WORK ORDER

Ref : WO / TS / 17-18 / 002 Date : April 01st, 2017

To,

M/s Viera Enterprises,

Add : B-57, Malviya Nagar, Jaipur
Contact Person : Mr. Vivek Gupta
Mob. : 077929-45252
Email Id : vieraenterprises1@gmail.com

Sub. : Work Order for Waterproofing Treatment to be executed at Hotel Taleda Square, Gandhi Bhawan,
Ajmer, Rajasthan.

Dear Sir,

As per your Final quotation : QN/VE/16-17/1503 Dated March 15 th, 2017 and further discussion held with You,
We are pleased to award you the above mentioned Waterproofing Treatment work as per details given below.

No Particulars Unit Qty Rate

Water proofing of Toilets as approved method & details

1) Clean the surface to remove all loose particles and any
deleterious matter.
2) Mark all the hair cracks.
3) Open, widen up all the cracks and repair with polymer modified
mortar (cement: send: Dr. Fixit URP is in ratio 1:1:1)
4) Apply Primer coat of Dr. fixit URP (modified styrene butadiene
latex) with 45 GSM Geo-textile Fiber mesh.
Rate
1.0 5) Two coat of water proofing treatment with First coat of Dr. fixit Sqft 32.00
only
Pidifin 2k an elastomeric ready to use, cement based (Mix
with Cement, Fine sand, Fine aggregate 1.2 mm, Soft
acrylic polymer and Recron P.P. fiber) flexible
waterproofing is polymer modified cementitious two
component water proofing system which forms a flexible
reinforced membrane on the entire surface.
6) When the First Coat is dry, apply second coat of Dr. Fixit pidifin
2k on the entire above treated surface
 Water proofing treatment on Terrace as approved method & details
1) Clean the surface to remove all loose particles and any
deleterious matter.
2) Mark all the hair cracks.
3) Open, widen up all the cracks and repair with polymer modified
mortar (cement: send: Dr. Fixit URP is in ratio 1:1:1)
4) Making of Gola50X50 mm in the corner of the wall and floor by
cement mortar mix with Dr. Fixit URP (A multipurpose mortar
additive, adhesive and cement modifier). Including pasting of
GEO TEXTILE FIBER MESH 70 gsm by Dr. Fixit URP Cement
slurry.
Rate
2.0 5) Two coat of water proofing treatment with First coat of Dr. fixit Sqft 42.00
only
roof seal flex an elastomeric ready to use, cement based (Mix
with Cement, Fine sand, Fine aggregate 1.2 mm, Soft acrylic
polymer and Recron P.P. fiber) flexible waterproofing is polymer
modified cementitious two component water proofing system
which forms a flexible reinforced membrane on the entire
surface.
6) When the First Coat is dry second coat of Dr. fixit roof seal flex
on the entire above treated surface
Note:- Cement sand plaster 1:4 (mix with water proofing compound)
on the above treated surface in proper slop By the client is
recommended at their own cost.
3.0 Water proofing treatment on Water Tank or swimming pool as Sqft Rate 57.00
approved Only
1) Treatment of Construction joints as per specification - A U
shaped groove will be made of 10mm wide and 10-15mm deep.
Depth will be filled up with Polymer Modified Mortar consist
cement putty consistency one parts of compound Dr. Fixit URP
Mixed with one part of Cement and one part of sand.
2) Treatment of Tie Hole point - The tie hole points shall be cut
open up to a depth of 10 mm. Depth will be filled up with Dr.
Fixit Super Latex cement putty consistency one parts of
compound Acrylic Polymer Mixed with two part of Cement.
3) Apply of one coat DR. Fixit Super latex SBR in the cutting
surface and outer of the Water pipe. Peripheral gaps between
pipes and excavated hole to be filled with Depth will be filled up
with super fluid micro concrete.
4) Making of Gola 75X75 mm in the corner of the wall and floor by
cement mortar mix with Dr. Fixit Super Latex (A multipurpose
mortar additive, adhesive and cement modifier). Including
pasting Geo-textile Fiber mesh 70 GSM by Dr. Fixit Super
Latex Cement slurry.
5) Clean the surface to remove all loose particles and any
deleterious matter. Three coat of water proofing treatment with
First coat of Dr. Fixit Krystalline (a composed of high quality
cement, properly selected & graded inert aggregates,
proprietary waterproofing active chemicals & additives)
with cement slurry.
6) When the First Coat is dry Apply second coat of Dr. Fixit
 Fastflex ( a two component cementitious coating,
composed of high quality cement, properly selected &
graded fillers, additives and liquid polymer)on the entire
above treated surface.
7) When Second coat dry apply third and final coat of Dr. Fixit Fast
flex on the entire above treated surface.
Water proofing treatment on Vertical Wall From inside basement
as approved
1) Treatment of Construction joints as per specification - A U
shaped groove will be made of 10mm wide and 10-15mm deep.
Depth will be filled up with DR. FIXIT URP cement putty
consistency one parts of compound Acrylic Polymer Mixed with
two part of Cement. Including pasting of GEO TEXTILE
FABRIC 70 gsm by Dr. Fixit URP Cement slurry on all
Construction Joints and corner of walls.
2) Treatment of Tie Hole point - The tie hole points shall be cut
open up to a depth of 10 mm. Depth will be filled up with Dr.
Fixit URP cement putty consistency one parts of compound
Acrylic Polymer Mixed with two part of Cement.
3) Clean the above surface and apply one coat of Dr. Fixit
Rate
4.0 Krystalline for blocking the pores of surface. Sqft 50.00
Only
4) Making of Gola 75X75 mm in the corner of the wall and floor by
cement mortar mix with Dr. Fixit URP (A multipurpose mortar
additive, adhesive and cement modifier). Including pasting of
GEO Textile Fiber Mesh 70 GSM by Dr. Fixit URP Cement
slurry.
5) Two coat of water proofing treatment with First coat of Dr. fixit
Pidifin 2K an elastomeric ready to use, cement based (Mix with
Cement, Fine sand, Fine aggregate 1.2 mm, Soft acrylic
polymer and Recron P.P. fiber) flexible waterproofing is polymer
modified cementitious two component water proofing system
which forms a flexible reinforced membrane on the entire
surface.
6) When the First Coat is dry second coat of Dr. Fixit Pidifin 2K on
the entire above treated surface
Rate
5.0 Cement Grouting (with material) as per actual at site Nos. 360.00
Only
Rate
6.0 Epoxy Grouting (Labor only) Nos. 630.00
Only
Rate
7.0 PU Grouting (Labor only) Nos. 900.00
Only
Scope of Work
The Scope includes Water Proofing of Toilet, Terrace, Water Tank, and Swimming Pool & Vertical Wall of
Basement as per the details. We reserve our right to reduce/increase the scope of work and no claim for
compensation or revision of rates shall be entertained on this account.

Special Conditions
1) No damage will be allowed over the worked area.
2) Cement, sand, mortar, grit, water, electricity will be provided by client free of cost.
3) Plaster and concreting before waterproofing where ever required will be done by Client.
4) Major Civil Repair will be done by client before handed over the site to be treated to contractor.
5) Facility for lifting material such as lifts etc. will be provided by Client if Possible.
6) Protection plaster with neat punning as recommended over the water proofed area will be done by client
required as per standard norms for safety of coating.
7) Rs. 1 lac will be paid in advance with work order which will be adjusted on pro-rata basis in RA bills

Approved Make : Dr. Fixit

Mode of Measurement : Actual Area will be measured in Square feet as per coated at site.

Completion Date : The work will be completed in all respect up to 6 th Floor on 30th April, 2017, and for 7th Floor
up to 5th, May, 2017.

Accepted by : Viera Enterprises For :

Taleda Square

Authorized Signatory Authorized

Signatory
 Technical description of Products Used at Site

S. No. Product Name Description

1. Dr. Fixit Pidicrete URP Dr. Fixit Pidicrete URP is based on modified styrene butadiene latex supplied
(SBR Latex for as a ready to use bonding agent in liquid consistency. It is used for repair of
waterproofing & spalled concrete floors, columns, beams, chhajas, slabs & waterproofing of
repairs) toilets & bathrooms, small terraces etc. as it bonds strongly to old & new
concrete and to plasters. It reduces shrinkage, prevents cracking, dust pick
up & improves abrasion resistance.

2. Dr. Fixit Krystalline Dr. Fixit Krystalline is composed of high quality cement, properly selected &
(Cementitious graded inert aggregates, proprietary waterproofing active chemicals &
crystalline waterproof additives. It is used as a chemically active waterproofing treatment for
coating for concrete) concrete. Dr. Fixit Krystalline, when mixed with water and applied as a brush
coat to concrete, it penetrates deeply into the capillaries of the concrete to
form billions of needle like crystals which blocks the pores, voids & micro
cracks in concrete. It is effective against substances of high contact pH value
(Range pH 3-11 in contact and 2-12 with intermittent contact).

3. Dr. Fixit Fast flex (High Dr. Fixit Fastflex is a two component cementitious coating, composed of high
performance Polymer quality cement, properly selected & graded fillers, additives and liquid
modified Cementitious polymer. It is suitable for achieving waterproofing for the water retaining
Coating) structures such as swimming pools, water tanks, reservoirs, other wet areas,
etc, because it provides strong bonding, good waterproofing and excellent
resistant to hydrostatic water pressure by forming highly elastic seamless
coating over the applied concrete or masonry surfaces.

4. Dr. Fixit Pidifin 2K (2 Dr. Fixit Pidifin 2K is a two component cementitious & acrylic flexible
pack Cementitious waterproofing & protective coating composed of best quality portaland
waterproof Coating) cement, properly selected & graded aggregates, additives & acrylic emulsion
polymer as a binder. It is applied to waterproof and protect concrete and
similar structures. specially formulated for swimming pools, retaining walls,
pile Heads, water tanks, submerged tunnels, sumps, bridge decks, marbles,
granites and a wide variety of extreme service class structures because on
curing it forms an excellent elastomeric, waterproof & protective layer over
the substrate.
5. Dr. Fixit Super latex Dr. Fixit Super Latex is based on modified Styrene butadiene latex used for
(SBR Latex for high performance applications in waterproofing and repairs. It is used for
waterproofing & repairs of spalled concrete such as floors, columns, beams, chhajjas, slabs
repairs) & waterproofing of toilets & bathrooms & terraces. It bonds strongly to old &
new concrete & plaster.
6. Dr. Fixit Roofseal Flex Dr. Fixit Roofseal Flex is a two component cementitious coating, composed of
(Heavy Duty high quality cement, properly selected & graded fillers, additives and acrylic
Cementitious polymer. It is suitable for achieving waterproofing for roofs, because it
waterproof coating for provides strong bonding, good waterproofing and excellent resistant to
new terrace) hydrostatic water pressure by forming highly elastic seamless coating over
the applied concrete surfaces.
 Terms & Conditions
1. Subcontracting/Subletting
The Contractor shall not assign or sub-let the work given under the work order or any benefit or interest
therein without the prior written consent of the Employer.

2. Billing
Final bill will be raised on actual measurement of the site considering 60% material cost & 40% labor cost.
Price approved above is excluding VAT & Service Tax & other taxes. Although TDS will be deducted from
contractors bill as applicable & TDS certificate will be given to contractor for the same .

3. Time for Completion

Time is essence of this contract. All works completion date 30 th April, 2017 for internal works up to 6th floor,
outer & terrace works complete in all respect. For 7th floor completion of works in all respect is 05 th, May,
2017.You shall deploy all necessary resources, equipment, tools and tackles required to achieve the
Milestone completion dates. The owners reserve rights to get the work executed from any other agency at
your risk and cost if there is unreasonable delay in execution of the work or failure in complying with the
instructions given by the site in charge.

If for reasons beyond your control, if the work is delayed, you will be granted proportionate extension of time
to complete your work. However the extension so granted shall not vitiate the contract nor any claim of
compensation or increase in rates arising there of shall be entertained

4. Water & Electricity

Water and electricity if necessary for installation as well as for drinking purposes shall be arranged by the
Client up to completion of the entire work.

5. Payment Terms
Rs. 1 lac will be paid in advance with work order which will be adjusted on pro-rata basis in RA bills
Payment should be done against running bills after verified by SIte.
5% after completion of work at site after verified by Site Head.

6. Completion Certificate
Pursuant to the virtual completion of work in all respects to the entire satisfaction of the PMC/Architect, a
completion certificate shall be issued. However issuance of completion certificate does not preclude the
Employers rights under Defects Liability period.

7. Penalty

Penalty @ 1% per week will be charged for delay up to a maximum of 10% on contract value for delay in
execution of awarded work. It will be the responsibility of the Client to provide open front as per requirement.

8. Security Arrangement

The contractor shall be responsible for adequate security arrangement at site for all their labour safety, and
the employer shall not be responsible for the same in any manner.

9. Labour Shed & Site Office / Stores

The provision of labour shed and temporary stores for contractor tool & tackles shall be provided by client.
10. THAT the contractor will take due care and precaution to avoid any accident, mis-happenings and provide
the first aid facilities at the site and will be responsible for the safety & security of his labour in all respect.

11. THAT all the staff members, labour, workers, supervisor, equipment operators etc. will be the employee of
contractor itself, and the owner will not be in any way treated as an employer. The contractor will solely be
responsible for their wages, salary, overtime or any payment is concerned. That the contractor has to pay
gratuity, pension if any. All the workmen etc. will be on the role of contractor and the owner will not have any
right of appointing or to terminate the service of any workmen only the contractor will be entitled to do so as
an employer. In case any accident or any mis-happening takes place then the contractor will only be
responsible for all the damages, medical expenses, award/order/judgment/decree passed by any
Tribunal/Court of law such as Workmen Compensation Commissioner, Labour Court, Tribunal, Civil Court or
High Courts etc.

12. THAT whenever any registration is required either in the labour department or in any other department
related to labour law, PF department etc. the contractor will have to complete all the formalities in this regard
and he will alone be responsible for any violation of the statutory rules and regulations any department.

13. THAT if the contractor becomes bankrupt or is prevented from or delayed in execution and in completion of
the work, the owner shall be entitled to give the notice in writing to the contractor and if the satisfactory reply
is not received with 7 days from the date of notice, the owner shall be entitled to employ other contractor for
completing the balance work at the cost, risk and responsibility of the contractor and in that case also the
contractor shall be liable for a deduction of 25% from his bills for the work done by him.

14. THAT the labour, the staff members of the contractor are liable to be searched for security reasons and
without the express permission of the owner the contractor cannot take away any material, machines,
equipments etc. from the site.

15. THAT if the Project Head/Engineer at any time considers that some more workmen should be employed by
the contractor, contractor shall abide by the decision of the Project Head/Engineer and act accordingly.

16. THAT in case at any time the Project Head/Engineer of the owner disapproves some work done by the
contractor it will be removed by the contractor immediately at its own cost.

17. THAT if the Project Head/Engineer considers that some particular work has not been executed properly, the
contractor shall immediately dissembles that portion and installs the same again to the entire satisfaction of
the Project Head/Engineer.

18. THAT if the owner considers, during the course of work, some alteration, addition or omission, it shall be
intimated to the contractor and contractor shall comply with the instructions.

19. THAT all the damages caused by the accident or the carelessness of the workmen, or any material is
wasted or is misused by the workmen, will be to the account of the contractor, who shall make good the
same.
20. THAT save the matter provided in this work order, the rules, regulations and procedure of the owner shall be
applicable as amended from time to time.

21. Arbitration: The venue shall be civil court jurisdiction at Ajmer.

Thanking you,

Yours faithfully

M/S Taleda square Pvt. Ltd.

Accepted by

Viera Enterprises

__________

Witness:
[1] ________________________ [2]___________________________