BANK or the CONTRACTOR(S).
a. our liability under this bank guarantee shall not exceed ………… (in words)
c. we are liable to pay the guaranteed amount or any part thereof under this bank
guarantee only and only if you serve upon us a written claim or demand on or
before ………………
Witness SIGNATURE
1
Signature Name in Block Letters
Name in Block Letters
Designation
Occupation
Staff Code No.
Address
2
Signature
Name in Block Letters (Banker’s seal)
Occupation Attorney as per Power of
Address Attorney No…………dt.……………..
207
WHEREAS NLC India Limited, has awarded to the contractor a contract for
………………………………vide its Letter of Award/Contract No………………………….
date………………… .and its Amendment No.1 and Amendment No.2 (Applicable when
amendments have been issued ) (hereinafter called the “Contract”) in terms of which NLC
INDIA Limited, is required to hand over various equipment to the contractor for execution of
the contract.
That the contractor is obliged and shall remain absolutely responsible for the safe transit/
protection and custody of the Equipment at NLC India Limited, project site against all
risks whatsoever till the Equipment are duly used/ erected in accordance with the terms
208
Page 208 of 328
of the contract and the plant/ package duly erected and commissioned in accordance with
the terms of the contract is taken over by NLC India Limited, The contractor undertakes
to keep NLC India Limited harmless against any loss or damage that may be caused to
the Equipment.
1. The contractor undertakes that the Equipment shall be used exclusively for the
performance /execution of the contract strictly in accordance with its terms and
conditions and no part of the Equipment shall be utilized for any other work or
purpose whatsoever. It is clearly understood by the contractor that non-observance of
the obligations under this, custody cum indemnity bond by the contractor shall
interalia constitute a criminal, breach of trust on the part of the contractor for all
intents and purposes including legal/ penal consequences.
2. That NLC India Limited is and shall remain the exclusive, owner of the Equipment
free from all encumbrances, charges or liens of any kind, whatsoever. The Equipment
shall at all times be open to inspection and checking by Engineer-in-charge/Engineer
or other employees / agents authorised by him in this regard. Further, NLCIL India
Limited shall always be free at all times to take possession of the Equipment in
whatever form the Equipment may be, if in its opinion, the Equipment are likely to be
endangered, misuitilised or converted to uses other than those specified in the
contract, by any acts of omission or commission on the part of the contractor or any
other person or on account of any reason whatsoever and the contractor binds itself
and undertakes to comply with the directions or demand of NLCIL to return the
equipment without any demur or reservation.
3. That this custody cum Indemnity Bond is irrevocable. If at any time any loss or
damage occurs to the Equipment or the same or any part thereof is misutilised in any
manner whatsoever then the contractor hereby agrees that the decision of the
Engineer-in-charge/ Engineer of NLCIL as to assessment of loss or damage to the
equipment shall be final and binding on the contractor. The contractor binds itself
and undertakes to replace the lost and/ or damaged Equipment at its own cost and/ or
shall pay the amount of Loss to NLCIL without any demur, reservation or protest.
This is without prejudice to any other right or remedy that may be available to NLCIL
against the contractor under the contract and under this custody cum Indemnity Bond.
4. NOW THE CONDITION of this bond is that if the contractor shall duly and
punctually comply with the terms and condition of this bond to the satisfaction of
NLCIL THEN, the above shall be void, but otherwise it shall remain in full force and
virtue.
209
Page 209 of 328
Schedule No.1
I Signature ……………………………….
Name………………………………….
Address……………………………..
II Signature……………………………
Name…………………………….
Address……………………………
Indemnity Bonds are to be executed by the authorised persons and (i) in case of contracting
company under common seal of the company or (ii) having the power of attorney issued
under common seal of the company with authority to execute Indemnity Bonds, (iii) in case
(ii), the original power of Attorney if it is specifically for this contract or a Photostat copy of
the power of Attorney if it is General power of Attorney and such documents should be
attached to Indemnity Bond.
210
Page 210 of 328
Appendix - F
This Deed of undertaking executed this .................... ....... day of ............ ........... ........
by ...................... .............. a Company incorporated under ............................ and having
its Registered Office at ...................... .............. ................ herein after called ......................
................ or Consortium partners which expression shall include its successors, executors
and permitted assigns and (Bidder's Name) .................................... a Company
incorporated under the Companies Act 1956 having its registered office at
................... .......... ................. hereinafter called ........... ...................... (Bidder's Name) or
'CONTRACTOR' which expression shall include its successors, executors and permitted
assigns) in favour of NLC India Limited, a company incorporated under the Companies
Act 1956 having its Registered Office at Chennai-600 010 (hereinafter called the
'PURCHASER'), which expression shall include its successors, executors and assigns.
2. Without prejudice to the generality of the undertaking in para -1 above, the methods
of achieving the objectives setforth above shall be as follows:
b. The Consortium partners will be fully responsible for the quality of manufacture
and the timely delivery of all the major components of system manufactured at
his works or at his CONTRACTOR's work for incorporation in the equipment as
per the Contract Schedule.
3. In the event of any breach in the performance of the obligations setforth above, we
the collaborator and the CONTRACTOR, shall jointly and severally pay the loss
or damage to the PURCHASER on his demand. Further we the Consortium
partners and the CONTRACTOR, jointly and severally undertake to pay to
the PURCHASER the liquidated damages arrived at in accordance with the
provisions of the Contract, in the event of any delay in supply or in completion of
functional test including commissioning of the system without any demur,
reservations, protest and recourse. Further, any extension of time, relaxation or
indulgence by the PURCHASER to the CONTRACTOR/ Consortium partners
shall not prejudice the rights of the PURCHASER under this undertaking against the
Consortium partners of the CONTRACTOR.
4. We, the Consortium partners and the CONTRACTOR agree that this undertaking
shall be irrevocable and further agree that this undertaking shall continue to be
enforceable till the end of warranty period under the Contract. We further agree that
this undertaking shall without prejudice to the various liabilities of the
CONTRACTOR including his Contract Performance Guarantee as well as his other
obligations in terms of the Contract.
5. The Performance, rights and responsibility of the party shall be in accordance with the
Contract and further the liability of the CONTRACTOR/ Consortium partners under
this Undertaking shall not in any case exceed the limits as stipulated in the Contract.
212
Page 212 of 328
Contract or after three months. The guarantee amount shall be payable to the
PURCHASER on demand without any condition whatsoever.
……………………………………….
(Official address)
(Official address)
213
Page 213 of 328
NLC INDIA LIMITED
(FORMERLY NEYVELI LIGNITE CORPORATION LIMITED)
(A“Navratna” -Government of India Enterprise)
Block – 1, NEYVELI – 607 801, Cuddalore Dist. Tamil Nadu, INDIA.
Volume-2 of 2
TECHNICAL SPECIFICATION
FOR
Installation of 2 x 10 MW (AC) Grid interactive Solar PV Power Project integrated with
8 MWhr. Battery Energy Storage System at Andaman includes Operation and
Maintenance of the entire system for ten years after one year warranty period
TECHNICAL SPECIFICATION
TABLE OF CONTENTS
NO
1 Project Information 2
2.1.1.1 The 2x10MW (AC) of Grid interactive solar PV power project integrated with
installed capacity of 8 MWhr with ½ hr backup battery energy storage system shall
be designed in such a way that for minimum 11 years ( including 1st year PG period )
the entire system is capable of injecting the smooth power from the solar PV into the
grid and guaranteed net energy export to the existing 33 KV South Andaman Grid as
per requirements stipulated in the relevant clauses of this specification. The general
guiding principles for design basis shall be as follows:
The month wise average solar Insolation values for the project site (Attampahad,
ANI) shall be based on considering the long term published data from NASA,
available for the location.
The established efficiency of solar PV modules at different operating conditions
shall be as per international standards and as per the standards of the
manufacturer in India for the supply of solar cells / modules proposed for this
project.
The design and selection of solar PV module, panel, array configuration, series
and parallel connections, orientation, inverter designs, transformer selection,
power export scheme etc., shall be such as to ensure maximum electric power
generation and minimum loss to the generated power results.
The Contractor should carry out Shadow Analysis at the site along with the
topographic survey for designing strings & arrays layout for optimal usage of
space, material and labour. The Contractor shall submit Shadow Analysis Report
along with the array layout drawings to NLCIL for review and approval. The
Project site location is surrounded with back water from sea. To protect the
2.1.1.6 The Contractor shall design the entire system to meet the requirements of safety and
statutory regulations of the Andaman & Nicobar Administration authorities. If any
modifications are required to meet the Andaman & Nicobar Administration
regulations/requirements, the contractor shall carry out the same without any extra
cost to NLCIL.
2.1.1.7 The equipments and systems shall be designed, manufactured, assembled, tested,
shipped, installed and commissioned according to the applicable codes, standards
and regulations. The design and installation shall be fully in conformity with the
standards and codes as applicable but not limited to the following.
ANSI : American National Standard Institute
ASME : American Standard of Mechanical Engineers
AWS : American Welding Society
ASTM : American Standards for Testing Material
ISO : International Organization for Standardization
ASA : American Standard Association
DIN : Deutsche Industrie Normen
EN : European Standards
SECTION 2.2
SOLAR PV MODULES, ARRAY YARD AND DC SYSTEMS
2.2.1.2 Solar PV Cells offered for this project shall be tested as per testing standards for its
characteristics, surface condition, surface profiling, thickness shape, flatness
measurements, etc. The modules using the solar cells described above shall conform
to latest IEC 61215 in all respects. The contractor shall furnish latest IEC 61215 Test
reports along with constructional data form for the offered PV modules to be
supplied during detailed engineering. The IEC 61215 test certificates and test reports
consisting of list of the Makes & Description of the each component including Solar
PV Cells used in the manufacture of Solar PV modules shall be furnished during
detailed engineering. The solar PV modules of same type and rating (above 240 Wp
rating) will be maintained at each string level. The exact type and rating of solar PV
modules at the respective inverter level will be finalised during detailed engineering.
The Contractor shall submitt IEC 61730 certificate and test reports (for safety
qualification testing) for the offered PV modules. In addition, the bidder shall also
furnish IEC 61701 certificate and test reports (for corrosion testing) for the offered
PV modules during detailed engineering. The Project site location is surrounded
with back water from sea. Any additional protective care in the manufacture of
modules shall be taken to ensure design life of 25 years.
2.2.1.3 All materials used in the Solar PV module shall have a proven history of reliability
and stable operation in external applications. It shall perform satisfactorily in high
relative humidity with atmospheric temperatures prevailing at the site and should
have lowest temperature coefficient and shall withstand gust prevailing at site on the
surface of the panel. Each and every SPV module shall be checked for conformity
with relevant standard. Modules shall not have negative tolerance and the same shall
be incorporated in manufacturing and inscribed in the name plate rating.
2.2.1.5 PV modules after manufacture must be tested for random sample and approved by
one of the NABL accredited Test Centres in India/International Laboratory
Accreditation Cooperation (ILAC) Member Labs in abroad. Manufacturing Quality
Plan for PV modules shall be submitted for approval by NLCIL. Random sample
testing by NLCIL during manufacture of PV Modules shall be included in the MQP.
2.2.1.6 Solar PV Peak power rating of the module shall not be less than 240Wp. The module
conversion efficiency shall be minimum 15% and above under standard test
conditions. The cell should have minimum fill factor of 0.7. It shall be made of high
transitivity glass and front surface shall give high encapsulation gain.
2.2.1.7 The front surface of the module shall consist of impact resistant, low iron and high
transmission, toughened, plain/patterned glass.
2.2.1.9 The module frame shall be made of corrosion resistance materials, preferably having
aluminium anodized finish.
2.2.1.10 Minimum clearance between the lower edge of the modules and the developed
ground level shall be finalised during detailed engineering.
2.2.1.11 Bidder shall carefully design complete layout and arrangement of equipments in the
land available and requisite number of modules shall be installed to achieve the rated
power generation and guaranteed net energy export. The inter row distance between
solar PV arrays shall be sufficient for easy movement of men / materials for panel
cleaning, maintenance works, etc.
If the solar PV Modules fail to conform to this warranty, the manufacturer will repair
or replace the solar modules as per contract terms.
2.2.1.15 Modules shall be provided with a Module junction box of minimum IP 65 rated
high quality enclosure with provision for external terminal connection and
adequate capacity by-pass diodes. The Module junction box should have
weatherproof lid, cable gland entry points and connecting copper cable with
MC4 type/equivalent/compatible connector.
10
2.2.2.2 Each string shall have a suitable fuse to prevent the reverse current flow with
suitable arrangement for its connection. Y harness is allowed for paralleling two
strings. The Array Junction Box shall have suitable surge protection device (SPD)
and shall consist of Metal Oxide Variasters (MOV) which shall be provided between
positive and negative conductor and earth ground. DC photovoltaic fuses for positive
side for each string shall be provided and shall have fuse holder with fuse blown
indication, easy to isolate the string during fault conditions. It shall be so designed
that it should protect the modules from reverse current flow.
2.2.2.3 The Surge Protection Device shall have following minimum specifications.
Repetitive Surges x15(8/20 μS) In : 20kA
Surge Current (8/20 μS) Imax : 40kA
During earth fault and failure of MOV, the SPD shall be capable of safely
disconnecting the healthy system. SPD shall have thermal disconnector to interrupt
the surge current arising from internal and external faults. In order to avoid the fire
hazard due to possible DC arcing in the SPD due to operation of thermal
disconnector, the SPD shall be capable of extinguishing the arc by itself.
2.2.2.4 The String Monitoring Units shall be tested using automatic calibration tools so that
the accuracy of measured current and voltage reading shall be within +- 0.15%.
2.2.2.5 The Array Junction Box / Combiner box and String Monitoring Unit shall have
suitable arrangement for the following:
Combine a cluster or group of modules into independent
charging string that will be wired through the String Monitoring
Unit.
Provides DC Isolator of suitable rating for disconnection at the
outgoing.
Provides a test point for each sub-group for quick fault location.
11
2.2.2.6 The String Monitoring Units shall be Intelligent, multichannel, industrial grade,
reliable, field proven microprocessor based unit. Required operating power shall be
made available to the String Monitoring Units from the respective PCSS 110V DC,
UPS and 230 V AC Auxiliary power supply system through cable network. DC to
DC converter for String Monitoring Unit power supply is also acceptable. Solar
power shall be utilized to power the SMU by employing a suitably sized DC-DC
converter. The constructional, operational, connectivity and communication features
of the SMU are further elaborated in the control and automation section of this
specification.
2.2.3.1 The offer shall include adequate array yard lighting including erection of poles,
fixtures and cables as per IS standards, keeping the general security in mind. Watch
Tower lightings shall be installed to cover the solar power plant boundary lighting. A
minimum illumination level of 10 lux shall be maintained in the internal roads /
pathways. It is preferable to adopt low height bollard type road / path way
illuminators to avoid shadow on adjoining solar PV modules where ever warranted.
The yard lighting and watch tower lighting shall be fed from the station auxiliary
power system of the nearest PCSS. The lighting power from each PCSS shall be
taken to surrounding road / yard lights and watch tower lights through buried cable
network. Automated switching control shall be made available for the yard / road
and watch tower lighting system. Array yard lighting schemes and design
calculations along with drawings shall be submitted for approval by NLCIL.
2.2.4 DC CABLES
2.2.4.1 DC cables used for inter connecting PV modules and for PV modules to array
junction boxes / combiner boxes shall be FRLS, copper conductor cables and shall
be electron beam cured with (+) and (-) colour identification, conforming to the
requirements of TUV Specification 2Pfg 1169/08.2007.
12
2.2.4.2 Sizing of DC cable for PV array shall be selected in such a way that the maximum
voltage drop at full power from the first PV module to inverter should be less than
+3% (Including voltage drop in module to module interconnecting cable).
2.2.4.3 The Contractor shall design the array yard such that module mismatch loss shall be
less than 2% loss in system power.
2.2.4.4 For inter connecting PV modules, no cable joints shall be used. MC4
equivalent/compatible connectors with necessary length of DC cables with positive
and negative ends, which are built in component of the PV Modules, shall be used
for interconnection of PV modules. DC cables for PV modules to Array junction
box/ Combiner box and String Monitoring Unit shall be provided without any cable
joints.
2.2.4.5 Cable terminations at Array JB, Combiner Box, SMU shall be made with suitable
cable lugs and sockets etc, crimped properly and passed through suitable type cable
glands (Double compression) at the entry and exit point of the cubicles. The panel
bottoms should be properly sealed to prevent entry of snakes/lizard etc. inside the
panel.
2.2.4.6 All cables shall be marked with good quality letter and number ferrules of proper
sizes so that the cables can be identified easily.
2.2.4.7 Cables shall be fixed to non-moving module mounting structure / column with
adequate looping for allowing tilt of the module frame. Bunching of cables and tying
to module frame with cable ties shall not be adopted as temperature rise of module
frame tend to increase cable power loss and reduce cable life. All cable routed in the
array yard shall be laid taking into consideration of undulated, sloppy terrain of the
project site. Cable duct bank/hume pipe shall be provided for road crossings. For
buried cabling necessary cable markers shall be provided along the route.
2.2.4.8 Cable selection and sizing calculations and detailed explanations along with
catalogues shall be submitted for approval by NLCIL.
13
2.2.5.2 The lightning conductors shall be designed as per Indian Standards in order to
protect the entire Array Yard from lightning stroke including PCSS structure.
Necessary concrete foundation for holding the lightning conductor and spike in
position shall be made after giving due consideration to its shadow on adjoining
solar PV modules, maximum wind speed and maintenance requirement at site in
future.
2.2.5.3 The lightning conductor shall be earthed through flats and connected to the earth
mats with earth pits as per applicable Indian Standards. Lightning protection of Early
Streamer Emission (ESE) type as per NFC 17-102 is also acceptable. The protection
class shall be minimum class II or higher as per NFC 17-102 (2011). Where ever
required, Air Terminals shall be provided at the highest point, especially in PCSS as
well as in watch towers. Each lightning conductor shall be fitted with individual
earth pit as per standards with earth electrode of 3M length including accessories and
masonry enclosure with cover plate as per IS 3043. The pit around the electrode
shall be treated with carbon based earth enhancement compound or conductive
concrete as per provisions of IS 3043. Test links shall be provided in the down
conductor as per standards.
2.2.5.4 Design calculations of the lightning system along with drawings shall be submitted
for approval by NLCIL.
2.2.6.1 The earthing for array yard shall be made with earth electrode of
3 M length including accessories and masonry enclosure with cover plate as per IS
3043. The pit around the electrode shall be treated with carbon based earth
enhancement compound or conductive concrete as required as per provisions of IS
3043. Necessary provision shall be made for bolted isolating joints of each earthing
pit for periodic checking of earth resistance. Soil resistivity measurement at the
project site shall be made by the contractor before commencing the earthing system
design.
2.2.6.2 Each Array structure of the Solar PV Yard shall be grounded properly. The array
structures are to be connected to earth pits as per IS standards.
2.2.6.3 The complete earthing system shall be mechanically and electrically connected to
provide independent return to earth. All equipments shall have two distinct earth
connections.
2.2.6.4 For each earth pit, necessary Test Point shall be provided.
14
2.2.6.6 The bidder shall ensure adequate earthing system protection to provide an acceptable
degree of protection as per IS 3043 for the array yard equipment. If necessary, more
numbers of earth pit and conductors may be provided to achieve earthing resistance
less than 1 Ohm. Design calculations along with drawings shall be submitted for
approval by NLCIL.
2.2.6.7 Earth resistance of the earth pits shall be tested in the presence of the NLCIL
officials.
2.2.7.1 All structures, boxes, panels and all other items except Galvanized and non-metallic
items shall be provided with approved scheme of surface paint.
2.2.7.2 Surface preparation - The surface preparation procedure shall be done as per IS:
1477 Part-1C16.2.1.2 for power tool cleaning or equivalent DIN standard st.3 or as
per paint manufacturer’s recommendation.
15
The paint shall be applied immediately after surface preparation to the specified
quality, preferably within two hours. Prior approval shall be obtained from NLCIL
regarding type of paint and manufacturer
2.2.7.5 Colour code -The shade of finish paint coat to be applied shall be as per IS: 5.The
colour scheme shall be approved by NLCIL.
2.2.7.6 Cathodic protection may also be incorporated to achieve longevity of structures for
surface protection from corrosion.
2.2.8 OTHERS
2.2.8.1 Any array yard work which is not mentioned or included here but necessary for safe
operation, maintenance, longevity and improvement in performance of the plant
shall be included in scope and carried out.
SECTION 2.3
ELECTRICAL POWER COLLECTION& EXPORT SYSTEMS
2.3.1.2 Cables of adequate size shall transfer the DC power for conversion in to AC in the
inverters. The location of each PCSS shall be selected in such a way to minimise
cable losses.
2.3.1.3 The indoor Power Collection Sub Station (PCSS), shall be RCC building as per
section 2.4.
16
2.3.1.5.1 The Power Conversion Units shall consist of an electronic inverter along with
associated control, protection and data logging devices. The system shall incorporate
a unidirectional inverter and should be designed to supply the AC power to the grid
at load end. The power conversion unit shall adjust the voltage and frequency levels
to suit the grid. All three phases shall be supervised with respect to rise/fall in
programmable threshold values of frequency. The PCU shall conform to IEC 62109
or equivalent standards for safety certification. The PCU shall have provision to be
isolated from grid through Air Circuit Breakers which shall be inbuilt with the
inverter or separate standalone panel.
2.3.1.5.2 PCU shall confirm to IEC 60068-2 standards for Environmental Testing.
2.3.1.5.3 The efficiency of the PCU shall be equal to or more than 98 % at 75% load as per
IEC- 61683. The bidder shall submit the conversion efficiency curve on partial
output powers for the inverter in his offer. The bidder should specify the overload
capacity in the bid.
2.3.1.5.4 The inverter should be warranted for minimum 5 years and the service life of the
inverter shall not be less than 25 years under harsh environmental conditions.
.
2.3.1.5.5 The PCU inverter shall capable to supply or absorb the reactive power for the grid pf
0.95 lead-lag. The PCU inverter shall also support for grid dynamic power factor of
0.8 lag-lead within its rated KVA capacity. The PCU shall have internal protection
arrangement against any sustained fault in the feeder line and against lightning in the
feeder line.
2.3.1.5.6 The PCU inverter shall have the required protection arrangements against earth
leakage faults.
17
2.3.1.5.8 The PCU inverter shall be transformer less design with necessary provision for
galvanic isolation. Each solid-state electronic device shall have to be protected to
ensure long life of the inverter as well as smooth functioning of the inverter.
2.3.1.5.9 The PCU inverter shall have special safety features like active anti islanding
detection and isolation facility as well as modular system features to harness solar
power during lesser irradiation conditions and to maintain equal aging of inverter
modular system. The PCUs shall conform to the latest edition of IEEE1547/UL
1741/ equivalent for protection against islanding of grid.
2.3.1.5.10 The PCU inverter must and be able to be successively switched “ON” and “OFF”
automatically based on solar radiation variations during the day.
2.3.1.5.11 Inverter system shall tend to balance unequal phase voltage (with 3-phase systems)
with reference to the red phase (line-1). Protection shall include negative sequence
protection also such that if the balancing of 3 Phase system failed, the protection
shall envisage isolation of the inverter from the circuit.
2.3.1.5.12 The PCU inverter front panel shall be provided with a display (LCD or equivalent/
LED + Mobile App Display) of all important parameters such as DC input voltage,
DC input current, AC output voltage, AC output current, AC output power, power
factor, frequency etc. In addition to the display in PCU panel, the same shall be
made available in the monitoring and controlling desk installed in the project
control room forming part of the supervisory control and data acquisition system
(SCADA) and EMS.
2.3.1.5.13 The PCU enclosure and internals including nuts, bolts etc shall have to be
adequately protected, taking into consideration the atmosphere and weather
prevailing in the area.
2.3.1.5.14 Dimensions and weight of the PCU shall be indicated by the bidder in the offer.
2.3.1.5.15 The PCU shall include appropriate self protective and self diagnostic feature to
protect itself and the PV array from damage in the event of PCU component
failure or from parameters beyond the PCU’s safe operating range due to
internal or external causes. The self-protective features shall not allow signals
from the PCU front panel to cause the PCU to be operated in a manner which
may be unsafe or damaging. Faults due to malfunctioning within the PCU,
including commutation failure, shall be cleared by the PCU protective devices.
18
2.3.1.5.16 PCU shall have arrangement for adjusting DC input current and should trip
against sustainable fault downstream and shall not start till the fault is rectified.
2.3.1.5.18 Bill of materials associated with PCUs should be clearly indicated while
delivering the equipment.
2.3.1.5.19 Standby Mode - The control system shall continuously monitor the output of the
solar power plant until pre-set value is exceeded and that value to be indicated.
2.3.1.5.20 Basic System Operation (Full Auto Mode) - The system shall automatically
“wake up” in the morning and begin to export power provided there is sufficient
solar irradiance and the grid voltage and frequency is in range.
2.3.1.5.21 Maximum Power Point Tracker (MPPT) – MPPT control algorithm shall adjust
the voltage of the SPV array to optimize energy fed into the grid.
2.3.1.5.22 Sleep Mode - Automatic “sleep” mode shall be provided so that unnecessary
losses are minimized at night. The power conditioner must also automatically
re-enter standby mode when threshold of standby mode is reached.
2.3.1.5.23 Maximum Power Point Tracking (MPPT) - Maximum power point tracker shall
be integrated in the power conditioner unit to maximize energy drawn from the
Solar PV array at all seasons and in varying solar insolation conditions. The
MPPT should be microprocessor based to minimize power losses. The details of
working mechanism of MPPT shall be furnished by the Contractor. The MPPT
must have provision for constant voltage operation. The MPPT unit shall
conform to IEC 62093 for design qualification. Multi MPPT and Master –Slave
configuration shall also be considered as applicable. The MPPT shall conform
to EN50530.
2.3.1.5.24 The inverter output shall always follow the grid in terms of voltage and
frequency. This shall be achieved by sensing the grid voltage & phase and
feeding this information to the feedback loop of the inverter. This control
variable shall then control the output voltage and frequency of the inverter, so
19
20
2.3.1.6 AC BREAKER
2.3.1.6.1 AC converted in the PCUs shall be transmitted through an AC breaker. AC
breaker as part of PCU inbuilt is also acceptable. Outgoings of the AC breaker
shall be connected to the HT transformer through appropriate size aluminium
cables.
2.3.1.6.3 The Contractor shall submit design calculations and drawings for the AC
Breaker for approval by NLCIL.
21
22
2.3.1.7.3 The transformer shall be of proven design and robust maintenance free
construction featuring liberal use of active materials viz. core iron and copper to
keep down losses at low levels and consequently the operating temperature well
within the limits of oil cooled transformers.
23
24
25
26
27
2.3.1.8 HT Breaker
2.3.1.8.1 Standards and Construction Features
The HT switchgear distribution board shall conform to IS 3427, IS 12729 and IS
13118 for all essential features of design, construction and testing. The board
shall be factory assembled and wired, totally enclosed, dead front, draw out
type, fully interlocked and compartmental design.
2.3.1.8.1.1 The switchgear must provide a maximum degree of personal safety and
operational security for the operators and others in the vicinity of the switchgear
under all operating and fault conditions. To fulfil the high safety requirement for
personnel, the switchgear insulation must be designed to provide the best
possible protection in the event of an arc fault. To ensure this condition, all
compartments of the switchgear shall satisfy the requirements of IEC 298.
2.3.1.8.1.2 The products of the arc shall not transport from one compartment to another.
There must be no danger to any person standing at the front or to the side of the
switchgear, caused by the venting of hot gases or the scattering of other
products of the arc. The circuit breaker compartment shall also meet the above
test requirement while the circuit breaker is being raked in or out of service.
2.3.1.8.1.3 The bus bars shall be of electrolytic grade copper, air insulated and housed in a
separate metal clad chamber at the top. The bus bars shall be provided with
insulation sleeving rated for full system voltage. Adequate electrical clearances
between live parts and between live part and earth shall be provided. The cross
28
2.3.1.8.1.4 The cable compartment shall be located at the bottom and shall be accessible
through bolted cover plates at the rear. The current transformers shall also be
located in the cable compartment.
2.3.1.8.1.5 The HT switchboard shall be provided with earthing truck or earthing switch
with safety interlock features for bus earthing and outgoing cable earthing. The
earthing switch / truck shall be interlocked with the circuit breaker so that it can
be closed only when the circuit breaker is racked out to isolated position. The
interlock shall also ensure that the cable side or bus side is dead before earth
switch is closed through voltage metering facility, audio visual alarm and
holding solenoid.
2.3.1.8.1.6 A copper earth bus shall be provided at the bottom of the switchboard
throughout its length. The switchboard, devices and terminal blocks shall be
provided with legibly engraved inscription plates for identification. The
switchboard shall be provided with caution notice boards conforming to IS 2551
in the front and rear.
2.3.1.8.1.7 The circuit breaker compartment of the switchboard shall have a fixed and a
moving portion, fixed portion being part of the switchboard. The moving
portion shall contain the circuit breaker of horizontal draw out design mounted
on a truck. The circuit breaker compartment shall have a front hinged door after
opening of which the circuit breaker shall be accessible.
2.3.1.8.1.8 The design of the board shall permit the moving portions to be withdrawn and
provide for isolation of the main contacts by means of plug and socket
connections. Automatic safety shutters shall be provided over the isolating
contacts in the stationary portion and shall be so designed as to close firmly over
the contacts when the circuit breaker is in drawn out position. The draw out
mechanism of the circuit breaker shall have Service, Isolated and Test positions
2.3.1.8.1.9 In the design of the switchgear, the following positive inter-locking shall be
provided:
2.3.1.8.1.10 Interlock to prevent movement of truck to “Service” position without
engaging secondary plug socket connections.
2.3.1.8.1.11 Interlock to prevent disconnection of secondary plug socket connection in
“Service” position.
2.3.1.8.1.12 Interlock to prevent withdrawal of truck past “Isolated” position without
disconnecting secondary plug socket connection.
2.3.1.8.1.13 Interlock to prevent switching ON of breaker unless truck is properly engaged in
“Service” or “Isolated” positions.
29
Front door shall be interlocked with the breaker such that the door cannot be
opened with the circuit breaker in service position or can the circuit breaker
inserted into the service position with door open. It shall be possible to defeat
the interlock with use of tools if this becomes necessary.
2.3.1.8.2.2 The duty requirement of the Circuit breaker shall be C2/M1class under all duty
conditions and shall be capable of performing their duties without opening
resistor. The circuit breaker shall meet the duty requirement of any type of fault
or fault location and shall be suitable for line charging and dropping when used
on HT effectively grounded or ungrounded systems and perform make and
break operations as per the stipulated duty cycles satisfactorily. The circuit
breaker shall be capable for breaking the steady & transient magnetizing current
corresponding to HV transformers. It shall also be capable of breaking line
charging currents as per IEC- 62271-100 with a voltage factor of 1.4. The rated
transient recovery voltage for terminal fault and short line faults shall be as per
IEC: 62271-100.
2.3.1.8.2.3 The Contractor shall indicate the noise level of breaker at a distance of 50 to
150 m from base of the breaker.
30
31
One (1) additional CT core of 0.2 S class shall be provided in the outgoing
breaker as redundancy for metering.
32
2.3.1.10.2 Battery
Type of cell : Valve regulated lead acid type (VRLA) only and the
battery shall be located in the ventilated room for RMU.
Nominal DC voltage : 110V DC
Load : To meet the requirements of breakers, ventilation fans, system
panels, IMU and SMU.
Battery capacity : Ah to suit based on 10 hour rate of
discharge
Duty : Sub Station duty
End cell voltage : 1.85 Volts (C10 or higher battery
33
2.3.1.10.3.2 The charger shall consist of input switchgears, two winding transformer, SCRs
and diodes, regulator, filter circuit, output switchgear, metering and protective
devices for under voltage, over voltage and earth fault, alarm indicator circuit
and integral DC distribution board. All necessary indications and meters like
AC voltmeter, DC voltmeter, DC ammeter etc. shall be provided. Indication for
DC battery connected to load shall also be provided.
2.3.1.10.3.4 Both float and boost chargers shall have control device to vary the voltage to
achieve the desired output.
2.3.1.10.3.5 The output voltage of bridge for float charger shall be 120V DC max. The
output voltage of the bridge for boost charger shall be 145V DC max.
2.3.1.10.3.6 The charger shall be provided with auto-changeover circuitry from float to boost
and vice versa in addition to manual changeover switch. The float circuit shall
be designed for supplying the continuous load current as well as charge the
battery. The boost circuit shall be suitable for delivering charging current
suitable for 110V, battery. RMS ripple factor in input voltage of the charger
shall not be more than 3%.
2.3.1.10.3.7 The charger shall be provided necessary communication port for interfacing
with plant SCADA for remote monitoring and control through Station Facility
Controller.
34
35
2.3.1.13.2 Lighting Power System in each PCSS for powering the lights inside PCSS, yard
lights and watch tower lights near each PCSS shall be derived from Auxiliary
power system PDB with necessary controls and cabling. All outdoor lighting
circuits will be controlled through industrial timers provided at LDBs.
2.3.1.13.3 PCSS Lighting and Lighting Power System design, calculations and drawings
shall be submitted for approval by NLCIL.
2.3.1.14.1.2 The insulation for the conductor shall be of high quality XLPE compound. The
insulation shall be applied through an extrusion process and chemically cross
linked in continuous vulcanizing process. The cable shall be shielded with
metallic tape over the extruded semi-conducting shield. The cores shall be
identified either by colour tape along the insulated core or running a number
tape along the conductor. The cable shall be provided with inner sheath either
with suitable fillers in the interstices and covered with a common tape or an
extruded sheath of required thickness. Armouring over the inner sheath shall be
provided with flat steel strips or steel wire. Outer sheath for the cable shall be
provided with heat resistant PVC compound to IS: 5831. The outer sheath shall
also be extruded over the steel armouring. The colour of the outer sheath shall
be black or orange.
36
2.3.1.14.1.4 Manufacturer’s identification mark, NLCIL mark along with ISI certification
mark shall be printed on the outer sheath of the cable as stipulated in IS 7098
part1 and part 2 of 1985 as applicable.
2.3.1.14.2.2 The cable used in the work shall be as far as possible of one manufacturer only.
The cables used in the yard shall be delivered to the site as complete coiled
drums/coils with wrapping seals intact. The contractor shall provide
manufacturer’s test certificate and date of manufacture at the time of delivering
the cables to the site. All multi-core cable drums shall be from manufacturer and
unwound cables delivered to site shall not be approved for installation
2.3.1.14.2.2 The cable conductor shall be of electrolytic pure grade Aluminium conforming to
IS 8130 of 1984.
2.3.1.14.2.3 All cables shall be fitted with suitable compression or packing ring to protect the
same from ingress of water and moisture. All glands shall be provided with
locking nut, earth tag and PVC cable shoe/shroud. PVC insulated earth
continuity conductors of appropriate size in conformity with Indian Electricity
Rules shall connect all earth tags to the main earth bars at terminations of cables.
37
2.3.1.14.2.4 The compression type cable lugs shall be used for terminations. The Crimping
termination of the cables shall be carried out with the help of correct compression
type crimping tool with proper size dies. The compression tools and terminations
materials shall be from a single manufacturer and care shall be taken to adhere to
manufacturer’s recommendations. PVC shoe/ shroud shall be fitted to cable
terminations to prevent dust and moisture entry into terminations.
2.3.1.14.2.5 Only terminal cable joints shall be accepted. No cable joint to join two cable ends
shall be accepted.
2.3.1.14.2.6 All LV cables shall be tested for insulation resistance and continuity test at two
stages.
2.3.1.14.2.6.1 Insulation and continuity test before after laying but before backfilling.
2.3.1.14.2.6.2 Insulation and continuity test after backfilling.
h) Cable shall be laid in the cable trench in PCSS building, routed in cable
trays on the module frames and Combiner box / Array JB support frames and
shall be buried in the yard with suitable protection. The type and specification of
the cable tray used and cable burying scheme shall be submitted for approval by
NLCIL before commencement of work.
2.3.1.14.3.2 The stranded conductor shall be made of thin strands of electrolytic copper not
less than 0.25mm. The number of strands shall be suitable for the size of the
cable. However the minimum number of strands shall be as follows:
38
2.3.1.14.3.3 All wiring for connecting various fittings shall be through steel conduits of
approved make. All Tees, Bends etc shall be of standard make. Approval for
materials should be obtained from NLCIL.
2.3.1.14.4 Control, Data, FAS and Communication cabling shall be selected to suit the
system configuration adopted by the contractor and as discussed further in
automation and control system of this specification. The cabling and
accessories for the same shall confirm to relevant IEC/ IS codes and practices.
2.3.1.14.5 Cable terminations shall be made with suitable cable lugs & sockets etc,
crimped properly and passed through brass compression type cable glands at the
entry & exit point of the cubicles. The panel bottoms should be properly sealed
to prevent entry of snakes/lizard etc. inside the panel.
2.3.1.14.6 All cable/wires shall be marked with good quality letter and number ferrules of
proper sizes so that the cables can be identified easily.
2.3.1.14.7 Cable sizing shall be based on voltage drop not exceeding 1% on DC side and
not exceeding 3% on AC side between source and load. Power and Control
cabling and wiring design and calculations with drawings shall be submitted for
approval by NLCIL.
2.3.1.16.2 The Lightning protection system for PCSS shall comprise of lightning
conductors on the roof with spike rods at the highest point above roof. The
system shall be designed as per Indian Standards / IEEE in order to protect the
entire Power Collection Sub Station from Lightning stroke.
39
2.3.1.17.2 The earthing for the power collection substation equipment shall be made as per
provisions of IS. Necessary provision shall be made for bolted isolating joints of
each earthing pit for periodic checking of earth resistance.
2.3.1.17.3 The complete earthing system shall be mechanically & electrically connected to
provide independent return to earth. All equipments shall have two distinct earth
connections.
2.3.1.17.4 For each earth pit, necessary Test Point shall have to be provided.
2.3.1.17.5 In compliance to Rule 33 and 61 of Indian Electricity Rules, 1956 (as amended
up to date), all non-current carrying metal parts shall be earthed with two
separate and distinct earth continuity conductors to an efficient earth electrode.
2.3.1.17.6 The contractor shall ensure adequate Earthing system protection to provide an
acceptable degree of protection as per IS for each PCSS. If necessary more
numbers of Earth pit & conductors may be provided. Theoretical earthing
design calculations with necessary drawings shall be submitted for approval by
NLCIL.
2.3.1.17.7 Earth resistance of the earth pits shall be tested in the presence of the
representative of NLCIL.
40
41
2.3.2.5 The 33KV Outdoor Switchyard Equipments include Circuit breaker, Current
Transformers, Potential Transformers, Isolators, Surge arresters, Aluminium bus,
ACSR conductors, Clamps and connectors, Columns, beams, poles, Support
Insulators, String insulators, Bus post /Pole Insulators, earth wire, HV/LV power,
control cables, communication cables etc., as per the requirement of CEA rules
and norms and as per A & N Electricity Department requirements.
2.3.2.6 CONDUCTOR
This specification covers design, manufacture, testing before dispatch, supply
and delivery of Aluminum Conductors Steel Reinforced (ACSR) Conductors.
Bus bar conductor shall be ‘Zebra’ ACSR Conductor. Conductor sizing
calculation for 33KV bus bar shall be submitted to the purchaser for establishing
42
2.3.2.7.1 The structural work shall include design, fabrication and supply of all
switchyard structures, galvanized steel structural work for
equipment supports, towers and lightning masts. All structural
steel shall be of mild steel confirming to the latest edition of the
standard as stated hereunder.
2.3.2.7.2 I.S. 2062 / 226 Specification for structural steel and quality steel.
2.3.2.7.3 I.S. 802. Use of structural steel in over head transmission line.
2.3.2.7.4 I.S 806 Code of practice for use of steel tubes.
2.3.2.7.5 I.S. 808 Specification of rolled steel, channel, beam and angle sections
43
2.3.2.8.6 Substation gantry structures shall be designed for 2 conditions i.e. Normal
condition & Short Circuit Conditions. Factor of safety of 2.0
under Normal conditions & 1.5 under Short Circuit condition
shall be taken.
2.3.2.8.7 Vertical levels of half the span of conductors/ string & the Earth wire on either
side of beam shall be taken for design.
2.3.2.8.9 The contractor shall furnish design, drawing, Bill of Material (BoM) of
structures on award of contract. The design drawing should
clearly indicate sections numbers and sizes of the bolts &
details of typical joints, member wise weights & total weight
of the structure.
2.3.2.8.10 There should be provision of connectivity of beam in the last feeder gantries for
future beam.
2.3.2.8.11 As designing is in the scope of contractor, supply/approval of design & drawing
shall not relieve the contractor from his responsibility for :–
2.3.2.8.11.1 Observing all the required clearances (phase to phase, phase to earth, sectional
clearances & ground clearances) as per tender specifications.
2.3.2.8.11.2 Calculation of force at all the joints/sections and their load carrying capacity
shall be as per details of design requirements given above.
2.3.2.8.12 Minimum thickness of members other than bracings shall be 5 mm and that for
bracings shall be 4 mm.
44
2.3.2.8.21 The structures may be erected by assembling in sections on the ground and hoisting
successive sections into place, or they may be built up in place by individual
members at the option of the contractor. If erected by assembling in sections, not
less than 50 percent of all bolting in place shall be done on each section before
starting another section.
2.3.2.8.22 All bolts shall be drawn up tight but not to such a degree as to endanger the strength
of the bolt. Wrenches approved by the engineer shall only be used on the work and
the use of any wrench, which may deform the nut or cut or flake galvanizing shall
not be permitted.
2.3.2.8.23 Reasonable amount of drift shall be allowed in assembling but reaming for
correction of mismatched holes shall not be permitted.
2.3.2.8.24 During structural erection inspection shall be carried out at every stage o identify all
loose bolts or other errors in erection are rectified in time.
2.3.2.8.25 All exposed structural steel shall be hot dip galvanized as per IS 4759. The
thickness of zinc coating shall not be less than 610 g/m².
2.3.2.8.26 All bolts, nuts and washers shall be hot dip galvanized as per IS 1367.
2.3.2.8.28 All foundation bolts shall be galvanized as per IS 5624 up to a depth of 300 mm
(minimum) below top of pedestal.
45
46
2.3.2.11 ISOLATORS
2.3.2.11.1 The isolators and accessories shall conform in general to IEC 62271-102 (or
equivalent Indian standard) except to the extent explicitly
modified in specification.
2.3.2.11.2 Earth switches shall be provided on isolators wherever called for.
Rated short time current of isolator and 25kA (rms) for 3 sec
earth switch
Rated dynamic short time withstand current
of isolator and earth switch 62.5kA (peak)
Impulse withstand voltage with 1.2/50 170kVp to earth 195 kVp across
micro sec. wave isolating distance
One minute Power frequency withstand 70 kV (rms) to earth & 80kV (rms)
Voltage across isolating distance
Temperature rise As per Table-IV of IS: 9921
Rated mechanical terminal load As per 62271-102
Safe duration of over load
150 % of rated current 5 minutes
120% of rated current 30 minutes
Creepage distance (Total) 900 mm
Temperature rise Max.Temp deg.C
a. Copper contacts in air
Silver faced Copper 105
Bare copper 75
b. Terminal of isolator to be connected to
Silver faced copper 105
Bare copper 90
48
2.3.2.11.6 They shall be constructed such that they do not open under influence of short
circuit current and wind pressure together. The earth switches
wherever provided shall be constructional interlocked so that the
earth switches can be operated only when the isolator is open
and vice-versa.
2.3.2.11.7 In addition to the constructional interlock, isolator and earth switches shall have
provision to prevent their electrical and manual operation unless
the associated and other interlocking conditions are met.
2.3.2.12.1.3 The instrument transformers shall be oil filled hermetically sealed units. The
instrument transformers shall be provided with filling and drain plugs.
2.3.2.12.1.4 Polarity marks shall indelibly be marked on each instrument transformer and at
the lead terminals at the associated terminal block.
2.3.2.12.1.5 The insulators shall have cantilever strength of more than 500 kg.
2.3.2.12.1.6 MARSHALLING BOX
The wiring diagram for the interconnection of three phase instrument
transformer shall be pasted inside the box in such a manner so that it is visible
and it does not deteriorate with time. Terminal blocks in the marshaling box
shall have facility for star/delta formation, short circuiting and grounding of
secondary terminals. The box shall have enough terminals to wire all control
circuits plus 20 spare terminals.
49
50
51
2.3.2.14.1 Type certificates and reports as per relevant standards shall be submitted for
NLCIL approval for Current Transformers, Voltage Transformers Breakers,
Isolators and Surge arrestors. These reports should be for the test conducted on
the equipment similar to those proposed to be supplied under this contract.
52
2.3.2.15.2 The lightning protection for switch yard shall comprise of vertical air
terminations mounted on steel tower. The system shall be designed as per
Indian Standards / IEEE in order to protect the entire switch yard and 33 KV
POWER EXPORT SWITCHYARD from lightning stroke. The towers shall
be interconnected using shield wire. The tower shall also be used for fixing
light fittings for illumination of switchyard.
2.3.2.15.3 The lightning conductor shall be earthed through flats and connected to the
Earth mats as per applicable Indian Standards with earth pits. Each
Lightning Conductor shall be connected to an individual earth pit as per
required Standards including accessories.
2.3.2.15.4 Theoretical lightning design calculations and drawings shall be submitted for
approval by NLCIL. The detailed requirement for lightning protection is
furnished under lightning and earthing section of this technical specification
53
2.3.2.16.5 For each earth pit, necessary Test Point shall have to be provided.
2.3.2.16.6 In compliance to Rule 33 and 61 of Indian Electricity Rules, 1956 (as amended up
to date), all non-current carrying metal parts shall be earthed with two separate and
distinct earth continuity conductors to an efficient earth electrode.
2.3.2.16.7 The switch yard earthing shall consist of a mat buried in ground to cover the entire
substation yard area with spacing between conductors as per design based on IEEE
80. The contractor shall ensure adequate Earthing system protection to provide an
acceptable degree of protection as per IS / IEEE 80 for the switch yard. Individual
earth pits shall be used for transformer neutral earthing and earthing of lightning
arrestors. All the earth pits shall also be connected to the earth mat. If necessary
more numbers of Earth pit & conductors may be provided. Theoretical earthing
design calculations with necessary drawings shall be submitted for approval by
NLCIL.
2.3.2.16.8 Earth resistance of the earth pits shall be tested in the presence of the representative
of NLCIL.
2.3.2.16.9 The earth mat shall be designed considering the earth fault current and soil
resistivity value at site. For the purpose of estimating requirement of earth
conductor, the earth fault current on 33 KV side shall be taken as 31.5 kA for 1
second. The soil resistivity values shall be measured by the contractor at site during
detailing and the system shall be designed accordingly.
2.3.2.16.10 The earth mat shall consist of GI flats of adequate size for the fault current
magnitude. The conductor sizing shall also consider adequate allowance for
corrosion for a period of 25 years. To estimate the touch and step potentials, shock
duration of 0.5 seconds shall be considered. The risers and equipment connections
shall be using a minimum conductor size of 50x6& 75x12 mm galvanized steel
strip.
2.3.2.16.11 Each equipment in switch yard shall have a minimum of two earth connections
to the earth mat. The earth mat shall be buried at a depth of 600 mm from the
finished ground level. All structures in the switchyard shall also be bonded to the
earth mat. The installation of the earth mat shall be coordinated with the equipment
foundations and cable trench construction so as to avoid interference. All cable
54
2.3.2.16.13 The detailed requirement for earthing scheme is mentioned under the section
‘Earthing and Lightning protection of Power evacuation scheme’.
2.3.2.17.1 The structural work shall include design, fabrication and supply of all switchyard
structures, galvanized steel structural work for equipment supports, towers and
lightning masts. All structural steel shall be of mild steel confirming to IS 2062.
2.3.2.17.2 Minimum thickness of members other than bracings shall be 5 mm and that for
bracings shall be 4 mm.
2.3.2.17.4 All fastening bolts and nuts shall conform to IS 1363/ IS 1367, all washers shall
conform to IS 2016/ IS 6610 and spring washers shall conform to IS 3063.
2.3.2.17.5 Minimum size of bolts for all bolted connections shall be 16 mm dia and minimum
two bolts shall be provided for each member connection in important structures like
towers and gantries. The center to center distance between bolts shall be a minimum
of 2.5 times the nominal diameter of the bolt.
2.3.2.17.7 All embedded members shall be installed during concreting in accordance with
construction drawings.
2.3.2.17.8 The steel structure shall not be erected on the foundations until at least 7 days after
placing of the concrete in the foundations. All base plates shall be set level, in exact
position and shall be given full and even bearing grouted into place. All anchor
bolts and base plates shall be set accurately to the grade and alignment designated
on drawing or as directed.
2.3.2.17.9 All galvanized steel shall be handled with care to avoid bending or damage to the
galvanizing. Pieces bent in handling may be used only after they are straightened to
the satisfaction of the engineer. Material on which galvanizing has been damaged
shall be repaired as specified.
55
2.3.2.17.11 The structures may be erected by assembling in sections on the ground and
hoisting successive sections into place, or they may be built up in place by
individual members at the option of the contractor. If erected by assembling in
sections, not less than 50 percent of all bolting in place shall be done on each
section before starting another section.
All bolts shall be drawn up tight but not to such a degree as to endanger the strength
of the bolt. Wrenches approved by the engineer shall only be used on the work and
the use of any wrench, which may deform the nut or cut or flake galvanizing shall
not be permitted.
2.3.2.17.12 Reasonable amount of drift shall be allowed in assembling but reaming for
correction of mismatched holes shall not be permitted.
2.3.2.17.13 During structural erection inspection shall be carried out at every stage to
identify all loose bolts or other errors in erection are rectified in time.
2.3.2.17.14 All exposed structural steel shall be hot dip galvanized as per IS 4759. The
thickness of zinc coating shall not be less than 610 g/m².
2.3.2.17.15 All bolts, nuts and washers shall be hot dip galvanized as per IS 1367.
2.3.2.17.17 All foundation bolts shall be galvanized as per IS 5624 up to a depth of 300 mm
(minimum) below top of pedestal.
56
2.3.2.18.2.2 All insulators shall be suitable for heavily polluted atmosphere and shall be able
to withstand the duty requirements of the associated equipment.
2.3.2.18.2.3 When operating under normal rated voltage, there shall be no electric discharge
between the conductors and bushing which would cause corrosion or
injury to conductors, insulators or supports by the formation of substances
produced by chemical action.
2.3.2.18.2.5 All iron parts shall be hot dip galvanised and all joints shall be airtight. All
current carrying contact surfaces shall be silver plated.
2.3.2.18.2.6 The strain insulators shall be of ball and socket type. The socket shall be
malleable cast iron and the pin shall be of steel. After machining is completed,
the ball and sockets shall be hot dip galavanised.
2.3.2.18.2.7 Individual units of each strings shall be identical and interchangeable and shall
be suitable for forming either suspension or strain strings and shall be so
designed as to prevent formation of any defect due to expansion or contraction
in porcelain or metal fittings.
2.3.2.18.3 TESTING
All routine tests and acceptance tests shall be carried out as per the latest
applicable standards.
Type Tests : If type test report of equipment of same design is not available the
test shall also be carried out on equipment as per relevant standards.
57
Clamp shall be designed to carry the same current as the conductor as specified
in Data Sheet-A and the temperature rise shall be equal or less than that of the
conductor at the specified ambient temperature. The rated current for which the
clamp/conductor is designed with respect to the specified reference ambient
temperature, shall also be indelibly marked on each component of the
clamp/connector, except on the hardware.
Connector design shall permit easy checking to ensure that the connector is
installed correctly.
For parallel connector, power tied wedge pressure connectors (latest state of the
art technology) shall be used instead of conventional parallel groove clamp.
Bolts shall have M10 or M12 thread. Tightening torque shall be 45 Nm and 80
Nm for M10 and M12 respectively.
58
Contact paste shall be easy to apply to the contact surfaces within temperature
range – 300o to +50oC, shall have good adherence and be chemically in relation
to both aluminium and copper conductors and other materials included in the
connector.
Contact paste shall not be poisonous or inflammable. Contact paste shall not
decay, evaporate, run away, harden or crack under the service conditions
described in the specification.
The clamps shall be light in weight and easy to handle. Suspension clamp shall
have ease of oscillation around horizontal axis and moment of inertia enabling it
to follow freely the movement of the conductor. The clamps shall have low
effective power loss.
Strain clamps for GI shield wires shall be made from hot dip galvanised
malleable cast iron, free from blow holes, cracks, etc.
2.3.2.19.6 Spacers
59
Spacer design shall take care of ease of fixing and removing during installation
and maintenance. Spacer shall have ultimate compression strength.
2.3.2.19.8 DESIGN
Bolted type of connector shall be designed to withstand normal assembly
stresses without suffering permanent deformation.
Connectors shall be designed to withstand stresses in service due to wind, ice,
vibrations, fluctuations in temperature and short-circuits, without suffering
permanent deformation or breakages. In addition, connectors for bundled
stranded conductors shall withstand short-circuit inertia forces.
Connector design shall be such that tensile bending and wrenching stresses
transmitted to the equipment terminals are minimum possible. Connectors shall
permit axial movement of the tubular conductor.
Parts of current carrying connectors which are in direct contact with the
conductor shall be designed so that dangerous galvanic corrosion in the contact
surface does not occur.
Flexible connectors shall be designed so that electric current during both normal
load and short circuiting is not transferred through mechanical support.
Current carrying connectors shall be designed so that hysteresis and eddy
current losses are small.
The shape of current carrying connectors shall be such that water collection is
eliminated. If this is not possible, the connector shall be supplied with drainage
holes of at least 6 mm.
60
The bus post clamps shall be so dimensioned that clashing between the copper
tube and clamp does not occur during short circuit.
The bus post clamps shall be so dimensioned that it is not notably heated by
hysteresis and eddy current losses.
The bus support clamp shall with respect to partial discharge be designed with a
reliable electric contact between the copper tube, all parts in the clamp and
insulator fixing.
Bus support clamp intended for flexible current carrying conductors shall for
each copper tube allow a total axial movement of at least 60 mm.
The surface of conductor shall be clean and dry and free from any excess grease
that may be used in its fabrication. The surface strands shall be smooth and free
from burrs and other projections which may be cause for increasing corona
losses when the conductor is used on extra high voltage lines.
The steel wire strands of ACSR conductor and steel conductor shall be hot dip
galvanised. Zinc coating shall be evenly and uniformly coated complying with
relevant standards
The steel core and the inner layer of aluminium wires, (where more than one
aluminium layer exists), shall be protected with a special grease in order to
provide additional protection against corrosion due to saline pollution. The
61
2.3.2.20.2 Material
Tube material shall be aluminium and shall comply with properties as specified
in Data Sheet A.
2.3.2.20.3 Constructional Features
For the inside diameter of the tube there shall be no plus tolerance and for the
outside diameter and thickness there shall be no minus tolerance.
Corona bells shall be provided wherever the bus extends beyond the clamps on
free ends for sealing the ends of the tubular conductor against rain and moisture
and to reduce the electrostatic discharge loss at the end points. There shall be a
small drain hole at the end of each tube.
2.3.2.20.5 TESTS
All routine tests shall be carried out as per the latest applicable standards.
If Type tests reports of the components of same material are not available the
test shall be carried out as per relevant standards.
62
2.3.2.21.4 Modbus protocol Communication ports shall be provided for remote connection
for control and indication. Relay and Control Panel shall interface with plant
SCADA and Energy Management system through RTU
2.3.2.21.5 The relays shall have indicators, such as LED indications, that show clearly and
unambiguously that the relay had operated for various functions. A
minimum of 3 indicators shall be provided for protection functions. The
indications shall be maintained until reset by the operator. Facilities to test
the indicators shall be available to indicate a healthy auxiliary power
supply. Suitable labeling shall be provided for each indicator.
2.3.2.21.6 The relay auxiliary supply shall be supplied from 110V DC system. The
functionality of the relay shall not be affected by the variation of DC
supply. The power supply module shall tolerate a variation of plus/ minus
30 % of the station DC supply and shall also withstand higher DC voltage
during rapid charging of station batteries. The power supply card or
module shall also be able to remain stable when transient dips in the DC
voltage occur.
2.3.2.21.6.1 The numerical relay shall be able to retain in a non-volatile memory all its latest
logics, algorithm, settings, registered values, events, oscillography and
operation indications in the event of DC power failure. The relay shall
also be able to continuously keep track of its internal clock (time and
date) in the event of DC power failure.
2.3.2.21.6.2 On-line changing of relay shall not affect the operational value until confirmed.
The relay shall have a minimum of two protection function group
settings and be able to be interchanged between the group settings. Any
changes of relay settings shall be authentically verified. To maintain the
level of security for relay operational setting, configurations, access to
these functions shall only be permitted through a system of passwords.
2.3.2.21.6.3 The relay shall be provided with necessary interrogation and fault analysis
software. The software shall be considered part of the relay and deemed
to be provided as part of the contract. Any hardware and accessories that
63
2.3.2.21.7.2 Trip & Auxiliary relays shall be housed in dust and moisture proof cases and
shall be arranged so that adjustments, testing and replacement can be
effected with the minimum of time and labour.
2.3.2.21.7.3 Trip & Auxiliary relays shall be provided with LCD/ LED or flag indicators,
phase labeled/coloured, where applicable. Where two or more phase
elements or functions are included in one case, separate indicators shall
be provided for each element or functions.
2.3.2.21.7.5 Relay contacts shall be suitably rated for tripping, control and indication
purposes. The contacts shall be suitable for making and breaking the
maximum currents, which they may be required to control in normal
service. Separate and sufficient number of contacts shall be provided for
tripping, control and alarm functions. Separate contacts shall be
provided for alarm tripping functions. Relay contacts shall make firmly
without bounce and the whole of the relay mechanisms shall be as far as
possible unaffected by vibration or external magnetic fields.
2.3.2.21.8 Instruments and Meters
64
2.3.2.22 Station DC control power system be installed in line with specification clause
2.3.1.10. Required capacity UPS shall be installed and UPS sizing and design
calculation shall be submitted for NLCIL approval. Auxiliary AC power
distribution system, Lighting power distribution system shall be installed to
meet the system requirements and drawings shall be submitted for NLCIL
approval.
65
2.3.3.2 All SMUs get connected to respective inverters of Power Conversion Unit
located in PCSS through Inverter Monitoring Unit (IMU) as second level sub
system. The third level sub system shall comprise of PCSS Control and
Monitoring units connected to Central Processer for interface with Supervisory
Control And Data Acquisition (SCADA) system and EMS. Other sub systems
integrated into the main control automation scheme are Switchyard RTUs,
Weather Monitoring Unit, RTUs of BESS, PCS, BMS etc. All three levels of
subsystems shall be connected through OFC either UG or OPGW in a redundant
ring network.
2.3.3.3.1 The String Monitoring Units shall be installed in each Combiner Box, Array JB
and DC Bus Panel and shall be connected to respective PCSS through the
Optical Fibre Cable (OFC) in a redundant ring network in order to have better
reliability with lesser field control cables.
2.3.3.3.2 The SMU shall be of Industrial Grade, reliable and field proven microprocessor
based unit having the following minimum specifications:
2. The system shall be designed to have a field bus connection from the PV
Junction box / combiner box and the measurements are made at the
initiation point and transmitted to the PCSS sub system as a digitalized
data signal. For Zoning of faults, measurements are also taken at higher
level Array JBs and DC Bus Panel and transmitted to PCSS sub system.
3. The SMU shall have multiple channels to interface the various strings of
the PCSS through a field bus type of connectivity conforming to IEC
60870 bus standards and protocols and remote I/Os shall be used to
achieve the same.
66
2.3.3.3.3 The SMU shall be capable of monitoring the parameters like Voltage, Current,
and power as well as rate of rise /drop of parameters for each string and each
array along with diagnostic digital status signals from each combiner box to
provide adequate information with respect to the performance fluctuation and
efficiency of the PV arrays connected to it. It shall be possible to monitor and
identify the non-performing or underperforming PV panel strings from the
PCSS sub system so that the same can be attended or isolated easily.
2.3.3.3.4 The SMU unit shall be of RTU type to acquire data on continuous basis and
store the data in the SCADA. The SMU shall have logical capabilities to
perform any interlocking and protection logics as per the process requirement.
The SMU shall have other standard features like RTC, self-diagnostic routines,
event logging, alarms, fluctuation feedback etc. For electrical parameters like
voltage, current, etc., direct I/O modules without the usage of transducers shall
be preferred.
2.3.3.3.5 The components and interconnections of SMU shall be suitable for higher
service temperature within Array Junction box and Combiner box prevailing in
the project site.
2.3.3.4.1 Inverter Monitoring Units shall be installed in each PCCS for each Power
Control Unit (PCU) or Inverters. This inverter-monitoring unit shall be
industrial grade microprocessor based unit with direct digital interface to the
PCUs. The IMU can be built in to PCU / inverter itself or it can be a separate
unit for each PCU / inverter or common for both PCUs / inverters.
2.3.3.4.2 The IMU shall collect all the operating conditions of the inverter including
fluctuation parameters in AC side from the PCU / inverters and transfer the data
to the PCSS Control and Monitoring Units through the bus connectivity as
shown in the configuration diagram.
2.3.3.4.3 These monitoring units shall be connected through a redundant bus network to
the control and monitoring unit (PCSS-CMU) as part of the PCSS Sub – system.
Provision shall be made in PCSS to attach a portable HMI such as Lap Top
when required.
2.3.3.4.4 The IMU shall be capable of accessing real time downstream and upstream
performance values, analyzing dynamic PR, automatic changing of control
parameters based on trending and comprehensive monitoring the status of all
equipment connected to it along with its parameters. Commands from SCADA
and EMS shall be issued through IMU to inverters for controlling and
smoothing of the AC side output.
2.3.3.4.5 The IMU unit shall be of RTU type to acquire data on continuous basis and
store the data in the SCADA. The IMU shall have logical capabilities to perform
67
2.3.3.5.1 The HT / 415 V SS RTU shall be industrial grade microprocessor based unit
with direct digital interface to the bus. This RTU is connected to different
substation systems such as HT Three winding Transformer, Tap Changer, HT
and 415 V Switchgears, voltage / current / Temperature measurement devices,
Position Sensors, Control and Automation Relays, 110 V DC system battery
status and charger functions, PCU Ventilation fan operating status, etc.
2.3.3.5.2 The HT / 415 V SS RTU shall be capable of controlling the operations of circuit
breaker with intelligent interlocks and safety configurations from remote server
such as SCADA and EMS. All relay functions shall be programmable through
SCADA and EMS. Status abnormality of all equipment in Power Collection Sub
Station shall be monitored by the HT / 415 V SS RTU for providing necessary
alarm / alerts.
2.3.3.5.3 RTU shall be with built – in memory and extended removable type flash
memory cards to acquire data on continuous basis and store the data in the
memory modules .The RTU shall have logical capabilities to perform any
interlocking and protection logics as per the process requirement . The RTU
shall have other standard features like RTC, self-diagnostic routines, event
logging, alarms etc.
2.3.3.6.1 The PCSS CMU shall be an industrial grade microprocessor based unit which
shall act as bridge between each PCSS data network and main Optic Fibre Ring
Network. It shall be capable of handling all data and control functions of PCUs
as well as Substation RTUs. The constructional features of PCSS CMU shall be
similar to SS RTUs.
2.3.3.6.2 The other systems which shall be hooked up to the main OFR network at PCSS
are, phone communication, Fire alarm repeater panel and Station Facility
Controller. The Station Facility Controller shall handle all substation facilities
such as yard and building lighting, UPS / 110V DC system battery, battery
charger and access control.
2.3.3.7.1 An optic fibre cable network in ring architecture is envisaged to connect the
entire plant for data transfers in a most economical manner. Single mode 6 or 12
core corrugated steel tape armoured Optical Fibre cable conforming to IEC
60794 shall be routed as buried at a depth of 600 mm below ground connecting
the entire plant.
68
2.3.3.7.3 Where ever required the optical fibre link between site and SCADA/EMS shall
be connected through Optical Fibre Ground Wire (OFGW) installed on
Transmission line towers to avoid crossing of public roads and private areas.
2.3.3.8.1 Central Processor unit connected to Optical Fibre ring network collects data and
interact with SCADA and EMS through sub net. The Central Processing unit
shall be a rugged industrial type microprocessor based unit with built in
redundancy.
2.3.3.8.2 The sub net in control room shall be a redundant data highway bus connecting
SCADA and EMS servers and weather monitor unit, HT RTU etc.
2.3.3.9.1 The WMU shall be an industrial microprocessor based unit capable of collecting
weather data from field instruments listed in Clause 2.3.3.13 below. Functions
of WMU are elaborated in Clause 2.3.13.15. Pyranometer data from WMS shall
be taken by SCADA and EMS for control operations of BESS charging and
discharging.
2.3.3.11.1 The computer aided SCADA and EMS shall be designed for simultaneous
monitoring and recording of various parameters of different sub-systems in the
solar power plant integrated with Battery Energy Storage System, power
generation on the DC and AC sides, capable of computing performance ratios
and efficiency of different sub system operations and implement corrective
action for achieving smoothend power output to grid and achieving maximum
plant output. SCADA and EMS shall be suitably connected with necessary
hardwares and softwares and proper linkages.
2.3.3.11.2 The SCADA and EMS shall be designed on reliable operating platform and time
tested software featuring, Energy Management, String level control if required
and inverter control, Battery management system control, DC & AC switch
gears, lighting automation system, security, alerts, analytical reporting, auditing
and data archiving functions etc.
2.3.3.11.3 SCADA and EMS shall be capable of providing different on screen dashboards
for overall / zone of the plant, combiner box monitoring, weather station
parameters, DC / AC SLD, Trend Charts, Alarm / Alert listing, Audit Reports,
69
2.3.3.11.4 Minimum of three operating stations with servers is envisaged for the SCADA
and EMS. Personal computer (PC) with monitor and key board shall serve as
servers. One server shall be Operating Station with data storage, second server
shall serve as back up data storage as well as Operating Station cum
Engineering Station and the third server shall be web connected to act as Web
Station with web data storage. The Data Acquisition System should be housed
in a desk made of sheet steel, powder coated.
2.3.3.11.5 The SCADA and EMS configuration, equipment details, software features, on
screen dashboards and other operational highlights shall be submitted for
NLCIL approval. Necessary design documents and drawings of SCADA and
EMS including Plant Monitoring Desk shall be submitted for approval by
NLCIL before commencement of supply.
2.3.3.11.6 Each PC shall be rugged & robust in nature to operate in a hostile environment.
The PC shall have minimum Intel Core i5 processor having 2 X 500 GB HDD
with minimum 4 GB RAM. The PC shall also have 21” or higher TFT Colour
monitor, DVD Drive with Writer, USB ports, Scroll Mouse and UPS for four
(4) hours power back up.
2.3.3.11.7 The printer shall be A4 and A3 colour laser type rugged & robust in nature and
of reputed make. The printer shall be equipped for printing, scanning, copying
and faxing and shall be hooked up to network.
2.3.3.11.8 The Data Acquisition System shall perform all measurements and continuous
recording of all data required for system operation.
2.3.3.11.9 SCADA and EMS shall provide fifteen (15) Minutes daily, monthly and annual
average of all parameters.
2.3.3.11.10 All data shall be recorded chronologically date wise. The data file should be MS
Excel compatible. The data logger shall have internal reliable battery backup
and data storage capacity to record all sorts of data simultaneously round the
clock. All data shall be stored in a common work sheet chronologically.
Representation of monitored data shall be available in graphic mode or in
tabulation form. All instantaneous data can be shown in the Computer Screen.
2.3.3.11.11 SCADA and EMS shall have feature to be integrated with the local system as
well remotely via the web using either a standard modem or a GSM/WIFI
modem. The bidder shall provide compatible software and hardware so that data
can be transmitted via. standard modem. Plant generation data shall be made
available for NLCIL web site for display in NLCIL intranet.
2.3.3.11.12 The SCADA and EMS shall enable automatic operation of entire solar PV
power plant in all modes, during power generation as well as in non-power
generation periods. Final out going breaker will be controlled by SCADA and
70
2.3.3.11.13 The Solar PV Power Plant integrated with Battery Energy Storage System will
be requiring interface with the A & N Electricity Department for power export.
It is the responsibility of contractor to make provisions in SCADA and EMS to
have required networking with A & N Electricity Department. The Contractor
shall provide necessary hardware to meet these requirements and their
standards.
2.3.3.12.2 Suitable capacity electronic IP PBX shall be provided at Project Control Room
with cable network for IP phones inside the project site building.
2.3.3.12.3 Proposed Voice Communication System Scheme, exchange and phone data
sheet, number and location of hand sets, etc., shall be submitted for approval by
NLCIL.
2.3.3.13 FURNITURE
71
2.3.3.14.1 Contractor shall provide all measuring instruments listed below for each site
location and with all necessary software & hardware to make it compatible with
SCADA and EMS.
1. Pyranometer -2 nos.
72
Input Power for Instrument & Peripherals : 230 VAC (If required)
2.3.3.14.3 If any higher version is required to meet system requirements with the approval
of NLCIL the same shall be installed without any extra cost to NLCIL. Each
instrument shall be supplied with necessary cables. Calibration certificate with
calibration traceability to World Radiation Reference (WRR) or World
Radiation Centre (WRC) shall be furnished along with the supply of the
instrument.
2.3.3.14.4 The signal cable length shall not exceed 20m. Contractor shall provide
Instrument manual in hard and soft form.
2.3.3.14.5 Bidder shall install two RTD type ambient temperature measuring instruments
at suitable places in PV array. Instruments shall have a range of - 4 0 C to 70oC.
SECTION 2.4
2.4.1.2 This specifications document is not exhaustive and the contractor shall be
responsible not only for the requirements specified herein but for the correct choice
73
2.4.1.3 In General, all civil works shall be carried out as per relevant latest BIS, unless
otherwise specified.
After attending NLCIL’s comments if any in the draft report, Six (6) sets of hard
copy and one (1) set of soft copy (in DVD/CD in editable AutoCAD format) of the
Final Survey report with all relevant drawings shall be submitted to NLCIL for
approval. The FGL should be got approved by NLCIL before commencement of
work at site.
Levelling and terracing works for the entire power plant area shall have to be done at
different levels & slopes based on the natural terrain and requirements. Hence
cutting, filling, levelling and other allied works are in the scope of the contractor.
The finished ground levels of array yard, sub stations, control room etc., shall be
74
2.4.2.3.2 The scope of sub-soil investigation includes, execution of complete soil exploration
including boring according to the site requirement, drilling, collection of undisturbed
soil sample where ever possible, otherwise disturbed soil samples, SPT, Electrical
Resistivity test, etc., conducting laboratory test of samples to find out the various
parameters mainly related to load bearing capacity and settlement, ground water
table level, sub soil conditions such as chemical characteristics of soil. The soil test
also includes analysis of ground water sample.
2.4.2.3.3 On completion of field and lab test, the contractor has to submit soft copy of Draft
Soil investigation report to NLCIL for review. The draft report shall contain data for
each borehole, layout drawing showing all test locations (with UTM coordinates),
along with recommendation regarding suitable type of foundation for all the
structures as well as recommendation for soil improvement, wherever necessary. The
report shall include Safe bearing capacity of soil for different types of foundations
(Shallow/Pile) based on soil parameters and settlement characteristics defining
clearly, how these capacities were arrived at, based on the relevant latest BIS
standards.
2.4.2.3.4 After attending NLCIL’s comments if any in this regard, the contractor shall submit
one (1) soft copy (in the form of DVD/CD) and six (6) hard copies of Final Soil
Investigation Report to NLCIL and get them approved, before commencement of
foundation designs.
75
2.4.3.1 Foundation for Modules Mounting Structures (MMS) can be shallow foundation or
driven cast-in-situ Pile/Under reamed pile depending on the soil conditions. While
designing the foundations, due consideration shall be given for the self weight of
module assembly and maximum wind speed as per latest IS 875-Part-3. The size of
the foundation shall be based on design parameters & to prevent liftoff of structure
due to wind forces. Minimum pile diameter shall be 300mm. The Grade of concrete
for foundation shall be M30. Top of concrete/height of collar for MMS foundation
shall be minimum 150mm above FGL. In case of pile foundation, necessary
INITIAL TEST (Pullout & Lateral load) for piles – minimum 2 tests at each site
shall be done as per latest IS2911(Part-4) and accordingly the depth of pile shall be
firmed up. Foundation work of Module Mounting Structure shall commence only,
after the proper leveling / grading of the site
2.4.3.2 Seismic parameters Zone & Importance Factor for the project sites shall be based on
latest BIS: 1893(Part-1).
2.4.3.3 Members shall be fabricated by cold forming process and shall have minimum yield
strength of 345 MPa and shall conform to the physical specifications of ASTM A653
or latest IS 811 or any other relevant international standards. Light gauge structural
steel or structural aluminium members can also be proposed subject to approval of
NLCIL. Mild steel members with weather protection coating as per ASTM A792M
or IS:15961 (latest revision) standard Al-Zn alloy hot dip process with minimum 150
GSM on both sides are acceptable for purlins (structural member connected to
modules) with minimum 0.9 mm base metal thickness and yield strength not less
than 550 MPa. Inside coating of purlins should be ensured.
1. Fabrication and erection shall be carried out in accordance with latest IS 800 and
IS 801.
2. Dimensions of plates, flat bars shall conform to latest IS 1730. The minimum
thickness of 2.5mm for MMS column post and minimum 2mm for other members
shall be ensured.
3. Bolts, nuts, screws, washers etc… shall be of stainless steel SS 304 of class A2-70
and sizes as per latest relevant BIS provisions. All fasteners shall be provided
according to connection design requirement. All bolts shall be tightened with
designed torque mechanically.
4. All structural members shall be hot dip galvanized as per IS 4759 or relevant
Indian standards and the average coating thickness shall be 80 micron and local
coating thickness shall be minimum 70 micron. In case of aluminium, anodized
coating as per IS 1868 (AC25) shall be provided.
5. Structural design of MMS structure shall be as per provisions of latest IS 801.
76
2.4.3.5 The contractor shall prepare array layout to suit their design and plan the total power
plant within the available land area without involving any major site modifications.
2.4.3.6 The structure shall be designed for simple mechanical and electrical installation. It
shall support Solar PV modules absorb and transfer the mechanical loads to the
ground properly. There shall be no requirement of welding or complex machinery at
site for installation of module mounting structure to the foundation.
2.4.3.7 The structure shall be designed to allow for easy replacement of any module as well
as easy access to the bottom of module by O&M staff.
2.4.3.8 General arrangement of Module mounting structures, array layout, and fabrication
drawing shall be submitted to NLCIL along with necessary supporting design
documents for approval, before commencement of fabrication/erection.
77
2.4.3.10 All building and other foundation drawings & designs shall be based on Final Soil
Investigation Report and to be submitted to NLCIL for approval, before starting the
work.
2.4.4.1 The roads shall be designed and constructed based on the General layout of the Solar
Power Plant. The main approach road from the existing nearest road to the Solar
Plant shall be a single lane road, designed to carry the equipments as per relevant
specification of IRC along with connecting RCC culverts (M25) wherever required.
The approach road, peripheral road & all internal roads are to be designed to suit the
Solar Plant layout and shall be of single lane of 3.6 M width. These roads shall be
laid with
a) WBM – using 40 mm BG metal - two layers – each of 135 mm pre-
consolidated thick – rolled to 100 mm thick - consolidated thickness totaling to
200 mm which includes dry and wet rolling of each layers, spreading gravel
for blindage and consolidation with water, spreading sand/M.sand/quarry dust
to a thickness of 3 mm and top rolling and
b) Top coat – Top finishing coat shall be of Bituminous Toping using 12 mm
downgraded metal with consolidated thickness of 20mm and seal coat.
2.4.4.2 All roads shall be provided with 0.60 M wide berm on both sides with 150mm thick
well compacted BG boulders/ locally available natural rock boulders and trapezoidal
earthen drains as per the approved drainage layout. The area between the solar arrays
shall be leveled for carrying panels and materials, modules washing, easy movement
during O & M, etc. The layout and details drawing of all roads and culverts (if any)
shall be submitted to NLCIL and got approved, before commencement of work.
2.4.5.2 Aesthetically designed sign board 2.4 M x 1.5 M shall be provided at the entrance of
approach road to Solar Power Plant at each plant site. The sign board shall contain
78
79
2.4.8.3 The Contractor shall submit to NLCIL the schematics of the wash water system with
location of pump, pipe work and tap off points as well as drains, module washing
accessories, etc., for review and approval.
2.4.8.4 The Contractor shall carry out chemical analysis of water independently to ascertain
the quality of supplied water and to size any equipment or system required for
treatment of raw water for successful operation of Plant for 11 years. Based on
chemical analysis of water, if any equipment/system is required for treatment of raw
water before it is used for module cleaning and the same shall be submitted to
NLCIL for approval.
2.4.9.2 The scope of civil works for the PSS includes design, supply of materials and
construction of all equipment / tower / mast foundations, cable trenches, earth
80
2.4.9.3 All pedestals for towers/equipment will extend to a minimum of 300mm above
FGL.
2.4.9.4 Supplying and spreading with crushed BG metal comprising of average 40mm
(30mm to 50mm) normal size over the entire Switchyard area to 100 mm.
thickness (min.).
2.4.9.5 The safe touch & step voltage will be achieved considering crushed stone/gravel
resistivity for Substation. Beside this if any extension of earth mat outside Sub-
Station area is required to achieve safe earth mat design; the same will be within
the scope of the Contractor.
2.4.9.6 Contractor will submit the design of switchyard foundation and structures with
details of load combinations, factor of safety, sag tension basis, etc. to NLCIL for
review and approval.
2.4.9.7 The scope of civil works detailed above for the switchyard is only indicative.
Any other civil & structural steel work which is not mentioned or not included
here but necessary for the establishment and operation of 33KV Switchyard for
Power evacuation purpose will be included in the scope and borne by the
Contractor.
81
2.4.10.2 DESIGN:
The Power Export Sub Station building shall be designed as RCC framed structure
with external staircase as per NBC. A portico with RCC slab for a minimum
dimension of 4.5mx3.6m shall also have to be provided at the main entrance. All
passages/corridors shall be provided with a minimum width of 2.0 m.
Steel Reinforcement:
All reinforcement steel used shall confirm IS 1786 and shall grade Fe 415/ Fe500.
The corrosion resistant steel bars alone shall be used in the concrete. The corrosion
resistant steel bars manufactured by SAIL/RINL/TISCO, JINDAL/VSPSAIL /SRMB/
SHYAM/ UDYOG/ TATASTEEL/ PULKIT/ TULSYAN/SURYADEV shall be used.
2.4.10.5 PLASTERING:
All internal and external surfaces of wall shall have 15 mm thick plastering in CM
1:4. Ceiling plastering shall be 12mm thick in CM 1:3
2.4.10.6 FLOORING:
Flooring for stores and HT Switchgear room shall be of cement concrete flooring as
per IS 2571. Flooring for office, pantry and SCADA room shall be approved quality
vitrified ceramic tile of approved colour and shade, minimum size 600 x600 mm
over PCC. Acid resistant tile flooring of 10mm thick confirming to IS4457 shall be
provided for Battery room. For pantry room platform, Polished Granite slab of
thickness 12 to 16mm shall be used.
82
2.4.10.8 DOORS & WINDOWS - Doors, windows and ventilators shall be provided with
electro colour dyed (15 micron thickness) aluminium framework with glazing.
Minimum size of door shall be 1.2 m x 2.1 m. However for toilets minimum width
shall be 0.75 m. All doors of toilet areas shall be FRP frame and FRP shutter. All
windows and ventilators of all buildings shall be provided with suitable MS Grill.
Doors and windows on external walls of the buildings shall be provided with RCC
sunshade over the openings with 300 mm Projection on either side of the openings.
Projection of sunshade from the wall shall be minimum 600 mm over window
openings, 750 mm over door openings & 1000 mm for rolling shutters (other than at
main entrance). The Rolling Shutter shall confirm to IS6248 and the size based on
functional requirement.
GLAZING: All windows and ventilators shall be provided with 4mm thick tinted
glass. For aluminum doors, tinted glass of 6 mm thickness shall be used. All glazing
work shall conform to relevant BIS.
2.4.10.10 PAINTING:
The emulsion paint for both internal & external walls shall be anti-fungal quality of
reputed brand suitable for masonry surfaces for the corresponding rainfall zone of
Project site. The ceiling & walls of the Battery room shall be painted with epoxy
based paint. All painting on masonry or concrete surface shall preferably be applied
by roller. If applied by brush then same shall be finished off with roller. All paints
shall be of approved make and quality. Minimum 2 finishing coats of paint shall be
applied over a coat of primer. For painting on concrete, masonry and plastered
surface IS: 2395 shall be followed. For painting on steel work and ferrous metals,
relevant BIS shall be followed.
83
2.4.11.2 DESIGN:
The Power Collection Sub Station building shall be designed as single storey RCC
framed structure.
84
2.4.11.5 PLASTERING:
All internal and external surfaces of wall shall have 15 mm thick plastering in CM
1:4. Ceiling plastering shall be 12mm thick in CM 1:3
2.4.11.6 FLOORING:
Flooring, including preparation of surface, cleaning etc. shall be of cement concrete
flooring as per IS: 2571 with ironite hardener.
2.4.11.7 ROOFING - Roof of the Control Room Building shall be sloped Cast-in-situ RCC
slab (Grade M 30) treated with waterproofing system. Concrete/ red clay tiles of
approved quality, brand shall also have to be provide over the RCC slab.
2.4.11.9 DOORS & WINDOWS - Doors, windows and ventilators shall be provided with
electro colour dyed (15 micron thickness) aluminum framework with glazing.
Minimum size of door shall be 1.2 m x 2.1 m.
Doors, rolling shutter and windows on external walls of the buildings shall be
provided with RCC sunshade over the openings with 300 mm Projection on either
side of the openings. Projection of sunshade from the wall shall be minimum 600
mm over window openings, 750 mm over door openings & 1000 mm for rolling
shutters (other than at main entrance)..
85
2.4.10.10 PAINTING:
The emulsion paint for both internal & external walls shall be anti-fungal quality of
reputed brand suitable for masonry surfaces for the corresponding rainfall zone of
Project site. All painting on masonry or concrete surface shall preferably be applied
by roller. If applied by brush then same shall be finished off with roller. All paints
shall be of approved make and quality. Minimum 2 finishing coats of paint shall be
applied over a coat of primer. For painting on concrete, masonry and plastered
surface IS: 2395 shall be followed. For painting on steel work and ferrous metals,
relevant BIS shall be followed.
SECTION 2.5
BATTERY ENERGY STORAGE SYSTEM (BESS)
The provision for a Battery Energy Storage System (BESS) with the Solar PV
Project has been incorporated in the Scheme with the objective of improving the
quality of power injected into the grid by Solar PV plants that rely on an intermittent
energy resource like Solar radiation and thus, contribute to stable and secure
operation of transmission grid. Specifically, the proposed Energy Storage System is
intended to be used for PV Power Smoothing application. The utility of BESS for
ancillary services including features such as Active Power Regulation services
(primary control or Frequency response) etc., shall also be included which is only for
demonstrative purpose.
The BESS shall remain connected to the grid as per Central Electricity Authority
Technical (standards for connectivity to the grid) regulation 2007 with all latest
amendments and its components shall be designed accordingly. BMS shall ensure
safe operation and mitigate fire risk. The BESS shall be configured to perform
multiple charge discharge cycles.
86
The Prime application of BESS shall be smoothing of power output from the Solar
PV plant due to fluctuation in solar radiations. Peak smoothing shall be
demonstrated within the deployed battery capacity in MW, for above 75% of the
instances within the specified assessment window i.e., when a need for response is
detected. BESS should respond in a manner that the combined Solar PV and BESS
output at the Point of Common Coupling (PCC) targets the 15 minutes moving
average value of the Solar PV array output. BESS shall charge and discharge power
at appropriate ramp rate such that the smooth power output from the combined
BESS and Solar plant is injected into grid.
For the purpose of smoothing assessment, this BESS application shall be carried out
for during solar hours every day. The upper and lower SOC for BESS operation
shall be set as per the system requirements. The Battery manufacturer’s specification
and operating instructions shall be selected in such a way to suit the above
requirements. Temporal resolution of the data provided shall be minimum 1 second.
Criteria
Description Criteria
Code
M1 Measure/Count of Instances Count those records in the 10
when the BESS is expected to hour assessment period
respond for the smoothing (Minimum temporal
application resolution of one second),
where BESS is expected to
respond
87
The BESS shall have anti-islanding protection as per IEC 62116 or equivalent
international standard
2.5.5 The digital inputs from Inverters, SMUs, Power Conversion System (PCS) of BESS,
Outgoing feeders, grid parameters and using other required inputs, the EMS shall
ensure that none of the solar fluctuation and intermittency shall affect the grid
parameters. Based on the history of data of various grid parameters available in Port
Blair including existing 5 MWp Solar Power Project , the forecast shall be finalised
during detailed engineering to achieve the above functions in a coordinated way.
2.5.6 Components required to support reactive power shall also be taken into
consideration for design of EMS and BESS
2.5.7 The critical parameters such as Response time, Discharge duration, Depth of
discharge, Frequency of Discharge, Cycle life, round trip cycle efficiency,
performance degradation, self discharge characteristics, short time discharge ratings,
transient response characteristics, auxiliary systems requirements etc. shall be
finalized during detailed engineering to meet system requirements.
2.5.8 Simulation studies shall be done for various conditions of Solar Generation, Grid
condition and fault conditions during detailed engineering. Necessary documents
required for obtaining the grid parameters available with Electricity Department.
ANI shall be provided by NLCIL. However it is the contractor’s responsibility to
carry out simulation studies based on available grid parameters and appropriate
assumptions. The simulation results shall be the basis for the design of the system
and it shall be submitted for approval by NLCIL and Electricity Department, ANI.
88
2.510 Prior to the dispatch of BESS, a unit part of the system which shall represent the
final BESS system to be installed at site, shall be taken into Factory Acceptance Test
(FAT). It shall be arranged by the contractor in any test place of convenience in the
presence of NLCIL and Electricity Department, ANI authorities. This test is
envisaged with an aim to minimize malfunctions during installation at site. The tests
that cannot be built during FAT shall be simulated and tested as close as possible in
a manner corresponding to the final functioning.
2.5.11 Fire protection system (FPS) shall be designed for the BESS in line with NFPA or
international norms regulations and CBIP guidelines as applicable and system
requirements taking into consideration of the project site at island.
2.512 Power Conversion System (PCS) for BESS shall have efficient cooling and a more
compact housing concept. The housing concept must be a closed-concept with an
air-conditioning system or a ventilation system and shall be supplied either in a
separate compartment or integrated system. The BESS shall be able to supply power
at power factor of 0.95 lead-lag during normal operation and should be able to allow
grid power factor until 0.8 lead-lag. During the period of back down/surrender, grid
outage conditions, the BESS shall be capable of getting charged from Solar PV
Power plant on stand alone basis. .
2.5.13 The response of PCS shall be in such a way that it meets the requirements of Energy
Management System (EMS) which is in the scope of the contractor as well as
Energy Management Centre which is in the scope of Electricity Department, A & N
Administration. The Energy Management System (EMS) shall function as the main
command centre for the entire plant and receive inputs via SCADA, from Solar PV
strings, inverters, HT transformers, Feeders, Battery Management system, Power
conversion system, weather monitoring unit, grid parameters etc. the charging and
discharging commands shall be issued accordingly.
2.5.14 Test certificates and test reports as per IEC 62133, IEC 61959 and IEC 61960 or
other international equivalent standards applicable for the battery technology
selected shall be submitted by the contractor for NLCIL approval during detailed
engineering. All other test certificates and test reports as per international standards
and norms for large scale Battery Energy Storage System shall be submitted for
NLCIL approval during detail engineering.
2.5.15 BESS replacements, repairs, substitutions, maintaining spares and consumables etc.,
shall be programmed and carried out by the contractor so that the annual guaranteed
net energy export is achieved. The tie up arrangements including after sales service
support for the entire cycle life of the Battery shall be made by the contractor with
Battery supplier and the same shall be submitted to NLCIL.
2.516 Load banks devices with dummy loads of capacity suitable for a unit part of BESS
specially designed for battery discharge testing shall also be a part of BESS
maintenance and testing system at project site..
89
2.5.18 The BESS shall consists of components but not limited to the following:
2.5.19 The contractor shall submit detailed technical particulars, drawings and documents of
the above components for NLCIL approval.
The following shall be the minimum BESS parameters. Bidder shall submit all
technical parameters to assess all BESS functionalities.
90
91
2.6.2 The Contractor shall do clean up of all equipment and area within project site prior
to preparing the equipment for trial run and start-up. The start up and commissioning
of the entire system shall be executed by the Contractor in a planned coordinated
sequence.
2.6.3 Power and control cabling shall be done as per approved scheme and in sections,
taking adequate precautions against electrical shocks as the solar PV cells are
capable of producing power on exposure to light. Necessary covers shall be supplied
for covering the solar PV modules during cabling termination works. Safety
precautions and manufacturers recommendations shall be strictly followed for BESS
testing and commissioning activities.
2.6.4 Calibration and commissioning of all instruments and control equipment supplied
under this contract shall be executed by the contractor. Hardware required for
erection of all instruments and control equipment covered under this contract shall
be supplied by the contractor.
92
2.6.7 Follow up of all the required activities to obtain A&N Administration / Central
Electrical Inspectors approval for the installation and carrying out any changes called
for by the Inspector at no extra cost to NLCIL.
Performance Guarantee Test shall be carried out for the entire system for one year
after provisional take over. Guaranteed Net Energy Export in Kwhr from BESS and
Solar plant combined measured at 33KV switchyard metering station of the Grid
interconnection take off points shall be as per the following table:
93
94
2.6.11 Following factors shall be considered while computing the “Base Net Energy
Export”
i) Actual insolation level at the project site shall be considered
while computing the base net energy export. However, effect due
to variation of metrological parameters viz., ambient
temperature, wind speed, humidity etc., shall not be considered.
ii) During the period of grid outage, back down/surrender, the
measured global solar insolation (for the period of Grid outage)
shall be excluded to calculate average global solar radiation for
the PG period.
iii) During the O&M period due to Battery replacements /
substitutions if any shall fall occurs in Annual Net Energy Export
in that year/years then the short fall in Annual Net Energy Export
shall be limited to maximum three years
iv) Along with Battery replacements/substitutions to meet the Annual
Net Energy Export re-powering of Solar PV modules. If required
shall also be included in the scope of work without any extra cost
to NLCIL
2.6.12 The contractor shall furnish the following during detailed engineering in relation to
Annexure 1 for NLCIL approval.
a. The basis, reference standards and calculations used for arriving
at the guaranteed month-wise net energy export data.
b. PV System Design Report with simulation parameters / variants,
shading diagrams, production charts, loss diagrams, etc
correlating with the above year wise net energy export data.
c. Guaranteed month-wise net energy export into the grid as per
simulation carried out using PVSYST version 5.5 or higher
version /Sun simulator/equivalent software for correlating with
the guaranteed month-wise net energy export data.
95
SECTION 2.7
QUALITY ASSURANCE, INSPECTION AND TESTING
2.7.1 GENERAL
2.7.1.1 The documents related to Manufacturing Quality plan shall be submitted for NLCIL
approval.
96
ii. Bidder shall furnish in their bid, the proposed list of sub vendors for each of the
bought out items.
iii. The proposed list of sub vendors furnished by the successful bidder will be
finalized before start of detailed engineering.
97
98
99
SECTION 2.9
2.9.1 GENERAL
2.9.1.1 The Bidder shall carry out O&M activities for the entire System including its
associated civil structures, roads, Power export Switchyard and control room
buildings, Security of the plant Buildings, Garden etc. The O & M activities also
includes the entire power evacuation system comprising of UG Cables, transmission
lines of grid take off points of the existing 33kV feeders connection point, gantries
and allied equipments up to the terminal point of connectivity for a period of 11
years including one year warranty.
2.9.1.2 Operation work includes day-to-day operation of the entire system. The
responsibility of ensuring uninterrupted operation of the entire system lies with the
contractor or else it will attract penalty/loss of compensation as per relevant clauses
of the specification.
2.9.1.3 The contractor shall furnish proposed maintenance (preventive) schedule for the
operation and maintenance of the entire system for NLCIL approval. As the O&M
contract period is for 11 years including warranty period, the long term
maintenance/replacement schedule indicating the unit replacement of
parts/equipments, if any, shall also be furnished considering the life of such
parts/equipments. Equipment overhaul schedule indicating the loss of generation
during such periods, if any, and the proposed catch up plans for maintaining the
scheduled/committed generation shall also be furnished.
2.9.1.4 The maintenance staff for the Entire System shall be available at all times in the
plant premises.
2.9.1.5 The Contractor shall maintain attendance register for all their staff deployed for
carrying out jobs on regular basis and shall be produced for verification on demand
by authorized personnel of NLCIL.
2.9.1.6 The Contractor shall ensure that all safety measures are taken at the site to avoid the
accidents to his employees or his sub Contractor employees.
2.9.1.7 In order to ensure longevity, safety of the core equipment and optimum performance
of the system, the Contractor shall use only genuine spares of high quality standards.
100
2.9.2 SCOPE
2.9.2.1 The Contractor shall provide his operation and maintenance staff for the entire
system for day-to-day operation and maintenance. The operation and maintenance
personnel shall be qualified, certified by competent authorities and well trained so
that they can handle any type of operational hazards quickly and timely. The
responsibility of providing suitable Personal Protection Equipments rests solely with
the contractor.
2.9.2.2 The security of the entire plant area shall rest with the contractor, till final take over
by NLCIL after completion of the contract period.
2.9.2.3 The maintenance personnel shall be in a position to check and test all the equipments
regularly, so that, preventive maintenance, could be taken well in advance to save
any equipment from damage. Abnormal behaviour of any equipment shall be
brought to the notice of NLCIL not later than 2 hours for taking appropriate action.
2.9.2.4 All repairing & replacement works are to be completed by the Contractor within
reasonable time from the time of occurrence of fault or defect If it is not possible to
set right the equipment within reasonable time, the Contractor shall notify NLCIL
indicating nature of fault & cause of damage etc. within 12 hours from the time of
occurrence of the fault.
2.9.2.5 During operation and maintenance, if there is any loss or damage to any component
of the power plant and the BESS due to miss-management/ miss-handling or due to
any other reasons, what so ever, the Contractor shall be responsible for immediate
replacement / rectification of the same. The damaged component may be repaired, if
it is understood after examination that performance of the components shall not be
degraded after repairing, otherwise the defective components shall have to be
replaced by new one without any extra cost to NLCIL.
2.9.2.6.1 Regular operation and maintenance of the entire System and submission of daily
performance to NLCIL. The Contractor shall maintain log book in this respect to
clearly record the date of checking & comments for action taken etc.
2.9.2.6.2 The scope of operation and maintenance includes all equipments/accessories of the
entire system and proper records of operation of the entire System shall be kept as
per direction of NLCIL.
101
2.9.2.6.4 Normal and preventive maintenance of the entire system shall be carried out on
regular basis.
2.9.2.6.5 Keeping & recording daily log sheet as per approved format shall be maintained
after commissioning of the entire system.
2.9.2.6.6 Under no circumstances, the contractor shall run the system in such a way that will
damage the grid.
2.9.2.6.7 The contractor shall submit monthly Performance report of entire system indicating
net energy export data as per approved format within three days of the following
month. The reporting shall also include any mismatch or abnormality in the
performance of the system based on SCADA and EMC details for review. Day to
day coordination with A & N Administration Electricity department and submitting
reports, details required by them shall also under the scope of the O & M contract.
2.9.2.6.8 The Contractor shall preserve all recorded data in both hard copy and soft copy
format and shall submit to NLCIL every month.
2.9.2.6.9 The Contractor shall develop & maintain gardens, which shall be developed by the
Contractor himself as per landscaping including daily watering and manuring as and
when necessary and on regular basis.
2.9.2.6.10 During operation and maintenance period, the Contractor shall refill the fire
extinguishers as per manufacturer’s recommendation before expiry.
2.9.3.1 Tools and tackles is not a supply item. A list of tools and tackles which are required
for O & M of the entire system shall be maintained by the contractor for use during
the O & M period. The contractor shall maintain all regular/special O&M tools apart
from the tools and tackles.
2.9.3.2 Such special tools used by the contractor during operation and maintenance period
shall be handed over to NLCIL at the time of completion of 11 years O&M period
including warranty period.
2.9.4.1 The Contractor shall provide all details of onsite testing instruments / equipments.
Details of equipment / instrument, make, numbers, range, accuracy, etc shall be
furnished to NLCIL
102
2.9.5.2 Repairs, replacements, cleaning of all joineries etc as and when necessary shall be
carried out by the contractor.
2.9.5.4 Cleaning & maintaining of power plant area clearing all weeds, leaves and other
wood rejects. Vegetation removal inside the power plant and also vegetation removal
& cutting of trees/branches en route the transmission lines of the power evacuation
system up to Grid Connecting substation on periodical basis as directed by NLCIL.
2.9.5.6 Painting of the buildings, structures/PCSS, Security room, fencing posts, gates,
transmission towers, and extension bays etc once in two years.
2.9.5.7 All minor repair maintenance in case of buildings and all other structures as and
when required as per the instructions of Project Manager/NLCIL.
2.9.6 OTHERS
2.9.6.1 Any Electrical /Civil maintenance work which are not mentioned or included here
but necessary for the entire life of the project shall be carried out by the Contractor.
103
1 January 5.65
2 February 6.47
3 March 6.83
4 April 6.65
5 May 5.08
6 June 4.38
7 July 4.45
8 August 4.45
9 September 4.64
10 October 4.99
11 November 4.86
12 December 5.19
Annual -
104
1 January
2 February
3 March
4 April
5 May
6 June
7 July
8 August
9 September
10 October
11 November
12 December
Annual -
105
1 January
2 February
3 March
4 April
5 May
6 June
7 July
8 August
9 September
10 October
11 November
12 December
Annual -
106
107
No. (b) kWh / m2 / day (d) (e) = (b) x (c)/(a) report as + ve (or) -ve
1 Jan 5.65
2 Feb 6.47
3 Mar 6.83
4 April 6.65
5 May 5.08
6 Jun 4.38
7 Jul 4.45
8 Aug 4.45
9 Sep 4.64
10 Oct 4.99
11 Nov 4.86
12 Dec 5.19
Annual -
108
1. The measured Net Energy export shall be calculated by adding all the net export values of the billing meters installed in the 33 KV Power Export
switchyard outgoing feeders.
2. If sum (f) is negative (-), there is shortfall in annual guaranteed Net Energy export during solar hours for PG test period
I. Short fall in Net Energy export for PG test period (Annually) : ________kWh
II. LD for shortfall in net energy export for PG test period : Rs. Per kWh
III. Total Penalty payable : Rs. ______ Item (i) x Item (ii)
109
No. (b) kWh / m2 / day (d) (e) = (b) x (c)/(a) report as + ve (or) -ve
1 Jan
2 Feb
3 Mar
4 April
5 May
6 Jun
7 Jul
8 Aug
9 Sep
10 Oct
11 Nov
12 Dec
Annual -
110
1. The measured Net Energy export shall be calculated by adding all the net export values of the billing meters installed in the 33 KV Power Export
switchyard outgoing feeders.
2. If sum (f) is negative (-), there is shortfall in annual guaranteed Net Energy export for balance 10 years O & M period.
I. Short fall in Net Energy export for O & M period (Annually ) : ________kWh
II. Compensation for shortfall in net energy export for O & M period : Rs. Per kWh
III. Total Compensation payable : Rs. ______ Item (i) x Item (ii)
3. During the O & M period due to Battery replacements/substitutions if any short fall in sum (f) occurs, the corresponding penalty as per 3(iii) shall be
deducted in that year/years. If the above shortfall is compensated in the subsequent years Annual Net Energy Export (which shall be limited to maximum
three years), then the corresponding amount of compensation shall be returned in the corresponding subsequent years
111
Project Control
room
Metering Station
33kV 33KV
GARACHARMA Existing 33KV Grid feeders BAMBOOFLAT
SUBSTATION (Panther 1& Panther 2) SUBSTATION
112
113
114