Chapter 2: Literature Review
2.1     Categories of building projects
Building construction projects can be divided in to three parts.
      1. High rise building projects
      2. Medium scale building projects
      3. Small scale building construction projects
High-rise buildings are buildings, which have 10 or more than 10 stories. Mainly high
rise buildings are used for office complexes and apartment complexes. These are
owned by private companies or the govemment. Most of these buildings are
constructed by private construction companies. Since the cost involvements of these
constructions are high, these buildings can be constructed only by the construction
companies, which have ICTAD grades M1 or M2. The private consultancy
companies do the Consultancy pati of these buildings. High-rise building projects are
normally constructed at urban areas. Recently most of these building projects were
started in Colombo and suburbs in Sri Lanka to facilitate the housing demand of
urban population.
Medium scale buildings are those, which have 2 to 10 stories. These buildings also
used as office complexes, shopping complexes and apartment complexes. These are
owned by individuals, private companies or the govemment. Most of these buildings
are constructed by private construction companies with the consultancy of private
consultation companies. Due to the cost involvement, construction companies which
having ICTAD grades Ml, M2 or M 3 can engage in construction ofthesc buildings.
                                           11
Small-scale construction projects are mainly consists of house construction projects.
Houses are considered as individual dwelling units. Normally houses consist of single
or two-storied buildings. Most of the occasions in house construction projects, the
involvement of the consultants is limited to prepare of designs. Usage of proper
project management methods is also minimal in these projects.
In this research, our focus is mainly on medium scale building construction projects.
Since these buildings are constructed all over the Sri Lanka, identification of causes
of project delays and their effects can be of great help for the professionals working
in those projects.
2.2       Types of Project Delays
Delays can be due to the fault of consultant, contractor or client. They can be
categorized in to three types (Williams, 2003).
      o   Excusable compensable delays
These delays are occurring due to the fault of clients. Therefore, contractors can claim
for damages and extension of time.
      o   Excusable non compensable delays
These are occurring due to other causes excluding the faults of clients and
contractors. Therefore, contractor can claim for extension of time. However,
contractor cannot claim for the damages. At the same time, clients cannot claim for
liquidation damages as well.
      •   Non excusable non compensable delays
These delays occmTed due to contractors' faults. Therefore, the contractor cannot
claim extension of time whereas, clients can claim for the liquidation damages of
such delays.
                                           12
      2.3        Studies on Causes of Project delays
      There are many studies carried out in all over the world to identify the causes of the
      project delays. However, specific studies to identify the causes and effects of project
      delays were limited.
      Sambasivan and Soon (2007) conducted a study to identify the causes and effects of
      the project delays in Malaysian construction industry. They have initially identified
      28 causes for delays of construction projects. They have divided these causes in to
      eight categories as follows,
            1. Client related causes
                      1.    Finance and payments of completed work
                     11.    Owner Interference
                    111.    Slow decision making
                     1v.    Unrealistic contract duration and requirements imposed
            2. Contractor related causes
                      1.    Subcontractors
                     11.    Site management
                     u1.    Construction methods
                     IV.    Improper planning
                      v.    Mistakes during construction stage
                     v1.    Inadequate contractor experience
            3.    Consultant related causes
                       1.   Contract management
                      11.   Preparation and approval of drawings
                     111.   Quality assurance/control
                     IV.    Waiting time for approval of tests and inspection
                                                   13
...
        4. Material related causes
                 1.        Quality of material
                11.        Shortage in material
        5. Labor and equipment category causes
                 1.        Labor supply
                11.        Labor productivity
               111.        Equipment availability and failure
        6. Contract related causes
                 1.        Change orders
                11.        Mistakes and discrepancies in contract document
         7. Contract relationship related causes
                  1.       Major disputes and negotiations
                 11.       Inappropriate overall organizational structure linking to the project
                111.       Lack of communication between the parties
         8. Extemal causes
                      1.    Weather condition
                 11.        Regulatory changes
                 111.       Problem with neighbors
                 IV.        Unforeseen site condition
      Accordingly, major causes of project delays in Malaysian construction industry are
      identified as follows (Sambasivan & Soon, 2006).
                                                     14
I.-
    1. Contractor's improper planning
   2. Contractor's poor site management
    3. Inadequate contractor experience
   4. Inadequate client's finance and payments for completed work
    5. Problems with subcontractors
    6. Shortage in material
    7. Labor supply
    8. Equipment availability and failure
    9. Lack of communication between parties
    10. Mistakes during the construction stage
In this study, the analysis was done by considering the total construction industry as a
whole. However the causes and effects of delays can be, vary with the type of the
project. For example, the causes of delays in building construction project can be
different from road construction project. Whereas the causes and effects of project
delays can be, vary from country to country.
Same kind of study was carried out by Alagbari et. al (2007). to identify the main
causes of delays in building construction projects in Malaysia. They have divided the
causes of project delays according to the responsibility. They have initially identified
32 causes of building project delays and categorized them according to the
responsibility of contractor, owner, consultant or extcmal as follows.
    1. Contractor's responsibility
             1.   Delay in delivery of materials to site
            11.   Shortage of materials on site
           111.   Construction mistakes and defective work
           IV.    Poor skills and experience oflabour
            v.    Shortage of site labour
           VJ.    Low productivity of labour
                                            15
             v11.           Financial problems
            vm.             Coordination problems with others
              IX.           Lack of subcontractor's skills
              x.            Lack of site contractor's staff
              XJ.           Poor site management
             xu.            Equipments and tool shortage on site
       2. Consultant's responsibility
                       1.       Absence of consultant's site staff
                      11.       Lack of experience on the part of the consultant
                     111.       Lack of experience on the part of the consultant's site staff
                                (managerial and supervisory personnel)
                     1v.        Delayed and slow supervision in making decisions
                      v.        Incomplete documents
                     VI.        Slowness in giving instructions
       3. Owner's responsibility
                       1.       Lack of working knowledge
                      11.       Slowness in making decisions
                     lll.       Lack of coordination with contractors
                     IV.        Contract modifications (replacement and addition of new work
                                to the project and change in specifications)
                      v.        Financial problems (delayed payments, financial diff:icultics,
                                and economic problems)
       4. External factors
                1.          Lack of materials on the market
               11.          Lack of equipment and tools on the market
              lll.          Poor weather conditions
              IV.           Poor site conditions (location, ground, etc.)
               v.           Poor economic conditions (currency, intlation rate, etc.)
              VI.           Changes in laws and regulations
                                                     16
lo.,
                vu.    Transpotiation delays
               Vlll.   Extemal work due to public agencies (roads, utilities and public
                       services)
     The main causes of project delays in Malaysian building construction projects were
     identified as follows (Algabari eta!, 2007).
               1. Financial difficulties and economic problems
               2. Supervision too late and slowness in making decisions
               3. Slow to give instructions
               4. Lack of materials on market
               5. Poor site management
               6. Material shmiages on site
               7. Construction mistakes and defective work
               8. Delay in delivery of materials to site
               9. Slowness in making decisions
                10. Lack of consultants experience
                11. Incomplete documents
     The study identified that the financial problems as the main factor in delaying
     construction projects from the contractor's as well as owners' point of view. From the
     consultants point of view the main factor that contributes to delay in construction
     projects was inclfcctive or lack of supervision, followed by slowness of giving
     instructions and lack of experience. The most impmiant extemal factor that causes
     delays was lack of material, tools & equipments at the site.
     The findings of Algabari et. al (2007) was different from that of Sambasivam and
     Soon (2007), although both researches were carried out in Malaysia at same time
     period. Sambasivam & Soon (2007) used generalized approach whereas Algabari et.
     a!. (2007) used specific approach to identify project delays in building construction
                                                17
..
projects in Malaysia. This shows that the causes of project delays can be vary from
project to project.
Asaaf and Al-Hejji (2006) identified causes of delays and their importance in large-
scale construction projects in Saudi Arabia. They identified 73 causes of project
delays by literature survey and interviewing the professionals involved in the
construction industry. They categorized those causes under nine categories as
follows.
    1. Project related
                        1. Original contract duration is too short
                       II.   Legal disputes b/w various parts
                      111.   Inadequate definition of substantial completion
                      IV.    Ineffective delay penalties
                       v. Type of construction contract (Turnkey, construction only)
                      v1. Type of project bidding and award (negotiation, lowest bidder)
    2. Owner related
                        1. Delay in progress payments by owner
                       11.   Delay to furnish and deliver the site to the contractor by the
                             owner
                       111. Change orders by owner during construction
                       IV.   Late in revising and approving design documents by owner
                        v. Delay in approving shop drawings and sample materials
                       v1. Poor communication and coordination by owner and other
                             parties
                      VII.   Slowness in decision making process by owner
                      vu1. Conflicts between joint-ownership of the project
                       IX.   Unavailability of incentives for contractor for finishing ahead
                             of schedule
                        x. Suspension ofwork by owner
                                                 18
     3. Contractor related
                     1.    Difficulties in financing project by contractor
                    11.    Conflicts in sub-contractors schedule in execution of project
                   111.    Rework due to enors during construction
                   IV.     Conflicts b/w contractor and other parties (consultant and
                           owner)
                    v. Poor site management and supervision by contractor
                   VI.     Poor communication and coordination by contractor with other
                           parties
                   VII.    Ineffective planning ami scheduling of project by contractor
                  Vl!L     Tmprq~u c,;,1si.ruCLion    methods impkrncdcd by contractor
                    IX.    Delays in sub-contractors work
                     x. Inadequate contractor's work
                   XI.     Frequent change of sub-contractors because of their i11efficicnt
                           work
                   xu.     Poor qualification of the contractor's technical staff
                  XIII.    Delay in site mobilization
     ..J.. Consultant rdatcd
                      1.   Delay in performing inspection and testing by consultant
                    11.    Delay in approving major changes in the scope of work by
                           consultant
                    111.   lnilexibility (rigidity) of con~;ultant
                    tv.    Puor conm1unication/coorJination bclween consultant and
                           other parties
                     v. Late in reviewing             and approving design   documents by
                           consulLtnt
                    VI.    Conflicts between consultant and design engineer
                   VII.    Inadequate experience of consultant
                                                 19
..
    5. Design related
                     1.     Mistakes and discrepancies in desit,TJ1 documents
                    II.     Delays in producing design documents
                  lll.      Unclear and inadequate details in drawings
                   1v. Complexity of project design
                    v. Insufficient data collection and survey before design
                   VI.          Misunderstanding of owner's requirements by design engineer
                  VII.      Inadequate design-team experience
                 Vlll.          Un-use of advanced engineering design software
    6. :vraterials related
                     L          ShurLlge of construe lion materials in market
                    11. Changes            in   material     types   and   specifications   during
                                construction
                   lll.         Delay in material delivery
                   IV.          Damage of sorted material while they arc needed urgently
                    v.          Delay in manufacturing special building materials
                   VI.          Late procurcmc11t of materials
                  VII.          Late in selection of finishing materials due to availability of
                                many types in market
    7. Equipment related
                     1. Equipment breakdowns
                    tl.         Shortage of equipment
                   111.         Low level of equipment-operator's skill
                   1v. Low productivity and efficiency of equipment
                    v. Lack ofhigh-teclmology mechanical equipment
    8. Labors related
                           1.       Shortage of labors
                          11.       Unqualified workforce
                      111.          Nationality of labors
                                                    20
L
                      1v.       Low productivity level of labors
                      v.        Personal conflicts among labors
      9. External causes
                     1. Effects of subsurface conditions (e.g., soil, high water table,
                            etc.)
                    11. Delay in obtaining pem1its from municipality
                    111. Hot weather effect on construction activities
                    1v. Rain effect on construction activities
                     v. Unavailability of utilities in site (such as, water, electricity,
                            telephone, etc.)
                    v1. Effect of social and cultural factors
                   v11. Traffic control and restriction at job site
                   v111. Accident during construction
                    1x. Differing site (ground) conditions
                     x. Changes in government regulations and laws
                    x1. Delay in providing services from utilities (such as water,
                            electricity)
                    x11. Delay in perfonning final inspection and ceriification by a third
                            party
    Ranking of CclllS\~S for delays in large construction projects in Saudi Aral;ia were
    categorized according to the respondents as table 1.1. (Asaafand Al-Hejji, 2006).
                                                21
L
    Table 1.1- Causes of project delays in large construction projects in Saudi Arabia
    (Asaaf and Al-Hejji, 2006)
                                                                                                        I
        Causes identified by                Causes identified by          Causes identified by
        Clients                      contractors                          consultants
     1  Shortage of labor            Delay in progress payments           Type of project bidding and
                                     by owners                            award
    2 Unqualified work force         Late in reweaving &                  Shortage of labor
                                     approving of design
                                     documents by owners
     3 Ineffective planning by        Change orders during                Delay in progress payments
         contractor              -
                                     constructions                        by owners
     4 Low productivity level of     Delay in producing design            Ineffective planning by
         labor                        documents                           contractor            ·----
     5 Hot weather effect on          Late in reweaving &                 Change orders by owner
         construction activities      approving of design                 during constructions
                                      documents by consultant
     6 Conflicts with sub             Difficulties in financing           Low productivity level of
         contractors                 _project by contractor               labor
     7 Poor site management by        Mistakes & discrepancies in         Difficulties in financing
         contractors                  design documents                    project by contra_ctor    --
     8 Inadequate contractor          Late procurement of                 Poor site management by
        ~xpenence___________          materials                           contractors             ----
    r--                              -----------------
     9 Effects of surface conditions Inf1exibility of consultant          Poor qualifications of
                                        ---
                                                                          contmctors technical staff
     10 Change orders by owner              Slowness of decision making   Delay in material delivery
        during constructions                by owners
     Asaaf and Al-Hejji (2006) ranked the causes of delays as follows.
        1. Ow·ncr related   i~1ctors
        2. Contractor related factors
        "
        .),   Design team related factors
        4. Labor related factors
        5. Consultant related factors
        6. Material related factors
        7. External factors
        8. Project elated factors
        9. Equipment related factors
                                                  22
L
     Average time ovemm in large construction projects in Saudi Arabia was between
     10% and 30% of original duration (Asaaf and Al-Hejji, 2006). Study indicated that
     the highest frequency factor for the delay was awarding the contracts to the lowest
     bidder. Common cause identified by all the parties was "Change orders by owner
     during construction".
     Major causes of project delays in large construction projects in Saudi Arabia
     identified by Asaaf and Al-Hejji (2006) is different from findings of Sambasivam &
     Soon (2007). In Saudi Arabia labour problem is one of the major cause for project
     delays (Asaaf and Al-Hejji, 2006), whereas in Malaysia labour problem has obtained
     middle level significance (Sambasivam & Soon, 2007). This shows that causes of
     project delays can be different from country to country.
     Odeh and Battaineh (2002) identified causes of delay in traditional type of contracts
     in Jordan. This research was aimed at identifying the main causes for delay in
     construction projects with traditional type contracts. Twenty-Eight causes of delays
     were identified in traditional construction projects in Jordan and categorized them in
     to following major gToups (Odeh & Battaineh, 2002).
         1. Client related factors
                         1. Finance and payments of completed work
                        11. Owner interference
                       111.    Slow decision making by owners
                        1v. Unrealistic imposed contract duration
         2. Contractor related factors
                         1. Subcontractors
                        11. Site management
                        lll.   Construction methods
                        1v. Improper planning
                         v. Mistakes during construction
                        v1. Inadequate contractor experience
                                                 23
''
L
       3. Consultant related factors
                      1. Contract management
                     11. Preparation and approval of drawings
                    1n. Quality assurance & control
                     1v. Waiting time for approval of tests and inspections
       4. Material related factors
                      1. Quality of material
                     11. Shortage of material
       5. Labor & equipment related factors
                      1. Labor supply
                     11. Labor productivity
                     111. Equipment availability and failure
       6. Contract related !actors
                      1. Change orders
                      11. Mistakes and discrepancies in contract document
       7. Contractual relationship related factors
                       1. Major disputes and negotiations
                      11.   Inappropriate overall org<mization structure linking all parties
                            to the project
                     111. Lack of communication among parties
        8. External factors
                       1. Weather conditions
                      11. Regulatory changes and building code
                      111. Problems with neighbors
                      1v. Unforeseen ground conditions
                                                24
....
According to findings ofOdeh and Battaineh (2002) major causes ofproject delays in
traditional construction projects can be ranked as follows.
Table 1.2- Causes ofproject delays in traditional contracts in Jordan (Odeh and
Battainelz, 2002)
       Causts identified by consultants           Causes identified by contractors
I      Inadequate contractor ex12erience          Labor productivity problems
2      Finance & payment problems of clients      Owner interference
3      Subcontractor related issues               Inadequate contractor experience
4      Owner interference                         Finance & payment problems of
                                                  clients                         ---·--·---
5      Slow decision making by mvners             Improper site management by
                                                  contractors
6      Unrealistic contract durations given by    Improper construction methods by
       clients                                    contractors
7      Improper contract management by            Equipment availability & failures
      consultants                                   --- r---
 8 Improper planning by contractor                       Slow decision making by owners
 9   _Labor pro_d ucti v i_!:Y_j2_to bler~~_s________ -Subcontractor   related issues
                                                          ---------------------
f---
 10 Shortage of labor                                    Improper planning by contractor
 Accordingly, the main factor contributes to delays in traditional construction projects
 in Jordan was Jack of labour productivity. This was again different from the
 Malaysian studies (Sambasivam & Soon, 2006). This depicts causes of delays can be
 varied t!-om country lo country.
 Frimpong et. al. (2003) carried out a case study to analyze causes of delays of
 groundwater projects in Ghana. Ground water projects consists of ground water
 exploration, bore hole drilling, pumping test, water quality analysis and civil works.
 Frimpong et. al. (2003) had identified 26 factors for the project delays by taking in to
    consideration of a specific ground water project in Ghana. The identified causes of
    delays arc as follows.
                                             25
1. Planning and scheduling deficiencies
2. Deficiencies in cost estimates prepared
3. Inadequate control procedures
4. Delays in work approval
5. Waiting for infonnation
6. Mistakes during construction
7. Delays in inspection and testing ofwork
8. Cash flow during construction
9. Frequent breakdowns of construction plant and equipment
 10. Shortages of technical personnel
 11. Labor shortages
 12. Monthly payment difficulties
 13. Poor contract management
 14. Shortage of materials, Plant/equipment parts
 15. Contractor's financial difficulties
 16. Low bid
 17. l'v1aterial procurem;::'nt
  18. Imported materials
  19. Late delivery ofmaterials and equipment
  20. Escalation of material prices
  21. Slow decision-making
  22. Inflation
  23. Difficulties in obtaining construction materials :1t onicial current prices
  24. Ground problems
  25. Bad weather
   26. Unexpected geological conditions
According to findings of Frimpong ct. al. (2003) ranked causes of delays of ground
water project are as follows.
   1. Monthly payment difficulties
   2. Poor contract management
    3. Material procurement
                                             26
         4. Inflation
         5. Contractor's financial difficulties
         6. Escalatim1 of material prices
         7. Cash flow during construction
         8. Planning and scheduling difficulties
         9. Bad weather
          10. Deficiencies of cost estimate prepared
       Findings of Nigeria (Frimpong et. al., 2003) were inline with that of Malaysia
       (Sam basi van & Soon, 2006). According to the both of studies, financial problems was
       identified as main ca1Jse for project delays. Rese<Jrch carried out by Frim1Jong ct. al.
       (2003) did not consider whole construction industry in Ghana. It only considered
       about a specific project.
       Jayawardane & Pandita (2003) identified 45 L1ctors for project delays of construction
       industry in Sri Lanka. They categorized those causes in to 11 categories as follows.
           1. Material related factors
                           1.        Shmiage of material
                          11.        Change the type and specifications
                          111.       Slow delivery
                          1V.        Damage in storage on site
           2. Manpower
                            1.       Shortage
                           11.       Labour skills
                          Ill.       Labour disputes/Strikes
            3. Equipment
                                      Failure
                            11.
                                1.
                                      Shortage
                                                                                  ...   ..
                            111.      Unskilled operation
                            1V.       Slow delivery
                                                           27
....
               v. Old machinery
4. Financing
                1. Contractor's cash position
               11. Delay in payments by clients
               111. Delay in certification by consultant
5. Changes
                1. Owner I consultant
                11.        Errors made by consultant
               111.        Foundation conditions encountered at field
               1v. Mistakes in soil investigation
                v. Water table condition
               v1. Geological condition at the site
               v11. Errors committed during construction at site
 6. Government relations
                  1.       Obtaining permits from relevant authorities
                 11. Excessive bureaucracy in Govemment offices
 7. Scheduling
                  1. Preparation and approval of drawings
                 11. Lack of training of management to model the construction
                           operation
                111.        Lack of data base in estimating duration and resources
                 1v. Inadequate early planning
 8. Controlling
                      1.    Waiting for sample approval
                  11. Inspection and testing procedure
                                                28
       9. Environment
                        1.    Rainy weather
                       II.    Social and cultural factors
                      111.    Limited working hours
        l 0. Contractual Relationship
                        1.    Conflicts between contractor and consultant
                       II.   Uncooperative owner
                      III.   Slowness of owner's decision making process
                      IV.    Joint ownership
                      v. Poor organization of contractor and consultant
                     VI.     Difficulties of coordination and insufficient communication
                    VII.     Delay due to sub contractor
                    Vlll.    Delay due to lack of facilities to sub contractor
                     IX.     Unavailability of professional construction management team
                      x. Legal disputes between parties involved in the project
       11. Location of site
                       1.    Access to the site
                      II.    Surrounding
                     111.    Lack of area for operation/ material stocks
     According to Jayawarclane & Pandita (2003), main delaying factor identified was
     rainy weather. Since Sri Lanka is a tropical country, this can be well acceptable. The
     other main causes of project delays identified by them were "Design changes by
     owners & consultants" and "Manpower shortages". Jayawardane & Panditha (2003)'s
     findings were generalized to the building construction projects in Sri Lanka.
     Project size, which measured in m 2 gross external floor area, and project standard,
     which measured in building construction cost/m 2 gross external floor area are founded
     as significant drivers of construction speed in residential building projects in
                                                  29
I
I.
L
    Gcnnany (Stoy et.al., 2007). This shows that the speed of construction can be vary
    with the type of the project.
    The causes of delays can be varied according to following factors.
          l. Geographical location of the project
          2. Type of the construction project
          3. Method of the construction project (i.e. traditional construction projects, Turn
             key projects, etc.)
    2.4      Studies on Effects due to construction delays
    Aibinu and Jagboro (2002) identified the efCects of construction delays in Nigeria.
    The identified effects due to project delays in Nigeria are as follows,
          l. Time ovenun
          2. Cost ove1Tun
          3. Disputes
          4. Arbitration
          5. Litigation
          6. Total abandonment
    According to their analysis ranking of eiiects of project delays were as follows
    (Anibu and Jagboro 2002).
          1. Time overrun
          2. Cost overrun
          "j , Disputes
          4. Total abandonment
          5. Arbitration
          6. Litigation
                                                 30
~
Effects of the delays in construction projects can be changed according to the type of
project (Samabasivan &      Soon, 2006). For example, delays in infrastructure
development project like southem high way will cause huge economic loss to the
whole country, whereas delay in construction of house can only affect to the
respective client.
 Sambasivan & Soon (2007) adopted same effects of project delays identified by
Anibu and Jagboro (2002). The ranking of effects due to project delays in Malaysian
construction industry as follows (Sambasivan & Soon, 2007).
     1. Time overrun
     2. Cost overrun
     3. Disputes
     4. Arbitration
        5. Litigation
        6. Total abandonment
 Although the first two effects due to project delays were identical in Malaysia
 (Sambasivan & Soon, 2007) and in Nigeria (Anibu & Jagaboro, 2002) "total
 abandonment" was more prominent in Nigeria. In Malaysia, "total abandonment" was
 categorized at last. This shows that the effects due to project delays can be varied
  from lhe country to country.
  2.5      :Methods to minimize project delays
  Most of studies identified that the improvement of 'contractors managerial skills' was
  one of the basic needs to reduce project delays Fringpong et.al. (2003) suggested
  introducing continuous training programs to contractors' managerial staff as a
  solution.
                                            31
                                                                                           ...;,.:
To reduce the selecting of incapable contractors at bidding stage Sambasivan & Soon
(2007) suggested introducing different selection process that gives more weight to
capabilities rather than the price of the bid.
''Change orders" is one of the major factors contributes to delays. To reduce delays
most of the studies suggested to minimize the change orders (Sambasivan & Soon,
2007; Assaf & Al-Hejji, 2006; Jayawardane & Pandita, 2003).
Fringpong et.al. (2003) suggested, introducing effective and efficient material
procurement system at the site level to minimize the shortage of materials at site.
To mitigate the delays occmTing due to approval of drawings Assaf and Al-Hcjji
(2006) suggeskd consultants to minimize the delays in the approval process.
Sambasivan and Soon (2007) suggested contractors to appoint able site managers for
the smooth execution ofwork .Since the site managers should plan the work program
according to day to day conditions they should be capable of handling those projects
with good project management skills.
To minimize the delays due to changes in weather conditions Jayawardane & Pandita
(2003) suggested to consider the weather pattems at the initial planning stage of the
project.
Since the 'shortage of labour' is a huge problem in construction industry
encouragement of existing workers to acquire new specialized skills was suggested
by Jayawardanc & Pandita (2006) after considering the construction industry in Sri
Lanka.
Aibinu and Jagboro (2002) suggested two methods to minimize project delays. First
was accelcralion of site activities and the second was to increase the contingency
allowances.
                                             32
    2.6      Relative Important Index
    Sambasivan & Soon(2007), Jayawardane & Pandita (2003), and Abinu & Jagoor
    (2002) used the relative impmiant index to determine the relative importance of the
    causes of project delays.
    They have adopted five point Liket scale to define the importance of the causes. The
    relative importance index as follow.
    RJI =    'j_yj_
             A*N
    Where 'W' is the weighting given to each factor by the respondent (ranging fi"om 1 to
    5), 'A' is the highest weight (i.e. 5), and 'N' is the total number of respondents. 'RII'
    value had a range from 0 to 1. Higher value of RII gives higher significance for the
    cause.
    Frimpong et. al. (2003) used same method to analyze the significance of causes.
    However, he names it     <lS   "relative impotiant weight".
    Assaf & AI. Hejji (2007) used diiierent approach to calculate the importance of the
    causes. He defined "Frequency Index" and "Severity Index" as follows.
    Frequency Index (FI)    =I a (n/N) * 100 /4
     Where "a" is the constant expressing the weight given by each respondent, "n" is the
     fi:cqucncy of tilt.? n;spon::;c, a1:d "N" i:; total number of rcspor;ses. Frequency index
     was used to categorize causes according to frequency of occurrence.
     Severity Index (SI)   =I a (n/N) * 100 /4
     Where "a" is the constant expressing the weight given by each respondent, "n" is the
     frequency of the response, and "N" is total number of responses. Severity index was
     used to categorize causes according to the severity of occurrence.
     The importance of each cause is based on the frequency and severity of it. Therefore,
     Assaf & A!. Hcjj i (2007) defined relative important index as follows.
                                                    33
l
Relative Importance Index (RII)               =   FI    * SI
Assaf & AI. Hejji (2007)'s approach of calculating relative impotiance index is better
than that of the other researchers'. Respondent has to answer two questions for one
cause (i.e. frequency of occunence and degree of severity), it gives more realistic
picture about the causes of delays.
2.7    Spearman's Rank Correlation Coefficient
The objective of rank conelation methods is to assess the degree of monotonicity
bct\veen two or more series of paired data (Costa & Roque, 2006). Conelation can be
defined as relationship measure among different parties of factors. It gives the
strength of their relationships. Speannan's rank correlation coefficient                            IS      a non-
parametric test. (Distribution free tests) These tests have the obvious advantage of not
requiring the assumption of normality or the homogeneity variance (Assaf & Al-
Hejji, 2006).
Speam1an's rank correlation coefficient can be defined as follows, when there are no
tied ranks.
p = 1 - 6} d        2                                                                     ~    .f•. . .../'.•;\\
                                                                                              '(.
                                                                                              &.
                                                                                                    •   •
                                                                                                             , .,
                                                                                                            ~¥#'1M
                                                                                                                     t
                                                                                                                     111:
                                                                                                                            (>"'
                                                                                                                                      .
                                                                                                                                   -;.-,.
                2
          n (n -1)                                                                        .
                                                                                          \ :>
                                                                                               \_:: --.:~:...
Where, 'd' is the difference in the rank of the values of each matched pair and 'n' is
the Number of pairs of rank.
 If tied rank exists, speannan' s rank conelation coefficient can be defined as follows,
 p=     -----=-----=----·----'1'-"--1
                                    ,__CI'-"-x.jyi) - cIxD C">'vi
         [ n ( Ixi 2) 2 -    (   LXi 2? r' 2      [   n ( LYi 2) 2 -   (   I y?) 2   Y2
                                                               34
Where,   X;   is the rank given by first group, y; is the rank given by second group and n
is the number of pairs of ranks.
In spearman's rank correlation coefficient if concordance is perfect p            =   1 If
discordance is perfect p     =   -1. The value of p in all other cases lies between these
limits (O'Brien & Griffiths, 1965). Spearman's rank conelation coefficient equal to 1
indicate the perfectly positive correlation. p= -1 indicates perfectly negative
correlation. p= 0 indicates no correlation among the pariies.
To check whether the value obtained for the spearman's rank conelation coefficient
could be a result of chance, significance level of the relationship is used. This
signilicance level can be checked by using a graph, which shows significant level and
the degree of freedom (Appendix 3). If the results are above 0.1% significance level,
it can be 99.9% confident that the correlation has not occurred by chance. If the
results are above 1% significance level, it can be 99 % confident that the correlation
has not occurred by chance.
 2.8     Chapter Summary
 There were quite a large number of researches were carried out in the world to
 identify causes of project debys and as well as there effects. The causes can be varied
 with the typ,:; or tlw projeLt. Although there were few rescarcht:s i11 Sri Lu1ka to
 identify the causes of project delays, no evidence was found regarding researches on
 their effects. Most of the researchers were used 'relative important index' method to
 identify the importance of the project delays. Those studies recommended
 'improvement of project management skills of the contractors' staff, 'minimization
 of change orders', 'introduction of efficient material procurement', etc. to reduce
 project delays.
                                               35